OFFICE LEASE

Exhibit 10.8

This Office Lease (this “Lease”), dated as of the date set forth in Section 1.1, is made by and between CA-225 SANTA XXXXX STREET LIMITED PARTNERSHIP, a Delaware limited partnership (“Landlord”), and XACTLY CORPORATION, a Delaware corporation (“Tenant”). The following exhibits are incorporated herein and made a part hereof: Exhibit A (Outline of Premises); Exhibit B (Work Letter); Exhibit C (Form of Confirmation Letter); Exhibit D (Rules and Regulations); Exhibit E (Judicial Reference); Exhibit F (Additional Provisions), Exhibit F-1 (Landlord’s Furniture); Exhibit F-2 (Location of Building Signage), and Exhibit F-3 (Form of Letter of Credit).

1.	BASIC LEASE INFORMATION


1.1	Date:		June 22, 2011

1.2	Premises:

	1.2.1	“Building”:	000 X. Xxxxx Xxxxx Xxxxxx, Xxx Xxxx, Xxxxxxxxxx 00000, commonly known as 000 Xxxx Xxxxx Xxxxx.

	1.2.2	“Premises”:	Subject to Section 2.1.1, 28,748 rentable square feet of space located on the 12^th floor of the Building and commonly known as Suite 1200, the outline and location of which is set forth in Exhibit A. If the Premises includes any floor in its entirety, all corridors and restroom facilities located on such floor shall be considered part of the Premises.

	1.2.3	“Property”:	The Building, the parcel(s) of land upon which it is located, and, at Landlord’s discretion, any parking facilities and other improvements serving the Building and the parcel(s) of land upon which such parking facilities and other improvements are located.

	1.2.4	“Project”:	The Property or, at Landlord’s discretion, any project containing the Property and any other land, buildings or other improvements.

1.3	Term

	1.3.1	Term:	The term of this Lease (the “Term”) shall commence on the Commencement Date and end on the Expiration Date (or any earlier date on which this Lease is terminated as provided herein).

	1.3.2	“Commencement Date”:	The earlier of (i) the first date on which Tenant conducts business in the Premises pursuant to this Lease, or (ii) the later of (a) the date on which the Premises is Ready for Occupancy (defined in Exhibit B), or (b) August 1, 2011.

	1.3.3	“Expiration Date”:	The last day of the 52^nd full calendar month commencing on or after the Commencement Date.


11.4		“Base Rent”:


Period During Term	Annual Base Rent Per Rentable Square Foot		Monthly Base Rent Per Rentable Square Foot (rounded to the nearest 100th of a dollar)		Monthly Installment of Base Rent

Commencement Date through last day of 12^th full calendar month of Term	$	28.80	$	2.40	$	68,995.20

13^th through 24^th full calendar months of Term	$	31.20	$	2.60	$	74,744.80

25^th through 36^th full calendar months of Term	$	33.60	$	2.80	$	80,494.40

37^th through 48^th full calendar months of Term	$	36.00	$	3.00	$	86,244.00

49^th full calendar month of Term through Expiration Date	$	38.40	$	3.20	$	91,993.60


	Notwithstanding the foregoing, Tenant shall be entitled to an abatement of Base Rent, in the amount of $68,995.20 per month, for the first four (4) full calendar months of the Term.

1.5	”Base Year“ for Expenses:	Calendar year 2011.

	“Base Year” for Taxes:	Calendar year 2011.

1.6	”Tenant’s Share”:	8.2431% (based upon a total of 348,754 rentable square feet in the Building), subject to Section 2.1.1.



1.7	“Permitted Use”:	General office use or any other use that: (a) is limited to software development; (b) is legally permitted; (c) is not a retail use; (d) does not generate an unusual amount of foot traffic or noise; (e) does not impose an unusual burden on the Building systems; (f) does not pose an unusual risk to the Building or to the safety or health of its occupants or adversely affect Landlord’s or Tenant’s insurance coverage; and (g) in all other respects is consistent with a first-class office building.

1.8	”Security Deposit”:	$0.00, as more particularly described in Section 21.

	Prepaid Base Rent:	$68,995.20, as more particularly described in Section 3.

1.9	Parking:	72 unreserved parking spaces, at the rate of $135.00 per space per month, as such rate may be adjusted from time to time to reflect Landlord’s then current rates.

		Zero (0) reserved parking spaces, at the rate of $N/A per space per month.

1.10	Address of Tenant:	Before the Commencement Date:

		XACTLY Corporation 00 X. Xxxxxx Xxxxxx Xxx Xxxx, XX 00000 Attention: Facilities Manager

		From and after the Commencement Date:

		The Premises, Attention: Facilities Manager.

1.11	Address of Landlord:	CA-225 Santa Xxxxx Street Limited Partnership c/o Equity Xxxxxx 0000 Xxxxxxxxxx Xxxxx, Xxxxx 000 Xxx Xxxx, Xxxxxxxxxx 00000 Attention: 000 Xxxx Xxxxx Xxxxx Property Manager

		with copies to:

		Equity Xxxxxx 0000 Xxxxxx Xxxxx, Xxxxx 000 Xxx Xxxxx, XX 00000 Attn: Managing Counsel



		and Equity Xxxxxx Xxx Xxxxx Xxxxxxxxx Xxxxx Xxxxx 0000 Xxxxxxx, XX 00000 Attn: Lease Administration

1.12	Broker(s):	Intero Real Estate Services., a California corporation, and Terra Commercial, a California corporation (collectively, “Tenant’s Broker”), representing Tenant, and N/A (“Landlord’s Broker”), representing Landlord.

1.13	Building HVAC Hours and Holidays:	“Building HVAC Hours” means 7:00 a.m. to 6:00 p.m., Monday through Friday, excluding the day of observation of New Year’s Day, Presidents Day, Memorial Day, Independence Day, Labor Day, Thanksgiving Day, Christmas Day, and, at Landlord’s discretion, any other locally or nationally recognized holiday that is observed by other buildings comparable to and in the vicinity of the Building (collectively, “Holidays”).

1.14	“Transfer Radius”:	None

1.15	“Tenant Improvements”:	Defined in Exhibit B, if any.

1.16	“Guarantor”:	As of the date hereof, there is no Guarantor.

1.17	Letter of Credit:	As more particularly described in Section 7 of Exhibit F.

2.	PREMISES AND COMMON AREAS.

2.1

The Premises.

2.1.1 Subject to the terms hereof, Landlord hereby leases the Premises to Tenant and Tenant hereby leases the Premises from Landlord. Landlord and Tenant acknowledge that the rentable square footage of the Premises is as set forth in Section 1.2.2 and the rentable square footage of the Building is as set forth in Section 1.6; provided, however, that Landlord may from time to time re-measure the Premises and/or the Building in accordance with any generally accepted measurement standards selected by Landlord and adjust Tenant’s Share based on such re-measurement; provided further, however, that any such re-measurement shall not affect the amount of Base Rent payable for, the determination of Tenant’s Share with respect to, or the amount of any tenant allowance applicable to, the initial Term. At any time Landlord may deliver to Tenant a notice substantially in the form of Exhibit C, as a confirmation of the information set forth therein. Tenant shall execute and return (or, by notice to Landlord, reasonably object to) such notice within five (5) days after receiving it, and if Tenant fails to do so, Tenant shall be deemed to have executed and returned it without exception.

2.1.2 Except as expressly provided herein, the Premises is accepted by Tenant in its condition and configuration existing on the date hereof (or in such other condition and configuration as any existing tenant of the Premises may cause to exist in accordance with its lease), without any obligation of Landlord to perform or pay for any alterations to the Premises, and without any representation or warranty regarding the condition of the Premises, the Building or the Project or their suitability for Tenant’s business. Landlord shall deliver the Premises to Tenant vacant and with the floors cleared of trash and swept.

2.2 Common Areas. Tenant may use, in common with Landlord and other parties and subject to the Rules and Regulations (defined in Exhibit D), any portions of the Property that are designated from time to time by Landlord for such use (the “Common Areas”).

3. RENT. Tenant shall pay all Base Rent and Additional Rent (defined below) (collectively, “Rent”) to Landlord or Landlord’s agent, without prior notice or demand or any setoff or deduction, at the place Landlord may designate from time to time. As used herein, “Additional Rent” means all amounts, other than Base Rent, that Tenant is required to pay Landlord hereunder. Monthly payments of Base Rent and monthly payments of Additional Rent for Expenses (defined in Section 4.2.2), Taxes (defined in Section 4.2.3) and parking (collectively, “Monthly Rent”) shall be paid in advance on or before the first day of each calendar month during the Term; provided, however, that the installment of Base Rent for the first full calendar month for which Base Rent is payable hereunder shall be paid upon Tenant’s execution and delivery hereof. Except as otherwise provided herein, all other items of Additional Rent shall be paid within 30 days after Landlord’s request for payment. Rent for any partial calendar month shall be prorated based on the actual number of days in such month. Without limiting Landlord’s other rights or remedies, (a) if any installment of Rent is not received by Landlord or its designee within five (5) business days after its due date, Tenant shall pay Landlord a late charge equal to 5% of the overdue amount; and (b) any Rent that is not paid within 10 days after its due date shall bear interest, from its due date until paid, at the lesser of 12% per annum or the highest rate permitted by Law (defined in Section 5). Tenant’s covenant to pay Rent is independent of every other covenant herein.

4. EXPENSES AND TAXES.

4.1 General Terms. Except during the period in which Tenant is entitled to an abatement of Base Rent pursuant to Section 1.4, Tenant shall pay, in addition to Base Rent, in accordance with Section 4.4, for each Expense Year (defined in Section 4.2.1), an amount equal to the sum of (a) Tenant’s Share of any amount (the “Expense Excess”) by which Expenses for such Expense Year exceed Expenses for the Base Year, plus (b) Tenant’s Share of any amount (the “Tax Excess”) by which Taxes for such Expense Year exceed Taxes for the Base Year. No decrease in Expenses or Taxes for any Expense Year below the corresponding amount for the Base Year shall entitle Tenant to any decrease in Base Rent or any credit against amounts due hereunder. Tenant’s Share of the Expense Excess and Tenant’s Share of the Tax Excess for any partial Expense Year shall be prorated based on the number of days in such Expense Year.

4.2 Definitions. As used herein, the following terms have the following meanings:

4.2.1 “Expense Year” means each calendar year (other than the Base Year and any preceding calendar year) in which any portion of the Term occurs.

4.2.2 “Expenses” means all expenses, costs and amounts that Landlord incurs during the Base Year or any Expense Year because of or in connection with the ownership, management, maintenance, security, repair, replacement, restoration or operation of the Property. Landlord shall act in

a reasonable manner in incurring Expenses. Expenses shall include (i) the cost of supplying all utilities, the cost of operating, repairing, maintaining and renovating the utility, telephone, mechanical, sanitary, storm-drainage, and elevator systems, and the cost of maintenance and service contracts in connection therewith; (ii) the cost of licenses, certificates, permits and inspections, the cost of contesting any Laws that may affect Expenses, and the costs of complying with any governmentally-mandated transportation-management or similar program; (iii) the cost of all insurance premiums and deductibles; (iv) the cost of landscaping and relamping; (v) the cost of parking-area operation, repair, restoration, and maintenance; (vi) a management fee in the amount (which is hereby acknowledged to be reasonable) of 3% of gross annual receipts from the Building (excluding the management fee), together with other fees and costs, including consulting fees, legal fees and accounting fees, of all contractors and consultants in connection with the management, operation, maintenance and repair of the Property; (vii) payments under any equipment-rental agreements and the fair rental value of any management office space; (viii) wages, salaries and other compensation, expenses and benefits, including taxes levied thereon, of all persons engaged in the operation, maintenance and security of the Property, and costs of training, uniforms, and employee enrichment for such persons; (ix) the costs of operation, repair, maintenance and replacement of all systems and equipment (and components thereof) of the Property; (x) the cost of janitorial, alarm, security and other services, replacement of wall and floor coverings, ceiling tiles and fixtures in Common Areas, maintenance and replacement of curbs and walkways, repair to roofs and re-roofing; (xi) rental or acquisition costs of supplies, tools, equipment, materials and personal property used in the maintenance, operation and repair of the Property; (xii) the cost of capital improvements or any other items that are (A) intended to effect economies in the operation or maintenance of the Property, reduce current or future Expenses, enhance the safety or security of the Property or its occupants, or enhance the environmental sustainability of the Property’s operations, or (B) required under any Law that is enacted, or first interpreted to apply to the Property, after the date hereof; (xiii) the cost of tenant-relation programs reasonably established by Landlord; and (xiv) payments under any existing or future reciprocal easement agreement, transportation management agreement, cost-sharing agreement or other covenant, condition, restriction or similar instrument affecting the Property.

Notwithstanding the foregoing, Expenses shall not include:

(a) capital expenditures not described in clauses (xi) or (xii) above (in addition, (A) any capital expenditure shall be included in Expenses only if incurred after the Base Year and shall be amortized (including actual or imputed interest on the amortized cost) over the lesser of (i) the useful life of the item purchased through such capital expenditure, as reasonably determined by Landlord, or (ii) the period of time that Landlord reasonably estimates will be required for any Expense savings resulting from such capital expenditure to equal such capital expenditure; provided, however, that any capital expenditure that is included in Expenses solely on the grounds that it is intended to reduce current or future Expenses shall be so amortized over the period of time described in the preceding clause (ii); and (B) any capital expenditure that is incurred in the Base Year (and therefore excluded from Expenses pursuant to the preceding clause (A)) shall not be included, on an amortized basis or otherwise, in Expenses for any Expense Year);

(b) depreciation;

(d) costs of repairs to the extent Landlord is reimbursed by insurance or condemnation proceeds;

(e) except as provided in clause (xiii) above, costs of leasing space in the Building, including brokerage commissions, lease concessions, rental abatements, costs of constructing tenant improvements and construction allowances granted to specific tenants;

(f) costs of selling, financing or refinancing the Building;

(g) fines, penalties or interest resulting from late payment of Taxes or Expenses;

(h) organizational expenses of creating or operating the entity that constitutes Landlord;

(i) damages paid to Tenant hereunder or to other tenants of the Building under their respective leases;

(j) insurance deductibles other than (a) earthquake insurance deductibles up to the amount (the “Annual Limit”) of 0.5% of the total insurable value of the Property per occurrence (provided, however, that, notwithstanding any contrary provision hereof, if, for any occurrence, the earthquake insurance deductible exceeds the Annual Limit, then, after such deductible is included (up to the Annual Limit) in Expenses for the applicable Expense Year, such excess may be included (up to the Annual Limit) in Expenses for the immediately succeeding Expense Year, and any portion of such excess that is not so included in Expenses for such immediately succeeding Expense Year may be included (up to the Annual Limit) in Expenses for the next succeeding Expense Year, and so on with respect to each Expense Year; provided further, however, that in no event shall the portions of such deductible that are included in Expenses for any one or more Expense Years exceed, in the aggregate, 5.0% of the total insurable value of the Property), and (b) any other insurance deductibles up to $50,000.00 per occurrence;

(k) co-insurance payments;

(l) costs of cleaning up Hazardous Materials, except for routine cleanup performed as part of the ordinary operation and maintenance of the Property, and costs resulting from the presence of Hazardous Materials at the Property in amounts or conditions that violate applicable Laws (as used herein, “Hazardous Materials” means any material now or hereafter defined or regulated by any Law or governmental authority as radioactive, toxic, hazardous, or waste, or a chemical known to the state of California to cause cancer or reproductive toxicity, including (1) petroleum and any of its constituents or byproducts, (2) radioactive materials, (3) asbestos in any form or condition, and (4) materials regulated by any of the following, as amended from time to time, and any rules promulgated thereunder: the Comprehensive Environmental Response, Compensation and Liability Act of 1980, 42 U.S.C. §§9601 et seq.; the Resource Conservation and Recovery Act, 42 U.S.C. §§6901, et seq.; the Toxic Substances Control Act, 15 U.S.C. §§2601, et seq.; the Clean Xxxxx Xxx, 00 X.X.X. §§0000 et seq; the Clean Air Act, 42 U.S.C. §§7401 et seq.; The California Health and Safety Code; The California Water Code; The California Labor Code; The California Public Resources Code; and The California Fish and Game Code.);

(m) fines or penalties resulting from any violations of Law, negligence or willful misconduct of Landlord or its employees, agents or contractors;

(n) reserves;

(o) any cost of repairing damage resulting from a Casualty (defined in Section 11), other than (i) any insurance deductible (subject to clause (j) above), and (ii) if such damage is not covered by Landlord’s insurance (as determined without regard to any deductible), any portion of such cost that does

not exceed the maximum amount of the insurance deductible for such damage that would not have been excluded from Expenses under clause (j) above if such damage had been covered by Landlord’s insurance; or

(p) any cost of repairing damage resulting from a Taking (defined in Section 13).

lf, during any portion of the Base Year or any Expense Year, the Building is not 100% occupied (or a service provided by Landlord to tenants of the Building generally is not provided by Landlord to a tenant that provides such service itself, or any tenant of the Building is entitled to free rent, rent abatement or the like), Expenses for such year shall be determined as if the Building had been 100% occupied (and all services provided by Landlord to tenants of the Building generally had been provided by Landlord to all tenants, and no tenant of the Building had been entitled to free rent, rent abatement or the like) during such portion of such year. Notwithstanding any contrary provision hereof, Expenses for the Base Year shall exclude (a) any market-wide cost increases resulting from extraordinary circumstances, including Force Majeure (defined in Section 25.2), boycotts, strikes, conservation surcharges, embargoes or shortages, and (b) at Landlord’s option, the cost of any repair or replacement that Landlord reasonably expects will not recur on an annual or more frequent basis.

4.2.3 “Taxes” means all federal, state, county or local governmental or municipal taxes, fees, charges, assessments, levies, licenses or other impositions, whether general, special, ordinary or extraordinary, that are paid or accrued during the Base Year or any Expense Year (without regard to any different fiscal year used by such governmental or municipal authority) because of or in connection with the ownership, leasing or operation of the Property. Taxes shall include (a) real estate taxes; (b) general and special assessments; (c) transit taxes; (d) leasehold taxes; (e) personal property taxes imposed upon the fixtures, machinery, equipment, apparatus, systems, appurtenances, furniture and other personal property used in connection with the Property; (f) any tax on the rent, right to rent or other income from any portion of the Property or as against the business of leasing any portion of the Property; (g) any assessment, tax, fee, levy or charge imposed by any governmental agency, or by any non-governmental entity pursuant to any private cost-sharing agreement, in order to fund the provision or enhancement of any fire-protection, street-, sidewalk- or road-maintenance, refuse-removal or other service that is (or, before the enactment of Proposition 13, was) normally provided by governmental agencies to property owners or occupants without charge (other than through real property taxes); and (h) any assessment, tax, fee, levy or charge allocable or measured by the area of the Premises or by the Rent payable hereunder, including any business, gross income, gross receipts, sales or excise tax with respect to the receipt of such Rent. Any costs and expenses (including reasonable attorneys’ and consultants’ fees) incurred in attempting to protest, reduce or minimize Taxes shall be included in Taxes for the year in which they are incurred. Notwithstanding any contrary provision hereof, Taxes shall be determined without regard to any “green building” credit and shall exclude (i) all excess profits taxes, franchise taxes, gift taxes, capital stock taxes, inheritance and succession taxes, estate taxes, federal and state income taxes, and other taxes to the extent applicable to Landlord’s general or net income (as opposed to rents, receipts or income attributable to operations at the Property), (ii) any Expenses, and (iii) any items required to be paid by Tenant under Section 4.5. If any assessment included in Taxes can be paid by Landlord in installments, such assessment shall not be included in Taxes in any calendar year in an amount exceeding that which would be included in Taxes in such calendar year if such assessment were paid in the maximum number of installments permitted by Law.

4.3 Allocation. Landlord, in its reasonable discretion, may equitably allocate Expenses among office, retail or other portions or occupants of the Property. If Landlord incurs Expenses or Taxes for the Property together with another property, Landlord, in its reasonable discretion, shall equitably allocate such shared amounts between the Property and such other property.

4.4 Calculation and Payment of Expense Excess and Tax Excess.

4.4.1 Statement of Actual Expenses and Taxes; Payment by Tenant. Landlord shall endeavor to give to Tenant, after the end of each Expense Year, a statement (the “Statement”) setting forth the actual Expenses, Taxes, Expense Excess and Tax Excess for such Expense Year. If the amount paid by Tenant for such Expense Year pursuant to Section 4.4.2 is less or more than the sum of Tenant’s Share of the actual Expense Excess plus Tenant’s Share of the actual Tax Excess (as such amounts are set forth in such Statement), Tenant shall pay Landlord the amount of such underpayment, or receive a credit in the amount of such overpayment, with or against the Rent then or next due hereunder; provided, however, that if this Lease has expired or terminated and Tenant has vacated the Premises, Tenant shall pay Landlord the amount of such underpayment, or Landlord shall pay Tenant the amount of such overpayment (less any Rent due), within 30 days after delivery of such Statement. Any failure of Landlord to timely deliver the Statement for any Expense Year shall not diminish either party’s rights under this Section 4.

4.4.2 Statement of Estimated Expenses and Taxes. Landlord shall endeavor to give to Tenant, for each Expense Year, a statement (the “Estimate Statement”) setting forth Landlord’s reasonable estimates of the Expenses, Taxes, Expense Excess (the “Estimated Expense Excess”) and Tax Excess (the “Estimated Tax Excess”) for such Expense Year. Upon receiving an Estimate Statement, Tenant shall pay, with its next installment of Base Rent, an amount equal to the excess of (a) the amount obtained by multiplying (i) the sum of Tenant’s Share of the Estimated Expense Excess plus Tenant’s Share of the Estimated Tax Excess ( as such amounts are set forth in such Estimate Statement), by (ii) a fraction, the numerator of which is the number of months that have elapsed in the applicable Expense Year (including the month of such payment) and the denominator of which is 12, over (b) any amount previously paid by Tenant for such Expense Year pursuant to this Section 4.4.2. Until Landlord delivers a new Estimate Statement (which Landlord may do at any time), Tenant shall pay monthly, with the monthly Base Rent installments, an amount equal to one-twelfth (1/12) of the sum of Tenant’s Share of the Estimated Expense Excess plus Tenant’s Share of the Estimated Tax Excess, as such amounts are set forth in the previous Estimate Statement. Any failure of Landlord to timely deliver any Estimate Statement shall not diminish Landlord’s rights to receive payments and revise any previous Estimate Statement under this Section 4.

4.4.3 Retroactive Adjustment of Taxes. Notwithstanding any contrary provision hereof, if, after Landlord’s delivery of any Statement, an increase or decrease in Taxes occurs for the applicable Expense Year or for the Base Year (whether by reason of reassessment, error, or otherwise), Taxes for such Expense Year or the Base Year, as the case may be, and the Tax Excess for such Expense Year shall be retroactively adjusted. If, as a result of such adjustment, it is determined that Tenant has under- or overpaid Tenant’s Share of such Tax Excess, Tenant shall pay Landlord the amount of such underpayment, or receive a credit in the amount of such overpayment, with or against the Rent then or next due hereunder; provided, however, that if this Lease has expired or terminated and Tenant has vacated the Premises, Tenant shall pay Landlord the amount of such underpayment, or Landlord shall pay Tenant the amount of such overpayment (less any Rent due), within 30 days after such adjustment is made.

4.5 Charges for Which Tenant Is Directly Responsible. Tenant shall pay, 10 days before delinquency, any taxes levied against Tenant’s equipment, furniture, fixtures and other personal property located in or about the Premises. If any such taxes are levied against Landlord or its property (or if the assessed value of Landlord’s property is increased by the inclusion therein of a value placed upon such equipment, furniture, fixtures or other personal property of Tenant), Landlord may pay such taxes (or such increased assessment) regardless of their (or its) validity, in which event Tenant, upon demand, shall

repay to Landlord the amount so paid. If the Leasehold Improvements (defined in Section 7.1) are assessed for real property tax purposes at a valuation higher than the valuation at which tenant improvements conforming to Landlord’s “building standard” in other space in the Building are assessed, the Taxes levied against Landlord or the Property by reason of such excess assessed valuation shall be deemed taxes levied against Tenant’s personal property for purposes of this Section 4.5. Notwithstanding any contrary provision hereof, Tenant shall pay, 10 days before delinquency, (i) any rent tax, sales tax, service tax, transfer tax or value added tax, or any other tax respecting the rent or services described herein or otherwise respecting this transaction or this Lease; and (ii) any taxes assessed upon the possession, leasing, operation, management, maintenance, alteration, repair, use or occupancy by Tenant of any portion of the Property.

4.6 Books and Records. Within 60 days after receiving any Statement (the “Review Notice Period”), Tenant may give Landlord notice (“Review Notice”) stating that Tenant elects to review Landlord’s calculation of the Expense Excess and/or Tax Excess for the Expense Year to which such Statement applies and identifying with reasonable specificity the records of Landlord reasonably relating to such matters that Tenant desires to review. Within a reasonable time after receiving a timely Review Notice (and, at Landlord’s option, an executed confidentiality agreement as described below), Landlord shall deliver to Tenant, or make available for inspection at a location reasonably designated by Landlord, copies of such records. Within 60 days after such records are made available to Tenant (the “Objection Period”), Tenant may deliver to Landlord notice (an “Objection Notice”) stating with reasonable specificity any objections to the Statement, in which event Landlord and Tenant shall work together in good faith to resolve Tenant’s objections. Tenant may not deliver more than one Review Notice or more than one Objection Notice with respect to any Expense Year. If Tenant fails to give Landlord a Review Notice before the expiration of the Review Notice Period or fails to give Landlord an Objection Notice before the expiration of the Objection Period, Tenant shall be deemed to have approved the Statement. Notwithstanding any contrary provision hereof, Landlord shall not be required to deliver or make available to Tenant records relating to the Base Year, and Tenant may not object to Expenses or Taxes for the Base Year, other than in connection with the first review for an Expense Year performed by Tenant pursuant to this Section 4.6. If Tenant retains an agent to review Landlord’s records, the agent must be with a CPA firm licensed to do business in the State of California and its fees shall not be contingent, in whole or in part, upon the outcome of the review. Tenant shall be responsible for all costs of such review. The records and any related information obtained from Landlord shall be treated as confidential, and as applicable only to the Premises, by Tenant, its auditors, consultants, and any other parties reviewing the same on behalf of Tenant (collectively, “Tenant’s Auditors”). Before making any records available for review, Landlord may require Tenant and Tenant’s Auditors to execute a reasonable confidentiality agreement, in which event Tenant shall cause the same to be executed and delivered to Landlord within 30 days after receiving it from Landlord, and if Tenant fails to do so, the Objection Period shall be reduced by one day for each day by which such execution and delivery follows the expiration of such 30-day period. Notwithstanding any contrary provision hereof, Tenant may not examine Landlord’s records or dispute any Statement if any Rent remains unpaid past its due date. If, for any Expense Year, Landlord and Tenant determine that the sum of Tenant’s Share of the actual Expense Excess plus Tenant’s Share of the actual Tax Excess is less or more than the amount reported, Tenant shall receive a credit in the amount of its overpayment against Rent then or next due hereunder, or pay Landlord the amount of its underpayment with the Rent next due hereunder; provided, however, that if this Lease has expired or terminated and Tenant has vacated the Premises, Landlord shall pay Tenant the amount of its overpayment (less any Rent due), or Tenant shall pay Landlord the amount of its underpayment, within 30 days after such determination.

5. USE; COMPLIANCE WITH LAWS.

5.1 Tenant shall not (a) use the Premises for any purpose other than the Permitted Use, or (b) do anything in or about the Premises that violates any of the Rules and Regulations, damages the reputation of the Project, interferes with, injures or annoys other occupants of the Building, or constitutes a nuisance. Subject to Exhibit B, Tenant, at its expense, shall comply with all Laws relating to (i) the operation of its business at the Project, (ii) the use, condition, configuration or occupancy of the Premises, or (iii) the Building systems located in or exclusively serving the Premises; provided, however, that nothing in this sentence shall be deemed to require Tenant to make any change to any Common Area or the Base Building. If, in order to comply with any such Law, Tenant must obtain or deliver any permit, certificate or other document evidencing such compliance, Tenant shall provide a copy of such document to Landlord promptly after obtaining or delivering it. Subject to Exhibit B, if a change to any Common Area or the Base Building becomes required under Law (or if any such requirement is enforced) as a result of any Tenant-Insured Improvement (defined in Section 10.2.2), the installation of any trade fixture, or any use of the Premises other than general office use, Tenant, upon demand, shall (x) at Landlord’s option, either make such change at Tenant’s cost or pay Landlord the cost of making such change, and (y) pay Landlord a coordination fee equal to 5% of the cost of such change. As used herein, “Law” means any existing or future law, ordinance, regulation or requirement of any governmental authority having jurisdiction over the Project or the parties.

5.2 Landlord, at its expense (subject to Section 4), shall cause the Base Building and the Common Areas to comply with all Laws (including the Americans with Disabilities Act (“ADA”)) to the extent that (a) such compliance is necessary for Tenant to use the Premises for general office use in a normal and customary manner and for Tenant’s employees and visitors to have reasonably safe access to and from the Premises, or (b) Landlord’s failure to cause such compliance would impose liability upon Tenant under Law; provided, however, that Landlord shall not be required to cause such compliance to the extent non-compliance (x) is triggered by any matter that is Tenant’s responsibility under Section 5.1 or 7.3 or any other provision hereof, or (y) arises under any provision of the ADA other than Title III thereof. Notwithstanding the foregoing, Landlord may contest any alleged violation in good faith, including by applying for and obtaining a waiver or deferment of compliance, asserting any defense allowed by Law, and appealing any order or judgment to the extent permitted by Law; provided, however, that after exhausting any rights to contest or appeal, Landlord shall perform any work necessary to comply with any final order or judgment

6. SERVICES.

6.1 Standard Services. Landlord shall provide the following services on all days (unless otherwise stated below): (a) subject to limitations imposed by Law, customary heating, ventilation and air conditioning (“HVAC”) in season during Building HVAC Hours; (b) electricity supplied by the applicable public utility, stubbed to the Premises; (c) water supplied by the applicable public utility (i) for use in lavatories and any drinking facilities located in Common Areas within the Building, and (ii) stubbed to the Building core for use in any plumbing fixtures located in the Premises; (d) janitorial services to the Premises, except on weekends and Holidays; and (e) elevator service (subject to scheduling by Landlord, and payment of Landlord’s standard usage fee, for any freight service).

6.2 Above-Standard Use. Landlord shall provide HVAC service outside Building HVAC Hours if Tenant gives Landlord such prior notice and pays Landlord such hourly cost per zone as Landlord may require. Tenant shall not, without Landlord’s prior consent, use equipment that may affect the temperature maintained by the air conditioning system or consume above-Building-standard amounts of any water furnished for the Premises by Landlord pursuant to Section 6.1. If Tenant’s consumption of

electricity or water exceeds the rate Landlord reasonably deems to be standard for the Building, Tenant shall pay Landlord, upon billing, the cost of such excess consumption, including any costs of installing, operating and maintaining any equipment that is installed in order to supply or measure such excess electricity or water. For purposes of the preceding sentence, any consumption of electricity by specialty equipment in a computer server room shall be deemed to exceed the standard rate for the Building. The connected electrical load of Tenant’s incidental-use equipment shall not exceed the Building-standard electrical design load, and Tenant’s electrical usage shall not exceed the capacity of the feeders to the Project or the risers or wiring installation.

6.3 Interruption. Any failure to furnish, delay in furnishing, or diminution in the quality or quantity of any service resulting from any application of Law, failure of equipment, performance of maintenance, repairs, improvements or alterations, utility interruption, or event of Force Majeure (each, a “Service Interruption”) shall not render Landlord liable to Tenant, constitute a constructive eviction, or excuse Tenant from any obligation hereunder. Notwithstanding the foregoing, if all or a material portion of the Premises is made untenantable or inaccessible for more than three (3) consecutive business days after notice from Tenant to Landlord by a Service Interruption that Landlord can correct through reasonable efforts, then, as Tenant’s sole remedy, Monthly Rent shall xxxxx for the period beginning on the day immediately following such 3-business-day period and ending on the day such Service Interruption ends, but only in proportion to the percentage of the rentable square footage of the Premises made untenantable or inaccessible.

7. REPAIRS AND ALTERATIONS.

7.1 Repairs. Subject to Section 11, Tenant, at its expense, shall perform all maintenance and repairs (including replacements) to the Premises, and keep the Premises in as good condition and repair as when Tenant took possession and as thereafter improved by Landlord and/or Tenant, except for reasonable wear and tear and repairs that are Landlord’s express responsibility hereunder. Tenant’s maintenance and repair obligations shall include (a) all leasehold improvements in the Premises, whenever and by whomever installed or paid for, including any Tenant Improvements, any Alterations (defined in Section 7.2), and any leasehold improvements installed pursuant to any prior lease, but excluding the Base Building (the “Leasehold Improvements”); (b) all supplemental heating, ventilation and air conditioning units, kitchens (including hot water heaters, dishwashers, garbage disposals, instar-hot dispensers, and plumbing) and similar facilities exclusively serving Tenant, whether located inside or outside of the Premises, and whenever and by whomever installed or paid for; and (c) all Lines (defined in Section 23). Notwithstanding the foregoing, if Tenant fails to perform such maintenance and repairs as required hereunder, Landlord may, at its option, after notifying Tenant, perform such work on Tenant’s behalf, in which case Tenant shall pay Landlord, upon demand, the cost of such work plus a coordination fee equal to 10% of such cost. Landlord shall perform all maintenance and repairs to (i) the roof and exterior walls and windows of the Building, (ii) the Base Building, and (iii) the Common Areas. As used herein, “Base Building” means the structural portions of the Building, together with all mechanical (including HVAC), electrical, plumbing and fire/life-safety systems serving the Building in general, whether located inside or outside of the Premises.

7.2 Alterations. Tenant may not make any improvement, alteration, addition or change to the Premises or to any mechanical, plumbing or HVAC facilities or other systems serving the Premises (an “Alteration”) without Landlord’s prior consent, which consent shall be requested by Tenant not less than 30 days before commencement of work and shall not be unreasonably withheld by Landlord. Notwithstanding the foregoing, provided that Landlord receives 10 business days’ prior notice, Landlord’s prior consent shall not be required for any Alteration that is decorative only (e.g. carpet installation or painting) and not visible from outside the Premises or that (i) is reasonably estimated

(together with any other Alterations performed without Landlord’s consent pursuant to this sentence during the 12-month period ending on the date of such notice) to cost less than $25,000.00; (ii) is not visible from outside the Premises; (iii) does not affect any system or structural component of the Building; and (iv) does not require work to be performed inside the walls or above the ceiling of the Premises. For any Alteration, (a) Tenant, before commencing work, shall deliver to Landlord, and obtain Landlord’s approval of, plans and specifications; (b) Landlord, in its discretion, may require Tenant to obtain security for performance satisfactory to Landlord; (c) Tenant shall deliver to Landlord “as built” drawings (in CAD format, if requested by Landlord), completion affidavits, full and final lien waivers, and all governmental approvals; and (d) Tenant shall pay Landlord upon demand (i) Landlord’s reasonable out-of-pocket expenses incurred in reviewing the work, and (ii) a coordination fee equal to 3% of the cost of the work; provided, however, that this clause (d) shall not apply to any Tenant Improvements.

7.3 Tenant Work. Before commencing any repair or Alteration (“Tenant Work”), Tenant shall deliver to Landlord, and obtain Landlord’s approval of, (a) names of contractors, subcontractors, mechanics, laborers and materialmen; (b) evidence of contractors’ and subcontractors’ insurance; and (c) any required governmental permits. Tenant shall perform all Tenant Work (i) in a good and workmanlike manner using materials of a quality reasonably approved by Landlord; (ii) in compliance with any approved plans and specifications, all Laws, the National Electric Code, and Landlord’s construction rules and regulations; and (iii) in a manner that does not impair the Base Building. If, as a result of any Tenant Work, Landlord becomes required under Law to perform any inspection, give any notice, or cause such Tenant Work to be performed in any particular manner, Tenant shall comply with such requirement and promptly provide Landlord with reasonable documentation of such compliance. Landlord’s approval of Tenant’s plans and specifications shall not relieve Tenant from any obligation under this Section 7.3. In performing any Tenant Work, Tenant shall not use contractors, services, labor, materials or equipment that, in Landlord’s reasonable judgment, would disturb labor harmony with any workforce or trades engaged in performing other work or services at the Project.

8. LANDLORD’S PROPERTY. All Leasehold Improvements (excluding trade fixtures) shall become Landlord’s property upon installation and without compensation to Tenant. Notwithstanding the foregoing, if any Tenant-Insured Improvements are Specialty Improvements (defined below), then Tenant, to the extent required by notice from Landlord, and before the expiration or earlier termination hereof, shall, at its expense, remove such Tenant-Insured Improvements (other than Excluded Items (defined below)), repair any resulting damage to the Premises or Building, and restore the affected portion of the Premises to its condition existing before the installation of such Tenant-Insured Improvements (or, at Landlord’s election, to a Building-standard tenant-improved condition as determined by Landlord, but only to the extent that the cost of such restoration does not exceed the cost of restoring the affected portion of the Premises to its condition existing before the installation of such Tenant-Insured Improvements). If Tenant fails to timely perform any work required under the preceding sentence, Landlord may perform such work at Tenant’s expense. When Landlord approves any Tenant-Insured Improvements pursuant to Section 7.2 or Exhibit B (or, in the case of any Tenant-Insured Improvements that do not require such approval, if Tenant specifically requests that Landlord do so, then, within 15 business days after such request), Landlord shall identify any such Tenant-Insured Improvements that are Specialty Improvements and will be required to be removed pursuant to this Section 8, and any such Tenant-Insured Improvements that are not so identified by Landlord shall not be required to be removed pursuant to this Section 8. As used herein, “Specialty Improvements” means any Tenant-Insured Improvements that, in Landlord’s reasonable judgment, are not typical multi-tenant office installations, including equipment racks; classrooms; file rooms (with or without reinforced flooring); libraries; workout/fitness rooms; shower rooms; locker rooms; kitchen facilities (other than coffee bar kitchenettes); server rooms; safes; vaults; non-customary finishes; areas without drop ceilings; and any

space configurations or improvements that would reduce the marketability or usefulness of the Building as a multi-tenant office building. As used herein, “Excluded Items” means the Tenant Improvements shown with reasonable specificity on the Approved Space Plan (defined in Section 2.4 of Exhibit B), except for any trade fixtures and the following: the production room. Tenant’s trade fixtures, furniture and other personal property installed at the Premises shall remain Tenant’s property and may be removed by Tenant from the Premises at any time, provided that Tenant (a) complies with any provisions hereof governing the scheduling or manner of such removal, and (b) repairs any damage to the Premises or the Building caused by such installation or removal.

9. LIENS. Tenant shall keep the Project free from any lien arising out of any work performed, material furnished or obligation incurred by or on behalf of Tenant. Tenant shall remove any such lien within 10 business days after notice from Landlord, and if Tenant fails to do so, Landlord, without limiting its remedies, may pay the amount necessary to cause such removal, whether or not such lien is valid. The amount so paid, together with reasonable attorneys’ fees and expenses, shall be reimbursed by Tenant upon demand.

10. INDEMNIFICATION; INSURANCE.

10.1 Waiver and Indemnification. Tenant waives all claims against Landlord, its Security Holders (defined in Section 17), Landlord’s managing agent(s), their (direct or indirect) owners, and the beneficiaries, trustees, officers, directors, employees and agents of each of the foregoing (including Landlord, the “Landlord Parties”) for (i) any damage to person or property (or resulting from the loss of use thereof), except to the extent such damage is caused by any negligence, willful misconduct or breach of this Lease of or by any Landlord Party, or (ii) any failure to prevent or control any criminal or otherwise wrongful conduct by any third party or to apprehend any third party who has engaged in such conduct. Tenant shall indemnify, defend, protect, and hold the Landlord Parties harmless from any obligation, loss, claim, action, liability, penalty, damage, cost or expense (including reasonable attorneys’ and consultants’ fees and expenses) (each, a “Claim”) that is imposed or asserted by any third party and arises from (a) any negligence or willful misconduct of, Tenant, any party claiming by, through or under Tenant, their (direct or indirect) owners, or any of their respective beneficiaries, trustees, officers, directors, employees, agents, contractors, licensees or invitees, or (b) any breach by Tenant of any representation, covenant or other term contained herein, except to the extent such Claim arises from any negligence, willful misconduct or breach of this Lease of or by any Landlord Party. Landlord shall indemnify, defend, protect, and hold Tenant, its (direct or indirect) owners, and their respective beneficiaries, trustees, officers, directors, employees and agents (including Tenant, the “Tenant Parties”) harmless from any Claim that is imposed or asserted by any third party and arises from (a) any negligence or willful misconduct of any Landlord Party, or (b) any breach by Landlord of any representation, covenant or other term contained herein, except to the extent such Claim arises from any negligence, willful misconduct or breach of this Lease of or by any Tenant Party.

10.2 Tenant’s Insurance. Tenant shall maintain the following coverages in the following amounts:

10.2.1 Commercial General Liability insurance covering claims of bodily injury, personal injury and property damage arising out of Tenant’s operations and contractual liabilities, including coverage formerly known as broad form, on an occurrence basis, with combined primary and excess/umbrella limits of $3,000,000 each occurrence and $4,000,000 annual aggregate.

10.2.2 Property insurance covering (i) all office furniture, trade fixtures, office equipment, free-standing cabinet work, movable partitions, merchandise and all other items of Tenant’s

property in the Premises installed by, for, or at the expense of Tenant, and (ii) any Leasehold Improvements installed pursuant to this Lease (“Tenant-Insured Improvements”). Such insurance shall be written on a special cause of loss form for physical loss or damage, for the full replacement cost value (subject to reasonable deductible amounts) new without deduction for depreciation of the covered items and in amounts that meet any co-insurance clauses of the policies of insurance, and shall include coverage for damage or other loss caused by fire or other peril, including vandalism and malicious mischief, theft, water damage of any type, including sprinkler leakage, bursting or stoppage of pipes, and explosion, and providing business interruption coverage for a period of one year.

10.2.3 Workers’ Compensation statutory limits and Employers’ Liability limits of $1,000,000.

10.3 Form of Policies. The minimum limits of insurance required to be carried by Tenant shall not limit Tenant’s liability. Such insurance shall be issued by an insurance company that has an A.M. Best rating of not less than A-VIII and shall be in form and content reasonably acceptable to Landlord. Tenant’s Commercial General Liability Insurance shall (a) name the Landlord Parties and any other party designated by Landlord (“Additional Insured Parties”) as additional insureds; and (b) be primary insurance as to all claims thereunder and provide that any insurance carried by Landlord is excess and non-contributing with Tenant’s insurance. Landlord shall be designated as a loss payee with respect to Tenant’s Property Insurance on any Tenant-Insured Improvements. Tenant shall deliver to Landlord, on or before the Commencement Date and at least 15 days before the expiration dates thereof, certificates from Tenant’s insurance company on the forms currently designated “XXXXX 25” (Certificate of Liability Insurance) and “XXXXX 28” (Evidence of Commercial Property Insurance) or the equivalent. Attached to the XXXXX 25 (or equivalent) there shall be an endorsement naming the Additional Insured Parties as additional insureds, and attached to the XXXXX 28 (or equivalent) there shall be an endorsement designating Landlord as a loss payee with respect to Tenant’s Property Insurance on any Tenant-insured Improvements, and each such endorsement shall be binding on Tenant’s insurance company. Upon Landlord’s request, Tenant shall deliver to Landlord, in lieu of such certificates, copies of the policies of insurance required to be carried under Section 10.2 showing that the Additional Insured Parties are named as additional insureds and that Landlord is designated as a loss payee with respect to Tenant’s Property Insurance on any Tenant-Insured Improvements.

10.4 Subrogation. Notwithstanding any contrary provision hereof (but subject to Section 11 hereof and Sections 4 and 8 of Exhibit D), each party waives, and shall cause its insurance carrier to waive, any right of recovery against the other party, any of its (direct or indirect) owners, or any of their respective beneficiaries, trustees, officers, directors, employees or agents for any loss of or damage to property which loss or damage is (or, if the insurance required hereunder had been carried, would have been) covered by property insurance, without regard to any negligence of the parties so released. For purposes of this Section 10.4 only, (a) any deductible with respect to a party’s insurance shall be deemed covered by, and recoverable by such party under, valid and collectable policies of insurance, and (b) any contractor retained by Landlord to install, maintain or monitor a fire or security alarm for the Building shall be deemed an agent of Landlord.

10.5 Additional Insurance Obligations. Tenant shall maintain such increased amounts of the insurance required to be carried by Tenant under this Section 10, and such other types and amounts of insurance covering the Premises and Tenant’s operations therein, as may be reasonably requested by Landlord, but not in excess of the amounts and types of insurance then being required by landlords of buildings comparable to and in the vicinity of the Building.

10.6 Landlord’s Insurance. Landlord shall maintain the following insurance, together with such other insurance coverage as Landlord, in its reasonable judgment, may elect to maintain, the premiums of which shall be included in Expenses: (a) Commercial General Liability insurance applicable to the Property, Building and Common Areas providing, on an occurrence basis, a minimum combined single limit of at least $3,000,000.00; (b) Special Cause of Loss Insurance on the Building at replacement cost value as reasonably estimated by Landlord; (c) Worker’s Compensation insurance to the extent required by Law; and (d) Employers Liability Coverage to the extent required by Law.

11. CASUALTY DAMAGE. With reasonable promptness after discovering any damage to the Premises (excluding trade fixtures), or to the Common Areas necessary for access to the Premises, resulting from any fire or other casualty (a “Casualty”), Landlord shall notify Tenant of Landlord’s reasonable estimate of the time required to substantially complete repair of such damage (the “Landlord Repairs”). If, according to such estimate, the Landlord Repairs cannot be substantially completed within 180 days after they are commenced, either party may terminate this Lease upon 60 days’ notice to the other party delivered within 10 days after Landlord’s delivery of such estimate. Within 90 days after discovering any damage to the Project resulting from any Casualty, Landlord may, whether or not the Premises is affected, terminate this Lease by notifying Tenant if (i) any Security Holder terminates any ground lease or requires that any insurance proceeds be used to pay any mortgage debt; (ii) any damage to Landlord’s property is not fully covered by Landlord’s insurance policies; (iii) Landlord decides to rebuild the Building or Common Areas so that it or they will be substantially different structurally or architecturally; (iv) the damage occurs during the last 12 months of the Term; or (v) any owner, other than Landlord, of any damaged portion of the Project does not intend to repair such damage provided, however, that (x) Landlord may not terminate this Lease pursuant to the preceding clauses (i), (ii), (iii) or (v) unless the Premises has been materially damaged or Landlord also exercises all rights it may have acquired as a result of the Casualty to terminate any other leases of space in the Building, and (y) Landlord may not terminate this Lease pursuant to the preceding clause (iv) unless the Premises has been materially damaged or Landlord also exercises all rights it may have acquired as a result of the Casualty to terminate any other leases that (1) relate to space in the Building, and (2) have less than 12 months left remaining in their terms when the Casualty occurs. If this Lease is not terminated pursuant to this Section 11, Landlord shall promptly and diligently perform the Landlord Repairs, subject to reasonable delays for insurance adjustment and other events of Force Majeure. The Landlord Repairs shall restore the Premises (excluding trade fixtures) and the Common Areas necessary for access to the Premises to substantially the same condition that existed when the Casualty occurred, except for (a) any modifications required by Law or any Security Holder, and (b) any modifications to the Common Areas that are deemed desirable by Landlord, are consistent with the character of the Project, and do not materially impair access to the Premises. Notwithstanding Section 10.4, Tenant shall assign to Landlord (or its designee) all insurance proceeds payable to Tenant under Tenant’s insurance required under Section 10.2 with respect to any Tenant-Insured Improvements, and if the estimated or actual cost of restoring any Tenant-Insured Improvements exceeds the insurance proceeds received by Landlord from Tenant’s insurance carrier, Tenant shall pay such excess to Landlord within 15 days after Landlord’s demand. No Casualty and no restoration performed as required hereunder shall render Landlord liable to Tenant, constitute a constructive eviction, or excuse Tenant from any obligation hereunder; provided, however, that if the Premises (other than trade fixtures) or any Common Area necessary for Tenant’s access to the Premises is damaged by a Casualty, then, during any time that, as a result of such damage, any portion of the Premises is untenantable or inaccessible and is not occupied by Tenant, Monthly Rent shall be abated in proportion to the rentable square footage of such portion of the Premises.

12. NONWAIVER. No provision hereof shall be deemed waived by either party unless it is waived by such party expressly and in writing, and no waiver of any breach of any provision hereof shall be deemed a waiver of any subsequent breach of such provision or any other provision hereof. Landlord’s

acceptance of Rent shall not be deemed a waiver of any preceding breach of any provision hereof, other than Tenant’s failure to pay the particular Rent so accepted, regardless of Landlord’s knowledge of such preceding breach at the time of such acceptance. No acceptance of payment of an amount less than the Rent due hereunder shall be deemed a waiver of Landlord’s right to receive the full amount of Rent due, whether or not any endorsement or statement accompanying such payment purports to effect an accord and satisfaction. No receipt of monies by Landlord from Tenant after the giving of any notice, the commencement of any suit, the issuance of any final judgment, or the termination hereof shall affect such notice, suit or judgment, or reinstate or extend the Term or Tenant’s right of possession hereunder.

13. CONDEMNATION. If any part of the Premises, Building or Project is taken for any public or quasi-public use by power of eminent domain or by private purchase in lieu thereof (a “Taking”) for more than 120 consecutive days, Landlord may terminate this Lease. If more than 15% of the rentable square footage of the Premises is Taken, or access to the Premises is substantially impaired as a result of a Taking, for more than 120 consecutive days, Tenant may terminate this Lease. Any such termination shall be effective as of the date possession must be surrendered to the authority, and the terminating party shall provide termination notice to the other party within 45 days after receiving written notice of such surrender date. Except as provided above in this Section 13, neither party may terminate this Lease as a result of a Taking. Tenant shall not assert any claim for compensation because of any Taking; provided, however, that Tenant may file a separate claim for any Taking of Tenant’s personal property or any fixtures that Tenant is entitled to remove upon the expiration hereof, and for moving expenses, so long as such claim does not diminish the award available to Landlord or any Security Holder and is payable separately to Tenant. If this Lease is terminated pursuant to this Section 13, all Rent shall be apportioned as of the date of such termination. If a Taking occurs and this Lease is not so terminated, Monthly Rent shall be abated for the period of such Taking in proportion to the percentage of the rentable square footage of the Premises, if any, that is subject to, or rendered inaccessible by, such Taking.

14. ASSIGNMENT AND SUBLETTING.

14.1 Transfers. Tenant shall not, without Landlord’s prior consent, assign, mortgage, pledge, hypothecate, encumber, permit any lien to attach to, or otherwise transfer this Lease or any interest hereunder, permit any assignment or other transfer hereof or any interest hereunder by operation of law, enter into any sublease or license agreement, otherwise permit the occupancy or use of any part of the Premises by any persons other than Tenant and its employees and contractors, or permit a Change of Control (defined in Section 14.6) to occur (each, a “Transfer”). If Tenant desires Landlord’s consent to any Transfer, Tenant shall provide Landlord with (i) notice o f the terms of the proposed Transfer, including its proposed effective date (the “Contemplated Effective Date”), a description of the portion of the Premises to be transferred (the “Contemplated Transfer Space”), a calculation of the Transfer Premium (defined in Section 14.3), and a copy of all existing executed and/or proposed documentation pertaining to the proposed Transfer, and (ii) current financial statements of the proposed transferee (or, in the case of a Change of Control, of the proposed new controlling party(ies)) certified by an officer or owner thereof and any other information reasonably required by Landlord in order to evaluate the proposed Transfer (collectively, the “Transfer Notice”). Within 15 business days after receiving the Transfer Notice, Landlord shall notify Tenant of (a) its consent to the proposed Transfer, (b) its refusal to consent to the proposed Transfer, or (c) its exercise of its rights under Section 14.4. Any Transfer made without Landlord’s prior consent shall, at Landlord’s option, be void and shall, at Landlord’s option, constitute a Default (defined in Section 19). Tenant shall pay Landlord a fee of $1,500.00 for Landlord’s review of any proposed Transfer, whether or not Landlord consents to it.

14.2 Landlord’s Consent. Subject to Section 14.4, Landlord shall not unreasonably withhold its consent to any proposed Transfer. Without limiting other reasonable grounds for withholding consent, it shall be deemed reasonable for Landlord to withhold consent to a proposed Transfer if:

14.2.1 The proposed transferee is not a party of reasonable financial strength in light of the responsibilities to be undertaken in connection with the Transfer on the date the Transfer Notice is received; or

14.2.2 The proposed transferee has a character or reputation or is engaged in a business that is not consistent with the quality of the Building or the Project; or

14.2.3 The proposed transferee is a governmental entity or a nonprofit organization; or

14.2.4 [Intentionally Omitted]; or

14.2.5 The proposed transferee or any of its Affiliates, on the date the Transfer Notice is received, leases or occupies (or, at any time during the 2-month period ending on the date the Transfer Notice is received, has negotiated with Landlord to lease) space in the Project.

Notwithstanding any contrary provision hereof, (a) if Landlord consents to any Transfer pursuant to this Section 14.2 but Tenant does not enter into such Transfer within six (6) months thereafter, such consent shall no longer apply and such Transfer shall not be permitted unless Tenant again obtains Landlord’s consent thereto pursuant and subject to the terms of this Section 14; and (b) if Landlord unreasonably withholds its consent under this Section 14.2, Tenant’s sole remedies shall be contract damages (subject to Section 20) or specific performance, and Tenant waives all other remedies, including any right to terminate this Lease.

14.3 Transfer Premium. If Landlord consents to a Transfer (other than a Permitted Transfer), Tenant shall pay Landlord an amount equal to 50% of any Transfer Premium (defined below). As used herein, “Transfer Premium” means (a) in the case of an assignment, any consideration (including payment for Leasehold Improvements) paid by the assignee for such assignment, less any reasonable and customary expenses directly incurred by Tenant on account of such assignment, including brokerage fees, legal fees, and Landlord’s review fee; and (b) in the case of a sublease, license or other occupancy agreement, for each month of the term of such agreement, the amount by which all rent and other consideration paid by the transferee to Tenant pursuant to such agreement (less all reasonable and customary expenses directly incurred by Tenant on account of such agreement, including brokerage fees, legal fees, construction costs and Landlord’s review fee, as amortized on a monthly, straight-line basis over the term of such agreement) exceeds the Monthly Rent payable by Tenant hereunder with respect to the Contemplated Transfer Space. Payment of Landlord’s share of the Transfer Premium shall be made (x) in the case of an assignment, within 10 days after Tenant receives the consideration described above, and (y) in the case of a sublease, license or other occupancy agreement, for each month of the term of such agreement, within five (5) business days after Tenant receives the rent and other consideration described above. Notwithstanding any contrary provision of this Section 14.3, Tenant shall not be required to pay Landlord any portion of any Transfer Premium arising from any Change of Control that occurs for a good faith operating business purpose and not in order to evade the requirements of this Section 14.3.

14.4 Landlord’s Right to Recapture. Notwithstanding any contrary provision hereof, except in the case of a Permitted Transfer (defined in Section 14.8) or a Change of Control, Landlord, by notifying Tenant within 15 business days after receiving the Transfer Notice, may terminate this Lease

with respect to the Contemplated Transfer Space as of the Contemplated Effective Date. If the Contemplated Transfer Space is less than the entire Premises, then Base Rent, Tenant’s Share, and the number of parking spaces to which Tenant is entitled under Section 1.9 shall be deemed adjusted on the basis of the percentage of the rentable square footage of the Premises retained by Tenant. Upon request of either party, the parties shall execute a written agreement prepared by Landlord memorializing such termination.

14.5 Effect of Consent. If Landlord consents to a Transfer, (i) such consent shall not be deemed a consent to any further Transfer, (ii) Tenant shall deliver to Landlord, promptly after execution, an executed copy of all documentation pertaining to the Transfer in form reasonably acceptable to Landlord, and (iii) Tenant shall deliver to Landlord, upon Landlord’s request, a complete statement, certified by an independent CPA or Tenant’s chief financial officer, setting forth in detail the computation of any Transfer Premium. In the case of an assignment, the assignee shall assume in writing, for Landlord’s benefit, all of Tenant’s obligations hereunder. No Transfer, with or without Landlord’s consent, shall relieve Tenant or any guarantor hereof from any liability hereunder. Notwithstanding any contrary provision hereof, Tenant, with or without Landlord’s consent, shall not enter into, or permit any party claiming by, through or under Tenant to enter into, any sublease, license or other occupancy agreement that provides for payment based in whole or in part on the net income or profit of the subtenant, licensee or other occupant thereunder.

14.6 Change of Control. As used herein, “Change of Control” means (a) if Tenant is a closely held professional service firm, the withdrawal or change (whether voluntary, involuntary or by operation of law) of 50% or more of its equity owners within a 12-month period; and (b) in all other cases, any transaction(s) resulting in the acquisition of a Controlling Interest (defined below) by one or more parties that did not own a Controlling Interest immediately before such transaction(s). As used herein, “Controlling Interest” means any direct or indirect equity or beneficial ownership interest in Tenant that confers upon its holder(s) the direct or indirect power to direct the ordinary management and policies of Tenant, whether through the ownership of voting securities, by contract or otherwise (but not through the ownership of voting securities listed on a recognized securities exchange). (Landlord acknowledges that, by operation of the definitions of “Transfer,” “Change of Control” and “Controlling Interest,” no stock of Tenant listed on a recognized securities exchange shall be deemed a Controlling Interest, and, therefore, no issuance of Tenant’s stock in an offering or sale on a recognized securities exchange shall be deemed a Change of Control or a Transfer.)

14.7 Effect of Default. If Tenant is in Default, Landlord is irrevocably authorized, as Tenant’s agent and attorney-in-fact, to direct any transferee under any sublease, license or other occupancy agreement to make all payments under such agreement directly to Landlord (which Landlord shall apply towards Tenant’s obligations hereunder) until such Default is cured. Such transferee shall rely upon any representation by Landlord that Tenant is in Default, whether or not confirmed by Tenant.

14.8 Permitted Transfers. Notwithstanding any contrary provision hereof, if Tenant is not in Default, Tenant may, without Landlord’s consent pursuant to Section 14.1, permit a Change of Control to occur or assign this Lease to (a) an Affiliate of Tenant (other than pursuant to a merger or consolidation), (b) a successor to Tenant by merger or consolidation, or (c) a successor to Tenant by purchase of all or substantially all of Tenant’s assets (a “Permitted Transfer”), provided that (i) at least 10 business days before the Transfer, Tenant notifies Landlord of such Transfer and delivers to Landlord any documents or information reasonably requested by Landlord relating thereto, including reasonable documentation that the Transfer satisfies the requirements of this Section 14.8; (ii) in the case of an assignment pursuant to clause (a) or (c) above, the assignee executes and delivers to Landlord, at least 10 business days before the assignment, a commercially reasonable instrument pursuant to which the assignee assumes, for

Landlord’s benefit, all of Tenant’s obligations hereunder; (iii) in the case of an assignment pursuant to clause (b) above, (A) the successor entity has a net worth (as determined in accordance with GAAP, but excluding intellectual property and any other intangible assets (“Net Worth”)) immediately after the Transfer that is not less than the Net Worth of Tenant immediately before the Transfer, and (B) if Tenant is a closely held professional service firm, at least 50% of its equity owners existing 12 months before the Transfer are also equity owners of the successor entity; (iv) except in the case of a Change of Control, the transferee is qualified to conduct business in the State of California; (v) in the case of a Change of Control, (A) Tenant is not a closely held professional service firm, and (B) Tenant’s Net Worth immediately after the Change of Control is not less than its Net Worth immediately before the Change of Control; and (vi) the Transfer is made for a good faith operating business purpose and not in order to evade the requirements of this Section 14. As used herein, “Affiliate” means, with respect to any party, a person or entity that controls, is under common control with, or is controlled by such party.

15. SURRENDER. Upon the expiration or earlier termination hereof, and subject to Sections 8 and 11 and this Section 15, Tenant shall surrender possession of the Premises to Landlord in as good condition and repair as when Tenant took possession and as thereafter improved by Landlord and/or Tenant, except for reasonable wear and tear and repairs that are Landlord’s express responsibility hereunder. Before such expiration or termination, Tenant, without expense to Landlord, shall (a) remove from the Premises all debris and rubbish and all furniture, equipment, trade fixtures, Lines, free-standing cabinet work, movable partitions and other articles of personal property that are owned or placed in the Premises by Tenant or any party claiming by, through or under Tenant (except for any Lines not required to be removed under Section 23), and (b) repair all damage to the Premises and Building resulting from such removal. If Tenant fails to timely perform such removal and repair, Landlord may do so at Tenant’s expense (including storage costs). If Tenant fails to remove such property from the Premises, or from storage, within 30 days after notice from Landlord, any part of such property shall be deemed, at Landlord’s option, either (x) conveyed to Landlord without compensation, or (y) abandoned.

16. HOLDOVER. If Tenant fails to surrender the Premises upon the expiration or earlier termination hereof, Tenant’s tenancy shall be subject to the terms and conditions hereof; provided, however, that such tenancy shall be a tenancy at sufferance only, for the entire Premises, and Tenant shall pay Monthly Rent (on a per-month basis without reduction for any partial month) at a rate equal to 150% of the Monthly Rent applicable during the last calendar month of the Term. Nothing in this Section 16 shall limit Landlord’s rights or remedies or be deemed a consent to any holdover. If Landlord is unable to deliver possession of the Premises to a new tenant or to perform improvements for a new tenant as a result of Tenant’s holdover, Tenant shall be liable for all resulting damages, including lost profits, incurred by Landlord.

17. SUBORDINATION; ESTOPPEL CERTIFICATES. This Lease shall be subject and subordinate to all existing and future ground or underlying leases, mortgages, trust deeds and other encumbrances against the Building or Project, all renewals, extensions, modifications, consolidations and replacements thereof (each, a “Security Agreement”), and all advances made upon the security of such mortgages or trust deeds, unless in each case the holder of such Security Agreement (each, a “Security Holder”) requires in writing that this Lease be superior thereto. Upon any termination or foreclosure (or any delivery of a deed in lieu of foreclosure) of any Security Agreement, Tenant, upon request, shall attorn, without deduction or set-off, to the Security Holder or purchaser or any successor thereto and shall recognize such party as the lessor hereunder provided that such party agrees not to disturb Tenant’s occupancy so long as Tenant timely pays the Rent and otherwise performs its obligations hereunder. Within 10 days after request by Landlord, Tenant shall execute such further instruments as Landlord may reasonably deem necessary to evidence the subordination or superiority of this Lease to any Security Agreement. Tenant waives any right it may have under Law to terminate or otherwise adversely affect

this Lease or Tenant’s obligations hereunder upon a foreclosure. Within 10 business days after Landlord’s request, Tenant shall execute and deliver to Landlord a commercially reasonable estoppel certificate in favor of such parties as Landlord may reasonably designate, including current and prospective Security Holders and prospective purchasers.

18. ENTRY BY LANDLORD. At all reasonable times and upon reasonable notice to Tenant, or in an emergency, Landlord may enter the Premises to (i) inspect the Premises; (ii) show the Premises to prospective purchasers, current or prospective Security Holders or insurers, or, during the last 12 months of the Term (or while an uncured Default exists), prospective tenants; (iii) post notices of non-responsibility; or (iv) perform maintenance, repairs or alterations. At any time and without notice to Tenant, Landlord may enter the Premises to perform required services. If reasonably necessary, Landlord may temporarily close any portion of the Premises to perform maintenance, repairs or alterations. In an emergency, Landlord may use any means it deems proper to open doors to and in the Premises. Except in an emergency, Landlord shall use reasonable efforts to minimize interference with Tenant’s use of the Premises. No entry into or closure of any portion of the Premises pursuant to this Section 18 shall render Landlord liable to Tenant, constitute a constructive eviction, or excuse Tenant from any obligation hereunder.

19. DEFAULTS; REMEDIES.

19.1 Events of Default. The occurrence of any of the following shall constitute a “Default”:

19.1.1 Any failure by Tenant to pay any Rent when due unless such failure is cured within five (5) business days after notice from Landlord of such failure; or

19.1.2 Except where a specific time period is otherwise set forth for Tenant’s cure herein (in which event Tenant’s failure to cure within such time period shall be a Default), and except as otherwise provided in this Section 19.1, any breach by Tenant of any other provision hereof where such breach continues for 30 days after notice from Landlord; provided that if such breach cannot reasonably be cured within such 30-day period, Tenant shall not be in Default as a result of such breach if Tenant diligently commences such cure within such period, thereafter diligently pursues such cure, and completes such cure within 60 days after Landlord’s notice; or

19.1.3 Abandonment of the Premises by Tenant; or

19.1.4 Any breach by Tenant of Sections 5, 14, 17 or 18 where such breach continues for more than two (2) business days after notice from Landlord; or

19.1.5 Tenant becomes in breach of Section 25.3.

If Tenant breaches a particular provision hereof (other than a provision requiring payment of Rent), and Landlord notifies Tenant of such breach, on three (3) separate occasions during any 12-month period, and if such breaches are collectively material, then Tenant’s subsequent breach of such provision shall be, at Landlord’s option, an incurable Default. The notice periods provided herein are in lieu of, and not in addition to, any notice periods provided by Law, and Landlord shall not be required to give any additional notice in order to be entitled to commence an unlawful detainer proceeding.

19.2 Remedies Upon Default. Upon any Default, Landlord shall have, in addition to any other remedies available to Landlord at law or in equity (which shall be cumulative and nonexclusive), the option to pursue any one or more of the following remedies (which shall be cumulative and nonexclusive) without any notice or demand:

19.2.1 Landlord may terminate this Lease, in which event Tenant shall immediately surrender the Premises to Landlord, and if Tenant fails to do so, Landlord may, without prejudice to any other remedy it may have for possession or arrearages in Rent, enter upon and take possession of the Premises and expel or remove Tenant and any other person who may be occupying the Premises or any part thereof, without being liable for prosecution or any claim or damages therefor; and Landlord may recover from Tenant the following:

(a) The worth at the time of award of the unpaid Rent which has been earned at the time of such termination; plus

(b) The worth at the time of award of the amount by which the unpaid Rent which would have been earned after termination until the time of award exceeds the amount of such rental loss that Tenant proves could have been reasonably avoided; plus

(c) The worth at the time of award of the amount by which the unpaid Rent for the balance of the Term after the time of award exceeds the amount of such Rent loss that Tenant proves could have been reasonably avoided; plus

(d) Any other amount necessary to compensate Landlord for all the detriment proximately caused by Tenant’s failure to perform its obligations hereunder or which in the ordinary course of things would be likely to result therefrom, including (but only to the extent reasonably attributable to the remaining Term) brokerage commissions, advertising expenses, expenses of remodeling any portion of the Premises for a new tenant (whether for the same or a different use), and any special concessions made to obtain a new tenant; plus

(e) At Landlord’s option, such other amounts in addition to or in lieu of the foregoing as may be permuted from time to time by Law.

As used in Sections 19.2.1(a) and (b), the “worth at the time of award” shall be computed by allowing interest at a rate per annum equal to the lesser of (i) the annual “Bank Prime Loan” rate cited in the Federal Reserve Statistical Release Publication G.13(415), published on the first Tuesday of each calendar month (or such other comparable index as Landlord shall reasonably designate if such rate ceases to be published) plus two (2) percentage points, or (ii) the highest rate permitted by Law. As used in Section 19.2.1(c), the “worth at the time of award” shall be computed by discounting such amount at the discount rate of the Federal Reserve Bank of San Francisco at the time of award plus 1%.

19.2.2 Landlord shall have the remedy described in California Civil Code § 1951.4 (lessor may continue lease in effect after lessee’s breach and abandonment and recover Rent as it becomes due, if lessee has the right to sublet or assign, subject only to reasonable limitations). Accordingly, if Landlord does not elect to terminate this Lease on account of any default by Tenant, Landlord may, from time to time, without terminating this Lease, enforce all of its rights and remedies hereunder, including the right to recover all Rent as it becomes due.

19.2.3 Landlord shall at all times have the rights and remedies (which shall be cumulative with each other and cumulative and in addition to those rights and remedies available under Sections 19.2.1 and 19.2.2, or any Law or other provision hereof), without prior demand or notice except as required by Law, to seek any declaratory, injunctive or other equitable relief, and specifically enforce this Lease, or restrain or enjoin a violation or breach of any provision hereof.

19.3 Efforts to Relet. Unless Landlord provides Tenant with express notice to the contrary, no re-entry, repossession, repair, maintenance, change, alteration, addition, reletting, appointment of a receiver or other action or omission by Landlord shall (a) be construed as an election by Landlord to terminate this Lease or Tenant’s right to possession, or to accept a surrender of the Premises, or (b) operate to release Tenant from any of its obligations hereunder. Tenant waives, for Tenant and for all those claiming by, through or under Tenant, California Civil Code § 3275 and California Code of Civil Procedure §§ 1174(c) and 1179 and any existing or future rights to redeem or reinstate, by order or judgment of any court or by any legal process or writ, this Lease or Tenant’s right of occupancy of the Premises after any termination hereof.

19.4 Landlord Default. Landlord shall not be in default hereunder unless it fails to begin within 30 days after notice from Tenant, or fails to pursue with reasonable diligence thereafter, the cure of any breach by Landlord of its obligations hereunder. Before exercising any remedies for a default by Landlord, Tenant shall give notice and a reasonable time to cure to any Security Holder of which Tenant has been notified.

20. LANDLORD EXCULPATION. Notwithstanding any contrary provision hereof, (a) the liability of the Landlord Parties to Tenant shall be limited to an amount equal to the lesser of (i) the value of Landlord’s interest in the Building, or (ii) the value of the equity interest Landlord would have in the Building if the Building were encumbered by third-party debt in an amount equal to 80% of the value of the Building (as such value is determined by Landlord); (b) Tenant shall look solely to Landlord’s interest in the Building for the recovery of any judgment or award against any Landlord Party; (c) no Landlord Party shall have any personal liability for any judgment or deficiency, and Tenant waives and releases such personal liability on behalf of itself and all parties claiming by, through or under Tenant; and (d) no Landlord Party shall be liable for any injury or damage to, or interference with, Tenant’s business, including loss of profits, loss of rents or other revenues, loss of business opportunity, loss of goodwill or loss of use, or for any form of special or consequential damage. For purposes of this Section 20, “Landlord’s interest in the Building” shall include rents paid by tenants, insurance proceeds, condemnation proceeds, and proceeds from the sale of the Building (collectively, “Owner Proceeds”); provided, however, that Tenant shall not be entitled to recover Owner Proceeds from any Landlord Party (other than Landlord) or any other third party after they have been distributed or paid to such party; provided further, however, that nothing in this sentence shall diminish any right Tenant may have under Law, as a creditor of Landlord, to initiate or participate in an action to recover Owner Proceeds from a third party on the grounds that such third party obtained such Owner Proceeds when Landlord was, or could reasonably be expected to become, insolvent or in a transfer that was preferential or fraudulent as to Landlord’s creditors.

21. SECURITY DEPOSIT. Concurrently with its execution and delivery hereof, Tenant shall deposit with Landlord the Security Deposit, if any, as security for Tenant’s performance of its obligations hereunder. If Tenant breaches any provision hereof, Landlord may, at its option, without notice to Tenant, apply all or part of the Security Deposit to pay any past-due Rent, cure any breach by Tenant, or compensate Landlord for any other loss or damage caused by such breach. If Landlord so applies any portion of the Security Deposit, Tenant, within three (3) days after demand therefor, shall restore the Security Deposit to its original amount. The Security Deposit is not an advance payment of Rent or measure of damages. Any unapplied portion of the Security Deposit shall be returned to Tenant within 45 days after the latest to occur of (a) the expiration of the Term, (b) Tenant’s surrender of the Premises as required hereunder, or (c) Landlord’s cure of any existing breach by Tenant of any provision hereof;

provided, however, that if Landlord estimates in good faith that Tenant may be required to make a payment to Landlord under Section 4.4.1, Landlord may retain such unapplied portion of the Security Deposit, to the extent of the estimated amount of such payment, until the date occurring 45 days after determination of the final Rent due from Tenant. Landlord shall not be required to keep the Security Deposit separate from its other accounts.

22. [Intentionally Omitted.].

23. COMMUNICATIONS AND COMPUTER LINES. All Lines installed pursuant to this Lease shall be (a) installed in accordance with Section 7; and (b) clearly marked with adhesive plastic labels (or plastic tags attached to such Lines with wire) to show Tenant’s name, suite number, and the purpose of such Lines (i) every six (6) fee t outside the Premises (including the electrical room risers and any Common Areas), and (ii) at their termination points. Landlord may designate specific contractors for work relating to vertical Lines. Sufficient spare cables and space for additional cables shall be maintained for other occupants, as reasonably determined by Landlord. Unless otherwise notified by Landlord, Tenant, at its expense and before the expiration or earlier termination hereof, shall remove all Lines and repair any resulting damage. As used herein, “Lines” means all communications or computer wires and cables serving the Premises, whenever and by whomever installed or paid for, including any such wires or cables installed pursuant to any prior lease.

24. PARKING. Tenant may park in the Building’s parking facilities (the “Parking Facility”), in common with other tenants of the Building, upon the following terms and conditions. Tenant shall not use more than the number of unreserved and/or reserved parking spaces set forth in Section 1.9. Tenant shall pay Landlord, in accordance with Section 3, any fees for the parking spaces described in Section 1.9. Tenant shall pay Landlord any fees, taxes or other charges imposed by any governmental or quasi-governmental agency in connection with the Parking Facility, to the extent such amounts are allocated to Tenant by Landlord. Landlord shall not be liable to Tenant, nor shall this Lease be affected, if any parking is impaired by (or any parking charges are imposed as a result of) any Law. Tenant shall comply with all rules and regulations established by Landlord from time to time for the orderly operation and use of the Parking Facility, including any sticker or other identification system and the prohibition of vehicle repair and maintenance activities in the Parking Facility. Landlord may, in its discretion, allocate and assign parking passes among Tenant and the other tenants in the Building. Tenant’s use of the Parking Facility shall be at Tenant’s sole risk, and Landlord shall have no liability for any personal injury or damage to or theft of any vehicles or other property occurring in the Parking Facility or otherwise in connection with any use of the Parking Facility by Tenant, its employees or invitees. Landlord may alter the size, configuration, design, layout or any other aspect of the Parking Facility, and, in connection therewith, temporarily deny or restrict access to the Parking Facility, in each case without abatement of Rent or liability to Tenant. Landlord may delegate its responsibilities hereunder to a parking operator, in which case (i) such parking operator shall have all the rights of control reserved herein by Landlord, (ii) Tenant shall enter into a parking agreement with such parking operator, (iii) Tenant shall pay such parking operator, rather than Landlord, any charge established hereunder for the parking spaces, and (iv) Landlord shall have no liability for claims arising through acts or omissions of such parking operator except to the extent caused by Landlord’s negligence or willful misconduct. Tenant’s parking rights under this Section 24 are solely for the benefit of Tenant’s employees and invitees and such rights may not be transferred without Landlord’s prior consent, except pursuant to a Transfer permitted under Section 14.

25. MISCELLANEOUS.

25.1 Notices. No notice, demand, statement, designation, request, consent, approval, election or other communication given hereunder (“Notice”) shall be binding upon either party unless (a) it is in writing; (b) it is (i) sent by certified or registered mail, postage prepaid, return receipt requested, (ii) delivered by a nationally recognized courier service, or (iii) delivered personally; and (c) it is sent or delivered to the address set forth in Section 1.10 or 1.11, as applicable, or to such other place (other than a P.O. box) as the recipient may from time to time designate in a Notice to the other party. Any Notice shall be deemed received on the earlier of the date of actual delivery or the date on which delivery is refused, or, if Tenant is the recipient and has vacated its notice address without providing a new notice address, three (3) days after the date the Notice is deposited in the U.S. mail or with a courier service as described above.

25.2 Force Majeure. If either party is prevented from performing any obligation hereunder by any strike, act of God, war, terrorist act, shortage of labor or materials, governmental action, civil commotion or other cause beyond such party’s reasonable control (“Force Majeure”), such obligation shall be excused during (and any time period for the performance of such obligation shall be extended by) the period of such prevention; provided, however, that this Section 25.2 shall not (a) permit Tenant to hold over in the Premises after the expiration or earlier termination hereof, or (b) excuse any of Tenant’s obligations under Sections 3, 4, 5, 21 or 25.3 or any of Tenant’s obligations whose nonperformance would interfere with another occupant’s use, occupancy or enjoyment of its premises or the Project.

25.3 Representations and Covenants. Tenant represents, warrants and covenants that (a) Tenant is, and at all times during the Term will remain, duly organized, validly existing and in good standing under the Laws of the state of its formation and qualified to do business in the state of California; (b) neither Tenant’s execution of nor its performance under this Lease will cause Tenant to be in violation of any agreement or Law; (c) Tenant (and any guarantor hereof) has not, and at no time during the Term will have, (i) made a general assignment for the benefit of creditors, (ii) filed a voluntary petition in bankruptcy, (iii) suffered the filing by creditors of an involuntary petition in bankruptcy which is not dismissed within 30 days, (iv) suffered the appointment of a receiver to take possession of all or substantially all of its assets, (v) suffered the attachment or other judicial seizure of all or substantially all of its assets, (vi) admitted in writing its inability to pay its debts as they come due, or (vii) made an offer of settlement, extension or composition to its creditors generally; and (d) each party that (other than through the passive ownership of interests traded on a recognized securities exchange) constitutes, owns, controls, or is owned or controlled by Tenant, any guarantor hereof or any subtenant of Tenant is not, and at no time during the Term will be, (i) in violation of any Laws relating to terrorism or money laundering, or (ii) among the parties identified on any list compiled pursuant to Executive Order 13224 for the purpose of identifying suspected terrorists or on the most current list published by the U.S. Treasury Department Office of Foreign Assets Control at its official website, xxxx://xxx.xxxxx.xxx/xxxx/xxxxxx.xxx or any replacement website or other replacement official publication of such list.

25.4 Signs. Landlord shall include Tenant’s name in any tenant directory located in the lobby on the first floor of the Building. If any part of the Premises is located on a multi-tenant floor, Landlord, at Tenant’s cost, shall provide identifying suite signage for Tenant comparable to that provided by Landlord on similar floors in the Building. Tenant may not install (a) any signs outside the Premises, or (b) without Landlord’s prior consent in its sole and absolute discretion, any signs, window coverings, blinds or similar items that are visible from outside the Premises.

25.5 Supplemental HVAC. if any supplemental HVAC unit (a “Unit”) serves the Premises, then (a) Tenant shall pay the costs of all electricity consumed in the Unit’s operation, together with the

cost of installing a meter to measure such consumption; (b) Tenant, at its expense, shall (i) operate and maintain the Unit in compliance with all applicable Laws and such reasonable rules and procedures as Landlord may impose; (ii) keep the Unit in as good working order and condition as exists upon its installation (or, if later, on the date Tenant takes possession of the Premises), subject to normal wear and tear and damage resulting from Casualty; (iii) maintain in effect, with a contractor reasonably approved by Landlord, a contract for the maintenance and repair of the Unit, which contract shall require the contractor, at least once every three (3) months, to inspect the Unit and provide to Tenant a report of any defective conditions, together with any recommendations for maintenance, repair or parts-replacement; (iv) follow all reasonable recommendation of such contractor; and (v) promptly provide to Landlord a copy of such contract and each report issued thereunder; (c) the Unit shall become Landlord’s property upon installation and without compensation to Tenant; provided, however, that upon Landlord’s request at the expiration or earlier termination hereof, Tenant, at its expense, shall remove any Unit installed by Tenant and repair any resulting damage; (d) the Unit shall be deemed (i) a Leasehold Improvement (except for purposes of Section 8), and (ii) for purposes of Section 11, part of the Premises; (e) if the Unit exists on the date of mutual execution and delivery hereof, Tenant accepts the Unit in its “as is” condition, without representation or warranty as to quality, condition, fitness for use or any other matter; (f) if the Unit connects to the Building’s condenser water loop (if any), then Tenant shall pay to Landlord, as Additional Rent, Landlord’s standard one-time fee for such connection and Landlord’s standard monthly per-ton usage fee; and (g) if any portion of the Unit is located on the roof, then (i) Tenant’s access to the roof shall be subject to such reasonable rules and procedures as Landlord may impose; (ii) Tenant shall maintain the affected portion of the roof in a clean and orderly condition and shall not interfere with use of the roof by Landlord or any other tenants or licensees; and (iii) Landlord may relocate the Unit and/or temporarily interrupt its operation, without liability to Tenant, as reasonably necessary to maintain and repair the roof or otherwise operate the Building.

25.6 Attorneys’ Fees. In any action or proceeding between the parties, including any appellate or alternative dispute resolution proceeding, the prevailing party may recover from the other party all of its costs and expenses in connection therewith, including reasonable attorneys’ fees and costs. Tenant shall pay all reasonable attorneys’ fees and other fees and costs that Landlord incurs in interpreting or enforcing this Lease or otherwise protecting its rights hereunder (a) where Tenant has failed to pay Rent when due, or (b) in any bankruptcy case, assignment for the benefit of creditors, or other insolvency, liquidation or reorganization proceeding involving Tenant or this Lease.

25.7 Brokers. Tenant represents to Landlord that it has dealt only with Tenant’s Broker as its broker in connection with this Lease. Tenant shall indemnify, defend, and hold Landlord harmless from all claims of any brokers, other than Tenant’s Broker, claiming to have represented Tenant in connection with this Lease. Landlord shall indemnify, defend and hold Tenant harmless from all claims of any brokers, including Landlord’s Broker, claiming to have represented Landlord in connection with this Lease. Tenant acknowledges that any Affiliate of Landlord that is involved in the negotiation of this Lease is representing only Landlord, and that any assistance rendered by any agent or employee of such Affiliate in connection with this Lease or any subsequent amendment or other document related hereto has been or will be rendered as an accommodation to Tenant solely in furtherance of consummating the transaction on behalf of Landlord, and not as agent for Tenant.

25.8 Governing Law; WAIVER OF TRIAL BY JURY. This Lease shall be construed and enforced in accordance with the Laws of the State of California. THE PARTIES WAIVE, TO THE FULLEST EXTENT PERMITTED BY LAW, THE RIGHT TO TRIAL BY JURY IN ANY LITIGATION ARISING OUT OF OR RELATING TO THIS LEASE, THE RELATIONSHIP OF LANDLORD AND TENANT, TENANT’S USE OR OCCUPANCY OF THE PREMISES, AND/OR ANY CLAIM FOR INJURY OR DAMAGE OR ANY EMERGENCY OR STATUTORY REMEDY.

25.9 Waiver of Statutory Provisions. Each party waives California Civil Code §§ 1932(2) and 1933(4). Tenant waives (a) any rights under (i) California Civil Code §§ 1932(1), 1941, 1942, 1950.7 or any similar Law, or (ii) California Code of Civil Procedure § 1265.130; and (b) any right to terminate this Lease under California Civil Code § 1995.310.

25.10 Interpretation. As used herein, the capitalized term “Section” refers to a section hereof unless otherwise specifically provided herein. As used in this Lease, the terms “herein,” “hereof,” “hereto” and “hereunder” refer to this Lease and the term “include” and its derivatives are not limiting. Any reference herein to “any part” or “any portion” of the Premises, the Property or any other property shall be construed to refer to all or any part of such property. Wherever this Lease requires Tenant to comply with any Law, rule, regulation, procedure or other requirement or prohibits Tenant from engaging in any particular conduct, this Lease shall be deemed also to require Tenant to cause each of its employees, licensees, invitees and subtenants, and any other party claiming by, through or under Tenant, to comply with such requirement or refrain from engaging in such conduct, as the case may be. Wherever this Lease requires Landlord to provide a customary service or to act in a reasonable manner (whether in incurring an expense, establishing a rule or regulation, providing an approval or consent, or performing any other act), this Lease shall be deemed also to provide that whether such service is customary or such conduct is reasonable shall be determined by reference to the practices of owners of buildings that (i) are comparable to the Building in size, age, class, quality and location, and (ii) at Landlord’s option, have been, or are being prepared to be, certified under the U.S. Green Building Council’s Leadership in Energy and Environmental Design (LEED) rating system or a similar rating system. Tenant waives the benefit of any rule that a written agreement shall be construed against the drafting party.

25.11 Entire Agreement. This Lease sets forth the entire agreement between the parties relating to the subject matter hereof and supersedes any previous agreements (none of which shall be used to interpret this Lease). Tenant acknowledges that in entering into this Lease it has not relied upon any representation, warranty or statement, whether oral or written, not expressly set forth herein. This Lease can be modified only by a written agreement signed by both parties.

25.12 Other. Landlord, at its option, may cure any Default, without waiving any right or remedy or releasing Tenant from any obligation, in which event Tenant shall pay Landlord, upon demand, the cost of such cure. If any provision hereof is void or unenforceable, no other provision shall be affected. Submission of this instrument for examination or signature by Tenant does not constitute an option or offer to lease, and this instrument is not binding until it has been executed and delivered by both parties. If Tenant is comprised of two or more parties, their obligations shall be joint and several. Time is of the essence with respect to the performance of every provision hereof in which time of performance is a factor. So long as Tenant performs its obligations hereunder, Tenant shall have peaceful and quiet possession of the Premises against any party claiming by, through or under Landlord, subject to the terms hereof. Landlord may transfer its interest herein, in which event Landlord shall be released from, Tenant shall look solely to the transferee for the performance of, and the transferee shall be deemed to have assumed, all of Landlord’s obligations arising hereunder after the date of such transfer (including the return of any Security Deposit) and Tenant shall attorn to the transferee. Landlord reserves all rights not expressly granted to Tenant hereunder, including the right to make alterations to the Project. No rights to any view or to light or air over any property are granted to Tenant hereunder. The expiration or termination hereof shall not relieve either party of any obligation that accrued before, or continues to accrue after, such expiration or termination.

[SIGNATURES ARE ON THE FOLLOWING PAGE]

IN WITNESS WHEREOF, Landlord and Tenant have caused this Lease to be executed the day and date first above written.


LANDLORD:

CA-225 SANTA XXXXX STREET LIMITED PARTNERSHIP, a Delaware limited partnership

By:	EOP Owner GP L.L.C.,
	a Delaware limited liability company,
	its general partner

	By:	/s/ Xxxx X. Xxxxxxx
	Name:	Xxxx X. Xxxxxxx
	Title:	Senior Vice President-Leasing

TENANT:

XACTLY CORPORATION, a Delaware corporation

By:	/s/ Xxxxx Xxxxxxxxxx
Name:	Xxxxx Xxxxxxxxxx
Title:	CFO

EXHIBIT B

000 XXXX XXXXX XXXXX

WORK LETTER

As used in this Exhibit B (this “Work Letter”), the following terms shall have the following meanings: “Agreement” means the lease of which this Work Letter is a part. “Tenant Improvements” means all improvements to be constructed in the Premises pursuant to this Work Letter. “Tenant Improvement Work” means the construction of the Tenant Improvements, together with any related work (including demolition) that is necessary to construct the Tenant Improvements.

1 ALLOWANCE.

1.1 Allowance. Tenant shall be entitled to a one-time tenant improvement allowance (the “Allowance”) in the amount of $15.12 per rentable square foot of the Premises to be applied toward the Allowance Items (defined in Section 1.2 below). Tenant shall be responsible for all costs associated with the Tenant Improvement Work, including the costs of the Allowance Items, to the extent such costs exceed the lesser of (a) the Allowance, or (b) the aggregate amount that Landlord is required to disburse for such purpose pursuant to this Work Letter. Notwithstanding any contrary provision of this Agreement, if Tenant fails to use the entire Allowance by March 31, 2012, the unused amount shall revert to Landlord and Tenant shall have no further rights with respect thereto.

1.2 Disbursement. Except as otherwise provided in this Work Letter, the Allowance shall be disbursed by Landlord only for the following items (the “Allowance Items”): (a) the fees of Landlord’s or Tenant’s architect or engineers; (b) plan-check, permit and license fees relating to performance of the Tenant Improvement Work; (c) the cost of performing the Tenant Improvement Work, including after hours charges, testing and inspection costs, freight elevator usage, hoisting and trash removal costs, and contractors’ fees and general conditions; (d) the cost of any change to the base, shell or core of the Premises or Building required by the Plans (defined in Section 2.5 below) (including if such change is due to the fact that such work is prepared on an unoccupied basis), including all direct architectural and/or engineering fees and expenses incurred in connection therewith; (e) the cost of any change to the Plans or Tenant Improvement Work required by Law; (f) the Landlord Supervision Fee (defined in Section 3.2.2 below); (g) sales and use taxes; and (h) all other costs expended by Landlord in connection with the performance of the Tenant Improvement Work.

1.3 Landlord Costs. Notwithstanding any contrary provision of this Agreement, Tenant shall not be responsible for any Landlord Cost (defined below) and no Landlord Cost shall be an Allowance Item. As used herein, “Landlord Cost” means any portion of the cost of the Tenant Improvement Work that is reasonably attributable to the following and not to any negligence, willful misconduct or breach of this Agreement of or by Tenant or any of its employees, agents, contractors or representatives: (a) any breach by Landlord of any provision of this Agreement; (b) any change to the Plans not approved by Tenant; (c) any failure of Landlord to pay any amount owing to the Contractor (defined in Section 3.1 below) as and when required; (d) any breach by the Contractor of its obligations under the Construction Contract (defined in Section 3.2.3 below); (e) attorneys’ fees incurred in connection with negotiation of the Construction Contract; (f) interest or other costs of financing construction costs; (g) costs reasonably recoverable by Landlord under warranties or insurance; (h) costs of repairing damage resulting from a Casualty; (i) construction management or supervision fees charged by Landlord in excess of the Landlord Supervision Fee; (j) any failure of the existing condition or configuration of any Common Area or the Base Building to comply with Law (other than any such failure resulting from any use of the Premises for other than general office purposes), but only to the extent that Landlord has actual knowledge (without inquiry) of such failure as of the date of Landlord’s execution and delivery of this Agreement; or (k) any construction costs exceeding the Construction Pricing Proposal (defined in Section 2.6 below) approved by Tenant pursuant to Section 2.6 below, as such approved Construction Pricing Proposal may be changed from time to time to reflect any revision to the Approved Construction Drawings (defined in Section 2.5 below) requested or approved by Tenant pursuant to Section 2.7 below.

2 PLANS AND PRICING.

2.1 Selection of Architect. Landlord shall retain Reel Xxxxxxx (the “Architect”) and the engineering consultants of Landlord’s choice (the “Engineers”) to prepare all architectural plans for the Premises and all engineering working drawings relating to the structural, mechanical, electrical, plumbing, HVAC, life-safety, and sprinkler work in the Premises. The plans and drawings to be prepared by the Architect and the Engineers shall be referred to in this Work Letter as the “Plans.” Tenant shall be

Exhibit B

responsible for ensuring that all elements of the design of the Plans are suitable for Tenant’s use of the Premises, and neither the preparation of the Plans by the Architect or the Engineers nor Landlord’s approval of the Plans shall relieve Tenant from such responsibility. Landlord shall cause the Architect and the Engineers to cause the Plans to comply with Law; provided, however, that Tenant, not Landlord, shall be responsible for any violation of Law by the Plans resulting from Tenant’s use of the Premises for other than general office purposes. Tenant shall be responsible for ensuring that the Plans comply with Law to the extent Landlord is not expressly so responsible under this Section 2.1, and neither the preparation of the Plans by the Architect or the Engineers nor Landlord’s approval of the Plans shall relieve Tenant from such responsibility. To the extent that either party (the “Responsible Party”) is responsible under this Section 2.1 for causing the Plans to comply with Law, the Responsible Party may contest any alleged violation of Law in good faith, including by seeking a waiver or deferment of compliance, asserting any defense allowed by Law, and exercising any right of appeal (provided that the other party incurs no liability as a result of such contest and that, after completing such contest, the Responsible Party makes any modification to the Plans or any alteration to the Premises that is necessary to comply with any final order or judgment).

2.2 [Intentionally Omitted.]

2.3 [Intentionally Omitted.]

2.4 Additional Programming Information. Landlord and Tenant acknowledge that they have approved the space plan for the Premises prepared by the Architect and designated as Project No: OXT.SP, Revised: June 16, 2011 (the “Approved Space Plan”). Tenant shall deliver to Landlord, in writing, all information that, together with the Approved Space Plan, is necessary, in the judgment of Landlord, the Architect and the Engineers, to complete the architectural, engineering and final architectural working drawings for the Premises in a form that is sufficient to enable subcontractors to bid on the work and to obtain all applicable permits for the Tenant Improvement Work (the “Construction Drawings”), including electrical requirements, telephone requirements, special HVAC requirements, plumbing requirements, and all interior and special finishes (collectively, the “Additional Programming Information”). The Additional Programming Information shall be consistent with Landlord’s requirements for avoiding aesthetic, engineering or other conflicts with the design and function of the balance of the Building (collectively, the “Landlord Requirements”) and shall otherwise be subject to Landlord’s reasonable approval. Landlord shall provide Tenant with notice approving or reasonably disapproving the Additional Programming Information within five (5) business days after the later of Landlord’s receipt thereof or the mutual execution and delivery of this Agreement. If Landlord disapproves the Additional Programming Information, Landlord’s notice of disapproval shall describe with reasonable specificity the basis for such disapproval and the changes that would be necessary to resolve Landlord’s objections. If Landlord disapproves the Additional Programming Information, Tenant shall modify the Additional Programming Information and resubmit it for Landlord’s review and approval. Such procedure shall be repeated as necessary until Landlord has approved the Additional Programming Information. If requested by Tenant, Landlord, in its sole and absolute discretion, may assist Tenant, or cause the Architect and/or the Engineers to assist Tenant, in preparing all or a portion of the Additional Programming Information; provided, however, that, whether or not the Additional Programming Information is prepared with such assistance, Tenant shall be solely responsible for the timely preparation and delivery of the Additional Programming Information and for all elements thereof and, subject to Section 1 above, all costs relating thereto.

2.5 Construction Drawings. After approving the Additional Programming Information, Landlord shall cause the Architect and the Engineers to prepare and deliver to Tenant Construction Drawings that conform to the Approved Space Plan and the approved Additional Programming Information. Such preparation and delivery shall occur within 15 business days after the later of Landlord’s approval of the Additional Programming Information or the mutual execution and delivery of this Agreement. Tenant shall approve or disapprove the Construction Drawings by notice to Landlord. If Tenant disapproves the Construction Drawings, Tenant’s notice of disapproval shall specify any revisions Tenant desires in the Construction Drawings. After receiving such notice of disapproval, Landlord shall cause the Architect and/or the Engineers to revise the Construction Drawings, taking into account the reasons for Tenant’s disapproval (provided, however, that Landlord shall not be required to cause the Architect or the Engineers to make any revision to the Construction Drawings that is inconsistent with the Landlord Requirements or that Landlord otherwise reasonably disapproves), and resubmit the Construction Drawings to Tenant for its approval. Such revision and resubmission shall occur within five (5) business days after the later of Landlord’s receipt of Tenant’s notice of disapproval or the mutual execution and delivery of this Agreement if such revision is not material, and within such longer period of time as may be reasonably necessary (but not more than 15 business days after the later of such receipt or such mutual execution and delivery) if such revision is material. Such procedure shall be repeated as necessary until Tenant has approved the Construction Drawings. The Construction Drawings approved by Landlord and Tenant are referred to in this Work Letter as the “Approved Construction Drawings”.

Exhibit B

2.6 Construction Pricing. Within 10 business days after the Construction Drawings are approved by Landlord and Tenant, Landlord shall provide Tenant with Landlord’s reasonable estimate (the “Construction Pricing Proposal”) of the cost of all Allowance Items to be incurred by Tenant in connection with the performance of the Tenant Improvement Work pursuant to such Construction Drawings (the “Approved Construction Drawings”). The Construction Pricing Proposal shall be based on a bid from the Contractor (defined in Section 3.1 below) which in turn shall be based on competitive written bids from at least three (3) subcontractors for each trade involved in the Tenant Improvement Work other than any trade affecting any fire/life-safety system of the Building. Tenant shall provide Landlord with notice approving or disapproving the Construction Pricing Proposal. If Tenant disapproves the Construction Pricing Proposal, Tenant’s notice of disapproval shall be accompanied by proposed revisions to the Approved Construction Drawings that Tenant requests in order to resolve its objections to the Construction Pricing Proposal, and Landlord shall respond as required under Section 2.7 below. Such procedure shall be repeated as necessary until the Construction Pricing Proposal is approved by Tenant. Upon Tenant’s approval of the Construction Pricing Proposal, Landlord may purchase the items set forth in the Construction Pricing Proposal and commence construction relating to such items.

2.7 Revisions to Approved Construction Drawings. If Tenant requests any revision to the Approved Construction Drawings, Landlord shall provide Tenant with notice approving or reasonably disapproving such revision, and, if Landlord approves such revision, Landlord shall deliver to Tenant notice of any resulting change in the most recent Construction Pricing Proposal, if any, together with notice of Landlord’s estimate of the length of any resulting delay in the substantial completion of the Tenant Improvement Work, whereupon Tenant, within one (1) business day, shall notify Landlord whether it desires to proceed with such revision. If Landlord has commenced performance of the Tenant Improvement Work, then, in the absence of such authorization, Landlord shall have the option to continue such performance disregarding such revision. Landlord shall not revise the Approved Construction Drawings without providing Tenant with notice of any resulting change in the most recent Construction Pricing Proposal, if any, or without Tenant’s approval, which shall not be unreasonably withheld, conditioned or delayed. Without limiting the foregoing, Tenant shall not withhold or condition its approval of any revision to the Approved Construction Drawings that is required in order to (a) address any unanticipated physical condition, or (b) cause the Approved Construction Drawings to comply with applicable Laws.

2.8 Time Deadlines. Tenant shall use commercially reasonable efforts to cooperate with Landlord and its architect, engineers and other consultants to complete all phases of the Plans, approve the Construction Pricing Proposal and obtain the permits for the Tenant Improvement Work as soon as possible after the execution of this Agreement, and Tenant shall meet with Landlord, in accordance with a schedule reasonably determined by Landlord, to discuss the parties’ progress. Without limiting the foregoing, Tenant shall approve the Construction Pricing Proposal pursuant to Section 2.6 above on or before Tenant’s Approval Deadline (defined below). As used in this Work Letter, “Tenant’s Approval Deadline” means August 1, 2011; provided, however, that Tenant’s Approval Deadline shall be extended by one day for each day, if any, by which Tenant’s approval of the Construction Pricing Proposal pursuant to Section 2.6 above is delayed by any failure of Landlord to perform its obligations under this Section 2.

3 CONSTRUCTION.

3.1 Contractor. XxXxxxxx Construction (or another general contractor selected by Landlord and reasonably approved by Tenant) (the “Contractor”) shall perform the Tenant Improvement Work. In addition, Landlord may select and/or approve of any subcontractors, mechanics and materialmen used in connection with the performance of the Tenant Improvement Work.

3.2 Construction.

3.2.1 Over-Allowance Amount. If the Construction Pricing Proposal exceeds the Allowance, then, concurrently with its delivery to Landlord of approval of the Construction Pricing Proposal, Tenant shall deliver to Landlord cash in the amount of such excess (the “Over-Allowance Amount”). Any Over-Allowance Amount shall be disbursed by Landlord before the Allowance and pursuant to the same procedure as the Allowance. After the Construction Pricing Proposal is approved by Tenant, if any revision is made to the Approved Construction Drawings or the Tenant Improvement Work that increases the Construction Pricing Proposal, then Tenant shall deliver any resulting Over-Allowance Amount (or any resulting increase in the Over-Allowance Amount) to Landlord immediately upon Landlord’s request.

3.2.2 Landlord’s Retention of Contractor. Landlord shall independently retain the Contractor to perform the Tenant Improvement Work in accordance with the Approved Construction Drawings. Tenant shall pay a construction supervision and management fee (the “Landlord Supervision Fee”) to Landlord in an amount equal to 3% of the aggregate amount of all Allowance Items other than the Landlord Supervision Fee. Landlord shall cause the Contractor to perform the Tenant Improvement Work in a good and workmanlike manner and in accordance with the Approved Construction Drawings.

Exhibit B

3.2.3 Contractor’s Warranties. Tenant waives all claims against Landlord relating to any defects in the Tenant Improvements; provided, however, that if, within 30 days after substantial completion of the Tenant Improvements, Tenant provides notice to Landlord of any non-latent defect in the Tenant Improvements, or if, within 11 months after substantial completion of the Tenant Improvements, Tenant provides notice to Landlord of any latent defect in the Tenant Improvements, then Landlord shall, at its expense, correct such defect. As used in this Work Letter, “Construction Contract” means the construction contract between Landlord and the Contractor pursuant to which the Tenant Improvements will be constructed.

4 COMPLETION.

4.1 Ready for Occupancy. For purposes of Section 1.3.2 of this Agreement, the Premises shall be deemed “Ready for Occupancy” upon the substantial completion of the Tenant Improvement Work. Subject to Section 4.2 below, the Tenant Improvement Work shall be deemed “substantially complete” on the later of (a) the date of completion of the Tenant Improvement Work pursuant to the Approved Construction Drawings (as reasonably determined by Landlord), with the exception of any details of construction, mechanical adjustment or any other similar matter the non-completion of which does not materially interfere with Tenant’s use of the Premises, or (b) the date Landlord receives from the appropriate governmental authorities, with respect to the Tenant Improvements, all approvals necessary for the occupancy of the Premises.

4.2 Tenant Delay. If the substantial completion of the Tenant Improvement Work is delayed (a “Tenant Delay”) as a result of (a) any failure of Tenant to approve the Construction Pricing Proposal pursuant to Section 2.6 above on or before Tenant’s Approval Deadline; (b) Tenant’s failure to timely approve any matter requiring Tenant’s approval; (c) any breach by Tenant of this Work Letter or the Lease; (d) any change to the Approved Construction Drawings (but only to the extent that Landlord notifies Tenant, when Landlord approves such change, of the length of the delay that will be caused by such change)); (e) Tenant’s requirement for materials, components, finishes or improvements that are not available in a commercially reasonable time given the anticipated date of substantial completion of the Tenant Improvement Work as set forth in this Agreement (but only to the extent that Landlord notifies Tenant, when Landlord approves such requirement, of the length of the delay that will be caused by such requirement); (f) [Intentionally Omitted]; or (g) any other act or omission of Tenant or any of its agents, employees or representatives, then, notwithstanding any contrary provision of this Agreement, and regardless of when the Tenant Improvement Work is actually substantially completed, the Tenant Improvement Work shall be deemed to be substantially completed on the date on which the Tenant Improvement Work would have been substantially completed if no such Tenant Delay had occurred. Landlord shall use reasonable efforts to provide Tenant with prompt notice (which notice, notwithstanding Section 25.1 of this Agreement, may be given orally, by e-mail, or by any other method) of any Tenant Delay so that Tenant may take action to avoid or minimize the same.

5 MISCELLANEOUS. Notwithstanding any contrary provision of this Agreement, if Tenant defaults under this Agreement before the Tenant Improvement Work is completed, Landlord’s obligations under this Work Letter shall be excused until such default is cured and Tenant shall be responsible for any resulting delay in the completion of the Tenant Improvement Work. This Work Letter shall not apply to any space other than the Premises.

Exhibit B

EXHIBIT C

225 WEST SANTA XXXXX

CONFIRMATION LETTER

, 20


To:

Re: Office Lease (the “Lease”) dated , 20 , between , a (“Landlord”), and , a (“Tenant”), concerning Suite on the floor of the building located at , California.

Lease ID:

Business Unit Number:

Dear :

In accordance with the Lease, Tenant accepts possession of the Premises and confirms the following:

The Commencement Date is and the Expiration Date is .

The exact number of rentable square feet within the Premises is square feet, subject to Section 2.1.1 of the Lease.

Tenant’s Share, based upon the exact number of rentable square feet within the Premises, is %, subject to Section 2.1.1 of the Lease.

Please acknowledge the foregoing by signing all three (3) counterparts of this letter in the space provided below and returning two (2) fully executed counterparts to my attention. Please note that, pursuant to Section 2.1.1 of the Lease, if Tenant fails to execute and return (or, by notice to Landlord, reasonably object to) this letter within five (5) days after receiving it, Tenant shall be deemed to have executed and returned it without exception.


“Landlord”:

,


a



By:


Name:


Title:

Agreed and Accepted as of , 200 .


“Tenant”:

,


a


By:


Name:


Title:

Exhibit C

EXHIBIT E

225 WEST SANTA XXXXX

JUDICIAL REFERENCE

IF THE JURY-WAIVER PROVISIONS OF SECTION 25.8 OF THIS LEASE ARE NOT ENFORCEABLE UNDER CALIFORNIA LAW, THE PROVISIONS SET FORTH BELOW SHALL APPLY.

It is the desire and intention of the parties to agree upon a mechanism and procedure under which controversies and disputes arising out of this Lease or related to the Premises will be resolved in a prompt and expeditious manner. Accordingly, except with respect to actions for unlawful or forcible detainer or with respect to the prejudgment remedy of attachment, any action, proceeding or counterclaim brought by either party hereto against the other (and/or against its officers, directors, employees, agents or subsidiaries or affiliated entities) on any matters arising out of or in any way connected with this Lease, Tenant’s use or occupancy of the Premises and/or any claim of injury or damage, whether sounding in contract, tort, or otherwise, shall be heard and resolved by a referee under the provisions of the California Code of Civil Procedure, Sections 638 — 645.1, inclusive (as same may be amended, or any successor statute(s) thereto) (the “Referee Sections”). Any fee to initiate the judicial reference proceedings and all fees charged and costs incurred by the referee shall be paid by the party initiating such procedure (except that if a reporter is requested by either party, then a reporter shall be present at all proceedings where requested and the fees of such reporter – except for copies ordered by the other parties – shall be borne by the party requesting the reporter); provided however, that allocation of the costs and fees, including any initiation fee, of such proceeding shall be ultimately determined in accordance with Section 25.6 of this Lease. The venue of the proceedings shall be in the county in which the Premises is located. Within 10 days of receipt by any party of a request to resolve any dispute or controversy pursuant to this Exhibit E, the parties shall agree upon a single referee who shall try all issues, whether of fact or law, and report a finding and judgment on such issues as required by the Referee Sections. If the parties are unable to agree upon a referee within such 10-day period, then any party may thereafter file a lawsuit in the county in which the Premises is located for the purpose of appointment of a referee under the Referee Sections. If the referee is appointed by the court, the referee shall be a neutral and impartial retired judge with substantial experience in the relevant matters to be determined, from Jams/Endispute, Inc., ADR Services, Inc. or a similar mediation/arbitration entity approved by each party in its sole and absolute discretion. The proposed referee may be challenged by any party for any of the grounds listed in the Referee Sections. The referee shall have the power to decide all issues of fact and law and report his or her decision on such issues, and to issue all recognized remedies available at law or in equity for any cause of action that is before the referee, including an award of attorneys’ fees and costs in accordance with this Lease. The referee shall not, however, have the power to award punitive damages, nor any other damages that are not permitted by the express provisions of this Lease, and the parties waive any right to recover any such damages. The parties may conduct all discovery as provided in the California Code of Civil Procedure, and the referee shall oversee discovery and may enforce all discovery orders in the same manner as any trial court judge, with rights to regulate discovery and to issue and enforce subpoenas, protective orders and other limitations on discovery available under California Law. The reference proceeding shall be conducted in accordance with California Law (including the rules of evidence), and in all regards, the referee shall follow California Law applicable at the time of the reference proceeding. The parties shall promptly and diligently cooperate with one another and the referee, and shall perform such acts as may be necessary to obtain a prompt and expeditious resolution of the dispute or controversy in accordance with the terms of this Exhibit E. In this regard, the parties agree that the parties and the referee shall use best efforts to ensure that (a) discovery be conducted for a period no longer than 6 months from the date the referee is appointed, excluding motions regarding discovery, and (b) a trial date be set within 9 months of the date the referee is appointed. In accordance with Section 644 of the California Code of Civil Procedure, the decision of the referee upon the whole issue must stand as the decision of the court, and upon the filing of the statement of decision with the clerk of the court, or with the judge if there is no clerk, judgment may be entered thereon in the same manner as if the action had been tried by the court. Any decision of the referee and/or judgment or other order entered thereon shall be appealable to the same extent and in the same manner that such decision, judgment, or order would be appealable if rendered by a judge of the superior court in which venue is proper hereunder. The referee shall in his/her statement of decision set forth his/her findings of fact and conclusions of law. The parties intend this general reference agreement to be specifically enforceable in accordance with the Code of Civil Procedure. Nothing in this Exhibit E shall prejudice the right of any party to obtain provisional relief or other equitable remedies from a court of competent jurisdiction as shall otherwise be available under the Code of Civil Procedure and/or applicable court rules.

Exhibit E

EXHIBIT F

000 XXXX XXXXX XXXXX

ADDITIONAL PROVISIONS

Early Entry. Tenant may enter the Premises before the Premises becomes Ready for Occupancy (but not before the date that Landlord reasonably estimates will occur 20 business days before the Premises becomes Ready for Occupancy), solely for the purpose of installing telecommunications and data cabling in the Premises, and (ii) after installation of the carpeting in the Premises and before the Premises becomes Ready for Occupancy (but not before the date that Landlord reasonably estimates will occur 20 business days before the Premises becomes Ready for Occupancy), solely for the purpose of installing equipment, furnishings and other personal property in the Premises. Other than the obligation to pay Base Rent and Tenant’s Share of any Expense Excess or Tax Excess, all of Tenant’s obligations hereunder shall apply during any period of such early entry. Notwithstanding the foregoing, Landlord may limit, suspend or terminate Tenant’s rights to enter the Premises pursuant to this Section 1 if Landlord reasonably determines that such entry is endangering individuals working in the Premises or is delaying completion of the Tenant Improvement Work.

Use of Landlord’s Furniture. During the Term Tenant may use, within the Premises only, the furniture owned by Landlord that is currently located in the Premises and described on Exhibit F-1 (“Landlord’s Furniture”). Tenant accepts Landlord’s Furniture in its existing condition, with no representations or warranties as to quality, condition, merchantability or fitness for use, any such warranties being specifically excluded. Tenant, at its expense, shall maintain Landlord’s Furniture (and, upon the expiration or earlier termination of this Lease, surrender Landlord’s Furniture to Landlord) in as good condition as exists on the date of delivery of possession thereof to Tenant, ordinary wear and tear excepted. Without limiting the foregoing, Tenant shall be responsible for repairing and/or replacing Landlord’s Furniture to the extent it is damaged by any Casualty during the Term, and shall cause Landlord’s Furniture to be covered by Tenant’s property insurance required under Section 10.2.2 of this Lease. Before delivering possession of the Premises to Tenant, Landlord, at its expense, shall remove all furniture other than Landlord’s Furniture.

3.	Building Signage.

3.1.

Tenant’s Right to Building Signage. Subject to the terms of this Section 3, from and after the Commencement Date, Tenant shall have the right to install, maintain, repair, replace and operate the Building Signage (defined below). As used herein, “Building Signage” means a sign (including the rectangular prism on which the lettering of the sign will be mounted) that (i) bears the Tenant Name (defined below) and is located on the west side of the Building facing Notre Dame Avenue, as more particularly shown in Exhibit F-2 attached hereto. As used herein, “Tenant Name” means, at any time, at Tenant’s discretion, (i) the name of Tenant set forth in the first paragraph of this Lease (“Tenant’s Existing Name”), or (ii) if Tenant’s name is not then Tenant’s Existing Name, then Tenant’s name, provided that such name is compatible with a first-class office building, as determined by Landlord in its reasonable discretion, and/or (iii) Tenant’s logo, provided that such logo is then being used by Tenant on a substantially nationwide basis and is compatible with a first-class office building, as determined by Landlord in its reasonable discretion. Notwithstanding any contrary provision hereof, (i) Tenant’s rights to the Building Signage under this Section 3 shall be personal to the party named as Tenant in the first paragraph of this Lease (“Existing Tenant”) and to any successor to Existing Tenant’s interest in the Lease that acquires its interest in the Lease solely by means of one or more Permitted Transfers originating with Existing Tenant, and may not be transferred to any other party; and (ii) if at any time the Minimum Occupancy Requirement (defined below) is not satisfied, then, at Landlord’s option (which shall not be deemed waived by the passage of time), Tenant shall no longer have any further right to the Building Signage under this Section 3, even if the Minimum Occupancy Requirement later becomes satisfied. For purposes hereof, the “Minimum Occupancy Requirement” shall be deemed satisfied if and only if at least 75% of the rentable square footage of the Premises has not been subleased, in whole or in part, for more than 75% of the balance of the term of the Lease.

3.2.

Landlord’s Approval. The size, color, materials and all other aspects of the Building Signage, including the manner in which it is attached to the Building and any provisions for illumination, shall be subject to Landlord’s approval, which may be withheld in Landlord’s reasonable discretion; provided, however, that Landlord’s approval as to aesthetic matters may be withheld in Landlord’s sole and absolute (but good faith) discretion. Without limiting the foregoing, Landlord may require that all aspects of the design, fabrication and installation of the Building Signage be consistent with those of the existing Building signs (i.e., for CBRE and Deloitte).

Exhibit F

3.3.

General Provisions. Tenant, at its expense, shall design, fabricate, install, maintain, repair, replace, operate and remove the Building Signage, in each case in a first class manner consistent with a first-class office building and in compliance with all applicable Laws. Without limiting the foregoing, Tenant shall not install or modify the Building Signage until after obtaining and providing copies to Landlord of ail permits and approvals necessary therefor. Tenant shall be solely responsible, at its expense, for obtaining such permits and approvals; provided, however, that Landlord shall reasonably cooperate with Tenant, at no material cost or liability to Landlord, in executing permit applications and performing any other ministerial acts reasonably necessary to enable Tenant to obtain such permits and approvals. Within 30 days after the expiration or earlier termination of the Lease (or, if earlier, the date on which Tenant becomes no longer entitled to Building Signage under this Section 3), Tenant, at its expense, shall remove the Building Signage and restore all damage to the Building caused by its installation, operation or removal. Notwithstanding any contrary provision of the Lease, Tenant, not Landlord, shall, at its expense, (i) cause its property insurance policy to cover the Building Signage, and (ii) promptly repair the Building Signage if it is damaged by fire or any other casualty (unless Tenant, by prompt written notice to Landlord, elects to remove the Building Signage altogether, in which event Tenant shall no longer be entitled to Building Signage under this Section 3). Except as may be expressly provided in this Section 3, the installation, maintenance, repair, replacement, removal and any other work performed by Tenant affecting the Building Signage shall be governed by the provisions of Section 7 of this Lease as if such work were an Alteration. If an emergency results from Tenant’s failure to maintain, repair, replace, operate or remove the Building Signage as required under this Section 3, then, without limiting Landlord’s remedies, Landlord, at its option, with notice to Tenant (by telephone, e-mail, fax or any other reasonable method, notwithstanding Section 25.1 of this Lease), may perform such maintenance, repair, replacement, operation or removal, in which event Tenant shall reimburse Landlord for the reasonable cost thereof upon Landlord’s demand. The costs of any utilities consumed in operation of the Building Signage shall be paid by Tenant upon Landlord’s demand in accordance with Section 6.2 of this Lease.

4.	Extension Option.

4.1.

Grant of Option; Conditions. Tenant shall have the right (the “Extension Option”) to extend the term of the Lease for one additional period of three (3) years commencing on the day following the expiration date of the Lease and ending on the 3^rd anniversary of the expiration date of the Lease (the “Extension Term”), if:

Not less than 12 and not more than 15 full calendar months before the expiration date of the Lease, Tenant delivers written notice to Landlord (the “Extension Notice”) electing to exercise the Extension Option and stating Tenant’s estimate of the Prevailing Market (defined in Section 4.5 below) rate for the Extension Term;

Tenant is not in default under the Lease beyond any applicable cure period when Tenant delivers the Extension Notice;

No part of the Premises is sublet (other than to an Affiliate of Tenant) when Tenant delivers the Extension Notice; and

The Lease has not been assigned (other than pursuant to a Permitted Transfer) before Tenant delivers the Extension Notice.

4.2.

Terms Applicable to Extension Term.

During the Extension Term, (a) the Base Rent rate per rentable square foot shall be equal to the Prevailing Market rate per rentable square foot; (b) Base Rent shall increase, if at all, in accordance with the increases assumed in the determination of Prevailing Market rate; and (c) Base Rent shall be payable in monthly installments in accordance with the terms and conditions of the Lease.

During the Extension Term Tenant shall pay Tenant’s Share of Expenses and Taxes for the Premises in accordance with the Lease, but the Base Year shall be the calendar year in which the Extension Term commences.

4.3.

Procedure for Determining Prevailing Market.

Initial Procedure. Within 30 days after receiving the Extension Notice, Landlord shall give Tenant either (1) written notice (“Landlord’s Binding Notice”) accepting Tenant’s estimate of the Prevailing Market rate for the Extension Term stated in the Extension Notice, or (ii) written notice (“Landlord’s Rejection

Exhibit F

Notice”) rejecting such estimate and stating Landlord’s estimate of the Prevailing Market rate for the Extension Term. If Landlord gives Tenant a Landlord’s Rejection Notice, Tenant, within 15 days thereafter, shall give Landlord either (i) written notice (“Tenant’s Binding Notice”) accepting Landlord’s estimate of the Prevailing Market rate for the Extension Term stated in such Landlord’s Rejection Notice, or (ii) written notice (“Tenant’s Rejection Notice”) rejecting such estimate. If Tenant gives Landlord a Tenant’s Rejection Notice, Landlord and Tenant shall work together in good faith to agree in writing upon the Prevailing Market rate for the Extension Term. If, within 30 days after delivery of a Tenant’s Rejection Notice, the parties fail to agree in writing upon the Prevailing Market rate, the provisions of Section 4.3.B below shall apply.

Dispute Resolution Procedure.

If, within 30 days after delivery of a Tenant’s Rejection Notice, the parties fail to agree in writing upon the Prevailing Market rate, Landlord and Tenant, within five (5) days thereafter, shall each simultaneously submit to the other, in a sealed envelope, its good faith estimate of the Prevailing Market rate for the Extension Term (collectively, the “Estimates”). Within seven (7) days after the exchange of Estimates, Landlord and Tenant shall each select an appraiser to determine which of the two Estimates most closely reflects the Prevailing Market rate for the Extension Term. Each appraiser so selected shall be certified as an MAI appraiser or as an ASA appraiser and shall have had at least five (5) years experience within the previous 10 years as a real estate appraiser working in San Jose, California, with working knowledge of current rental rates and leasing practices relating to buildings similar to the Building. For purposes hereof, an “MAI” appraiser means an individual who holds an MAI designation conferred by, and is an independent member of, the American Institute of Real Estate Appraisers (or its successor organization, or in the event there is no successor organization, the organization and designation most similar), and an “ASA” appraiser means an individual who holds the Senior Member designation conferred by, and is an independent member of, the American Society of Appraisers (or its successor organization, or, in the event there is no successor organization, the organization and designation most similar).

If each party selects an appraiser in accordance with Section 4.3.B.1 above, the parties shall cause their respective appraisers to work together in good faith to agree upon which of the two Estimates most closely reflects the Prevailing Market rate for the Extension Term. The Estimate, if any, so agreed upon by such appraisers shall be final and binding on both parties as the Prevailing Market rate for the Extension Term and may be entered in a court of competent jurisdiction. If the appraisers fail to reach such agreement within 20 days after their selection, then, within 10 days after the expiration of such 20-day period, the parties shall instruct the appraisers to select a third appraiser meeting the above criteria (and if the appraisers fail to agree upon such third appraiser within 10 days after being so instructed, either party may cause a court of competent jurisdiction to select such third appraiser). Promptly upon selection of such third appraiser, the parties shall instruct such appraiser (or, if only one of the parties has selected an appraiser within the 7-day period described above, then promptly after the expiration of such 7-day period the parties shall instruct such appraiser) to determine, as soon as practicable but in any case within 14 days after his selection, which of the two Estimates most closely reflects the Prevailing Market rate. Such determination by such appraiser (the “Final Appraiser”) shall be final and binding on both parties as the Prevailing Market rate for the Extension Term and may be entered in a court of competent jurisdiction. if the Final Appraiser believes that expert advice would materially assist him, he may retain one or more qualified persons to provide such expert advice. The parties shall share equally in the costs of the Final Appraiser and of any experts retained by the Final Appraiser. Any fees of any other appraiser, counsel or expert engaged by Landlord or Tenant shall be borne by the party retaining such appraiser, counsel or expert.

Exhibit F

If the Prevailing Market rate has not been determined by the commencement date of the Extension Term, Tenant shall pay Base Rent for the Extension Term upon the terms and conditions in effect during the last month ending on or before the Expiration Date until such time as the Prevailing Market rate has been determined. Upon such determination, the Base Rent for the Extension Term shall be retroactively adjusted. If such adjustment results in an under- or overpayment of Base Rent by Tenant, Tenant shall pay Landlord the amount of such underpayment, or receive a credit in the amount of such overpayment, with or against the next Base Rent due under the Lease.

4.4.

Extension Amendment. If Tenant is entitled to and properly exercises its Extension Option, and if the Prevailing Market rate for the Extension Term is determined in accordance with Section 4.3 above, Landlord, within a reasonable time thereafter, shall prepare and deliver to Tenant an amendment (the “Extension Amendment”) reflecting changes in the Base Rent, the term of the Lease, the expiration date of the Lease, and other appropriate terms, and Tenant shall execute and return the Extension Amendment to Landlord within 15 days after receiving it. Notwithstanding the foregoing, upon determination of the Prevailing Market rate for the Extension Term in accordance with Section 4.3 above, an otherwise valid exercise of the Extension Option shall be fully effective whether or not the Extension Amendment is executed.

4.5.

Definition of Prevailing Market. For purposes of this Extension Option, “Prevailing Market” shall mean the arms-length, fair-market, annual rental rate per rentable square foot under extension and renewal leases and amendments entered into on or about the date on which the Prevailing Market is being determined hereunder for space comparable to the Premises in the Building and office buildings comparable to the Building in the San Jose, California area. The determination of Prevailing Market shall take into account any material economic differences between the terms of the Lease and any comparison lease or amendment, such as rent abatements, construction costs and other concessions, and the manner, if any, in which the landlord under any such lease is reimbursed for operating expenses and taxes. The determination of Prevailing Market shall also take into consideration any reasonably anticipated changes in the Prevailing Market rate from the time such Prevailing Market rate is being determined and the time such Prevailing Market rate will become effective under the Lease.

5.	Provisions Required Under Existing Security Agreement. Notwithstanding any contrary provision of this Lease:

Permitted Use. No portion of the Premises shall be used for any of the following uses: any pornographic or obscene purposes, any commercial sex establishment, any pornographic, obscene, nude or semi-nude performances, modeling, materials, activities, or sexual conduct or any other use that, as of the time of the execution hereof, has or could reasonably be expected to have a material adverse effect on the Property or its use, operation or value.

Subordination and Attornment. This Lease shall be subject and subordinate to any Security Agreement (other than a ground lease) existing as of the date of mutual execution and delivery of this Lease (as the same may be amended, restated, replaced, supplemented or otherwise modified from time to time, an “Existing Security Agreement”) or any loan document secured by any Existing Security Agreement (an “Existing Loan Document”). In the event of the enforcement by any Security Holder of any remedy under any Existing Security Agreement or Existing Loan Document, Tenant shall, at the option of the Security Holder or of any other person or entity succeeding to the interest of the Security Holder as a result of such enforcement, attorn to the Security Holder or to such person or entity and shall recognize the Security Holder or such successor in the interest as lessor under this Lease without change in the provisions thereof; provided, however, the Security Holder or such successor in interest shall not be liable for or bound by (i) any payment of an installment of rent or additional rent which may have been made more than thirty (30) days before the due date of such installment, (ii) any act or omission of or default by Landlord under this Lease (but the Security Holder, or such successor, shall be subject to the continuing obligations of Landlord to the extent arising from and after such succession to the extent of the Security Holder’s, or such successor’s, interest in the Property), (iii) any credits, claims, setoffs or defenses which Tenant may have against Landlord, or (iv) any obligation under this Lease to maintain a fitness facility at the Property. Tenant, upon the reasonable request by the Security Holder or such successor in interest, shall execute and deliver an instrument or instruments confirming such attornment. Notwithstanding the foregoing, in the event the Security Holder under any Existing Security Agreement or Existing Loan Document shall have entered into a separate subordination, attornment and non-disturbance agreement directly with Tenant

Exhibit F

governing Tenant’s obligation to attorn to the Security Holder or such successor in interest as lessor, the terms and provisions of such agreement shall supersede the provisions of this Subsection.

Proceeds.

As used herein, “Proceeds” means any compensation, awards, proceeds, damages, claims, insurance recoveries, causes or rights of action (whenever accrued) or payments which Landlord may receive or to which Landlord may become entitled with respect to the Property or any part thereof (other than payments received in connection with any liability or loss of rental value or business interruption insurance) in connection with any taking by condemnation or eminent domain (“Taking”) of, or any casualty or other damage or injury to, the Property or any part thereof.

Nothing in this Lease shall be deemed to entitle Tenant to receive and retain Proceeds except those that may be specifically awarded to it in condemnation proceedings because of the Taking of its trade fixtures and its leasehold improvements which have not become part of the Property and such business loss as Tenant may specifically and separately establish. Nothing in the preceding sentence shall be deemed to expand any right Tenant may have under this Lease to receive or retain any Proceeds.

Nothing in this Lease shall be deemed to prevent Proceeds from being held and disbursed by any Security Holder under any Existing Loan Documents in accordance with the terms of such Existing Loan Documents. However, if, in the event of any casualty or partial Taking, any obligation of Landlord under this Lease to restore the Premises or the Building is materially diminished by the operation of the preceding sentence, then Landlord, as soon as reasonably practicable after the occurrence of such casualty or partial Taking, shall provide written notice to Tenant describing such diminution with reasonably specificity, whereupon, unless Landlord has agreed in writing, in its sole and absolute discretion, to waive such diminution, Tenant, by written notice to Landlord delivered within 10 days after receipt of Landlord’s notice, shall have the right to terminate this Lease effective 10 days after the date of such termination notice.

Exercise Facility. So long as Landlord or an affiliate of Landlord causes an exercise facility (“Exercise Facility”) to be maintained and operated at the building located at 00 Xxxxxxx, Xxx Xxxx, Xxxxxxxxxx (“Ten Almaden”) for general use by occupants of Ten Almaden, Landlord or such affiliate of Landlord shall cause such Exercise Facility to be made available for use by Tenant’s employees during the same hours and upon the same terms and conditions as such Exercise Facility is made generally available for use by occupants of Ten Almaden. Without limiting the foregoing, any employee of Tenant electing to use the Exercise Facility shall be required, before commencing such use, to execute and deliver to Landlord or affiliate of Landlord (or the operator of the Exercise Facility) Landlord’s (or such affiliate’s or such operator’s) then-standard form of license or other agreement governing the same and to pay the applicable fee. As of the date hereof, the fee to use the Exercise Facility is $200.00 per person per year.

7.	Letter of Credit.

7.1.

General Provisions. In lieu of the Security Deposit, Tenant may deliver to Landlord, as collateral for the full performance by Tenant of all of its obligations under this Lease and for all damages Landlord may suffer as a result of Tenant’s breach of one or more provisions of this Lease, including any damages arising under California Civil Code § 1951.2 following termination of this Lease, a standby, unconditional, irrevocable, transferable letter of credit (the “Letter of Credit”) in the form of Exhibit F-3 and containing the terms required herein, in the face amount of $183,987.20 (the “Letter of Credit Amount”), naming Landlord as beneficiary, issued (or confirmed) by Silicon Valley Bank or another financial institution acceptable to Landlord in Landlord’s sole discretion, permitting multiple and partial draws thereon, and otherwise in form acceptable to Landlord in its sole discretion. Tenant shall cause the Letter of Credit to be continuously maintained in effect (whether through replacement, renewal or extension) in the Letter of Credit Amount through the date (the “Final LC Expiration Date”) that is 60 days after the scheduled expiration date of the Term, as it may be extended from time to time. If the Letter of Credit held by Landlord expires before the Final LC Expiration Date (whether by reason of a stated expiration date or a notice of termination or non-renewal given by the issuing bank), Tenant shall deliver to Landlord, not later than 30 days before the expiration date of the Letter of Credit then held by Landlord, either

Exhibit F

(x) a new Letter of Credit or certificate of renewal or extension, or (y) a cash Security Deposit in the amount of the Letter of Credit Amount. In addition, if, at any time before the Final LC Expiration Date, the financial institution that issued (or confirmed) the Letter of Credit held by Landlord fails to meet the Minimum Financial Requirement (defined below), Tenant, within 15 business days after Landlord’s demand, shall deliver to Landlord, in replacement of such Letter of Credit, either (x) a new Letter of Credit issued (or confirmed) by a financial institution that meets the Minimum Financial Requirement and is otherwise acceptable to Landlord in Landlord’s reasonable discretion, or (y) a cash Security Deposit in the amount of the Letter of Credit Amount, whereupon Landlord shall return to Tenant the Letter of Credit that is being replaced. If Tenant delivers to Landlord a cash Security Deposit in the amount of the Letter of Credit Amount pursuant to clause (y) of either of the preceding two (2) sentences, such Security Deposit shall be governed by Section 21 of this Lease and Tenant shall have no further obligation under this Section 7 to provide Landlord with a Letter of Credit. For purposes hereof, a financial institution shall be deemed to meet the “Minimum Financial Requirement” on a particular date if and only if, as of such date, such financial institution (i) has not been placed into receivership by the FDIC; and (ii) has a financial strength that, in Landlord’s good faith judgment, is not less than that which is then generally required by Landlord and its affiliates as a condition to accepting letters of credit in support of new leases. Any new Letter of Credit or certificate of renewal or extension (a “Renewal or Replacement LC”) shall comply with all of the provisions of this Section 7, shall be irrevocable and transferable and shall remain in effect (or be automatically renewable) through the Final LC Expiration Date upon the same terms as the Letter of Credit that is expiring or being replaced.

7.2.

Drawings under Letter of Credit. If Tenant breaches any provision of this Lease, then (i) Landlord, without limiting its remedies, may draw upon the Letter of Credit in an amount necessary to satisfy any damages suffered by Landlord (including any damages arising under section California Civil Code § 1951.2 following termination of this Lease) as a result of such breach; and (ii) without limiting the preceding clause (i), if less than 60 days remain before the Final. LC Expiration Date, then Landlord, without limiting its remedies, may draw upon the Letter of Credit in its entirety. In addition, if Tenant fails to deliver to Landlord, when required under Section 7.1 above, a Renewal or Replacement LC complying with all of the provisions of this Section 7 or a cash Security Deposit in the amount of the Letter of Credit Amount, Landlord, without limiting its remedies, may draw upon the Letter of Credit in its entirety; provided, however, that Landlord shall pay to Tenant any unapplied proceeds from such draw upon Tenant’s delivery to Landlord of such Renewal or Replacement LC or such cash Security Deposit. Proceeds of the Letter of Credit obtained through a draw permitted under this Section 7.2 (“Permitted Proceeds”) may be held by Landlord, without segregation, in accordance with this Section 7 until applied to Landlord’s damages or paid to Tenant pursuant to this Section 7.

7.3.

Use of Permitted Proceeds. Except as provided below in this Section 7.3, Permitted Proceeds shall constitute Landlord’s sole and separate property (and not Tenant’s property or the property of Tenant’s bankruptcy estate) and Landlord may, immediately upon any draw (and without notice to Tenant), apply Permitted Proceeds to any damages suffered by Landlord (including any damages arising under section California Civil Code § 1951.2 following termination of this Lease) as a result of any breach by Tenant of any provision of this Lease (provided, however, that Landlord shall not so apply any Permitted Proceeds that have been obtained through a draw made pursuant to the second sentence of Section 7.2 above until after so applying any other Permitted Proceeds). Provided that Tenant is not in default under this Lease, Landlord shall pay to Tenant, within 45 days after the Final LC Expiration Date, the amount of any Permitted Proceeds that have not been applied to Landlord’s damages or paid to Tenant; provided, however, that if, before the expiration of such 45-day period, a voluntary petition is filed by Tenant or any Guarantor, or an involuntary petition is filed against Tenant or any Guarantor by any of Tenant’s or Guarantor’s creditors, under the Federal Bankruptcy Code, then such payment shall not be required until either all preference issues relating to payments under this Lease have been resolved in such bankruptcy or reorganization case or such bankruptcy or reorganization case has been dismissed, in each case pursuant to a final court order not subject to appeal or any stay pending appeal.

7.4.

Additional Covenants of Tenant. If, for any reason, at any time before the date, if any, on which Tenant delivers to Landlord a cash Security Deposit in the amount of the Letter of Credit Amount pursuant to Section 7.1 above, the sum of (a) the amount of the Letter of Credit, plus (b) the amount of any unapplied Permitted Proceeds held by Landlord, becomes less than the Letter of Credit Amount, Tenant shall, within five (5) days

Exhibit F

thereafter, provide Landlord with additional letter(s) of credit in an amount equal to the deficiency (or a replacement letter of credit in the total Letter of Credit Amount less the amount of any unapplied Permitted Proceeds held by Landlord), and any such additional (or replacement) letter of credit shall comply with all of the provisions of this Section 7, and if Tenant fails to comply with the foregoing, notwithstanding any contrary provision of this Lease, such failure shall constitute an incurable Default by Tenant. Tenant further covenants and warrants that it will neither assign nor encumber the Letter of Credit or any part thereof and that neither Landlord nor its successors or assigns will be bound by any such assignment, encumbrance, attempted assignment or attempted encumbrance.

7.5.

Nature of Letter of Credit. Landlord and Tenant (a) acknowledge and agree that in no event shall the Letter of Credit or any renewal thereof, any substitute therefor or any Permitted Proceeds be deemed to be or treated as a “security deposit” under California Civil Code § 1950.7, as it may be amended or succeeded, or any other Law applicable to security deposits in the commercial context (“Security Deposit Laws”); (b) acknowledge and agree that the Letter of Credit (including any renewal thereof, any substitute therefor or any Permitted Proceeds) is not intended to serve as a security deposit and shall not be subject to the Security Deposit Laws; and (c) waive any and all rights, duties and obligations either party may now or, in the future, will have relating to or arising from the Security Deposit Laws. Tenant hereby waives the provisions of California Civil Code § 1950.7 and all other provisions of Law, now or hereafter in effect, which (i) establish the time frame by which Landlord must refund a security deposit under a lease, and/or (ii) provide that Landlord may claim from the security deposit only those sums reasonably necessary to remedy defaults in the payment of rent, to repair damage caused by Tenant or to clean the Premises, it being agreed that Landlord may, in addition, claim those sums specified above in this Section 7 and/or those sums reasonably necessary to compensate Landlord for any loss or damage caused by Tenant’s breach of this Lease or the acts or omission of Tenant or any other Tenant Related Parties, including any damages Landlord suffers following termination of this Lease.

Late Delivery of Premises; Abatement of Base Rent. Notwithstanding any contrary provision hereof, if the Commencement Date does not occur on or before the Outside Completion Date (defined below), Tenant, as its sole remedy, shall be entitled to an abatement of Base Rent, beginning on the date that Base Rent otherwise first becomes payable hereunder, in the amount of the lesser of (i) the Per Diem Holdover Rent (defined below), if any, or (ii) $2,300.00, for each day in the period beginning on the Outside Completion Date and ending on the date immediately preceding the Commencement Date. As used herein, “Outside Completion Date” means the date occurring 120 days after the Start Date (defined below); provided, however, that the Outside Completion Date shall be postponed by one (1) day for each day, if any, by which the substantial completion of the Tenant Improvement Work is delayed by (a) any event of Force Majeure, or (b) any change to the scope of the Tenant Improvement Work from that described in the Approved Space Plan, except to the extent such delay resulting from such change constitutes a Tenant Delay. As used herein, “Start Date” means the latest of (i) the date of mutual execution and delivery of this Lease, (ii) the date on which Tenant approves the Construction Pricing Proposal pursuant to Section 2.6 of Exhibit B, or (iii) if any governmental permit is required for the Tenant Improvement Work, the Permit Completion Date (defined below). As used herein, “Permit Completion Date” means the date on which Landlord receives all governmental permits, if any, required for the Tenant Improvement Work; provided, however, that the Permit Completion Date shall be accelerated by one (1) day for each day, if any, by which Landlord’s submittal of all necessary applications for such permits to the appropriate governmental authorities is delayed by (x) any failure of Landlord to use reasonable efforts to make such submittal as soon as reasonably possible after the later of the date of mutual execution and delivery of this Lease or the date on which Tenant approves the Construction Pricing Proposal pursuant to Section 2.6 of Exhibit B (provided further, however, that, without limitation, Landlord shall not be deemed to have failed to use such reasonable efforts by virtue of taking (1) up to five (5) business days after such date to enter into a construction contract with a contractor, or (2) such additional time as is reasonably necessary for Landlord’s contractor, after entering into such construction contract, to make and attend any appointments with such governmental authorities to submit applications for “over-the-counter” permits for the Tenant Improvement Work), or (y) any failure of Landlord to comply with its obligations under Section 2 of Exhibit B. As used herein, “Per Diem Holdover Rent” means, for any day occurring after the expiration date of the Existing Lease (defined below), the amount, if any, by which the rent Tenant is required to pay (and actually pays) under the Existing Lease for such day exceeds the average per diem rent that Tenant was required to pay during the last full calendar month of the term of the Existing Lease. As used herein, “Existing Lease” means that certain lease dated October 29, 2010 as it may have been amended, between Tenant, as tenant, and Xxxxxxx Xxxxxxx and Xxxxxx Xxxxxxxx, as landlord, relating to approximately 23,973 rentable square feet in the building commonly known as The Metropole Building located at 00 X. Xxxxxx Xxxxxx, Xxx Xxxx, XX 00000-0000.

Exhibit F

EXHIBIT F-1

000 XXXX XXXXX XXXXX

XXXXXXXX’S FURNITURE


Date	Location	Item	Quantity
25-May		2 Drawer File Cabinate Grey	47
25-May		3 Drawer File Petistal Grey	30
25-May	Executive Administrator Station outside 1207	4 x 6 Lateral Shelves	24
25-May		Arm Chair (visitor)	34
25-May	1203	Executive Built-in	1
25-May	1205	Executive Built-in	1
25-May	1206	Executive Built-in	1
25-May	1207	Executive Built-in	1
25-May	1215	Executive Built-in	1
25-May	1216	Executive Built-in	1
25-May	1217	Executive Built-in	1
25-May	1236	Executive Built-in	1
25-May	1237	Executive Built-in	1
25-May	1239	Executive Built-in	1
25-May	1240	Executive Built-in	1
25-May	1245	Executive Built-in	1
25-May	1246	Executive Built-in	1
25-May	1247	Executive Built-in	1
25-May	1248	Executive Built-in	1
25-May	1249	Executive Built-in	1
25-May	1250	Executive Built-in	1
25-May	as part of set up of all offices that remain	3 Draw& Pedistal Wood	17
25-May		Keyboard Tray	36
25-May	1266 (current plan)	Grey Shelves	11
25-May		Reception Desk	1
25-May		Task Chair (desk)	35
25-May	1259 (current plan}	Refridgerator	2
25-May	1259 (current plan)	Microwave	1
25-May Lunch Room		Purple Arm Chair	5
25-May Lunch Room		Bar Chair	5
25-May Lunch Room		Silver Round Table	3
25-May Lunch Room		Refrigerator	2
25-May Lunch Room		Microwave	2

Exhibit F-1

EXHIBIT F-3

225 WEST SANTA XXXXX

FORM OF LETTER OF CREDIT



		[Name of Financial Institution]


Irrevocable Standby
Letter of Credit
No.


Issuance Date:


Expiration Date:


Applicant:

Beneficiary

[Insert Name of Landlord]

[Insert Building management office address]

Ladies/Gentlemen:

We hereby establish our Irrevocable Standby Letter of Credit in your favor for the account of the above referenced Applicant in the amount of U.S. Dollars ($ ) available for payment at sight by your draft drawn on us when accompanied by the following documents:

1.	An original copy of this Irrevocable Standby Letter of Credit.

Beneficiary’s dated statement purportedly signed by an authorized signatory or agent reading: “This draw in the amount of U.S. Dollars ($ ) under your Irrevocable Standby Letter of Credit No. represents funds due and owing to us pursuant to the terms of that certain lease by and between as landlord, and , as tenant, and/or any amendment to the lease or any other agreement between such parties related to the lease.”

It is a condition of this Irrevocable Standby Letter of Credit that it will be considered automatically renewed for a one year period upon the expiration date set forth above and upon each anniversary of such date, unless at least 60 days prior to such expiration date or applicable anniversary thereof, we notify you in writing, by certified mail return receipt requested or by recognized overnight courier service, that we elect not to so renew this Irrevocable Standby Letter of Credit. A copy of any such notice shall also be sent, in the same manner, to: Equity Office, 0 Xxxxx Xxxxxxxxx Xxxxx, Xxxxx 0000, Xxxxxxx, Xxxxxxxx 00000, Attention: Treasury Department. In addition to the foregoing, we understand and agree that you shall be entitled to draw upon this Irrevocable Standby Letter of Credit in accordance with 1 and 2 above in the event that we elect not to renew this Irrevocable Standby Letter of Credit and, in addition, you provide us with a dated statement purportedly signed by an authorized signatory or agent of Beneficiary stating that the Applicant has failed to provide you with an acceptable substitute irrevocable standby letter of credit in accordance with the terms of the above referenced lease. We further acknowledge and agree that: (a) upon receipt of the documentation required herein, we will honor your draws against this Irrevocable Standby Letter of Credit without inquiry into the accuracy of Beneficiary’s signed statement and regardless of whether Applicant disputes the content of such statement; (b) this Irrevocable Standby Letter of Credit shall permit partial draws and, in the event you elect to draw upon less than the full stated amount hereof, the stated amount of this Irrevocable Standby Letter of Credit shall be automatically reduced by the amount of such partial draw; and (c) you shall be entitled to transfer your interest in this Irrevocable Standby Letter of Credit from time to time and more than one time without our approval and without charge. In the event of a transfer, we reserve the right to require reasonable evidence of such transfer as a condition to any draw hereunder.

Exhibit F-3

This Irrevocable Standby Letter of Credit is subject to the International Standby Practices (ISP98) ICC Publication No. 590.

We hereby engage with you to honor drafts and documents drawn under and in compliance with the terms of this Irrevocable Standby Letter of Credit.

All communications to us with respect to this Irrevocable Standby Letter of Credit must be addressed to our office located at to the attention of .


Very truly yours,



[name]

[title]

Exhibit F-3

Document Metadata

Table of Contents

OFFICE LEASE

Document Metadata