Exhibit 10.8
GENERATION FACILITY
TRANSMISSION INTERCONNECTION AGREEMENT
BETWEEN
JERSEY CENTRAL POWER & LIGHT COMPANY
d/b/a GPU ENERGY
AND
AES RED OAK, L.L.C.
TABLE OF CONTENTS
PAGE
----
ARTICLE 1: DEFINITIONS........................................................2
ARTICLE 2: EFFECTIVE DATE AND TERM............................................8
ARTICLE 3: RESPONSIBILITIES OF THE COMPANY...................................10
ARTICLE 4: RESPONSIBILITIES OF THE POWER PRODUCER............................11
ARTICLE 5: MODIFICATIONS TO FACILITIES, INTERCONNECTIONS.....................14
ARTICLE 6: OPERATION.........................................................17
ARTICLE 7: MAINTENANCE NOTIFICATION AND COORDINATION.........................18
ARTICLE 8: REVENUE METERING..................................................20
ARTICLE 9: LAND RIGHTS AND ACCESS............................................23
ARTICLE 10: INSURANCE.........................................................23
ARTICLE 11: PERFORMANCE.......................................................26
ARTICLE 12: LIABILITY AND DEDICATION..........................................27
ARTICLE 13: INDEMNIFICATION...................................................29
ARTICLE 14: REPRESENTATIONS, WARRANTIES AND COVENANTS.........................32
ARTICLE 15: EVENTS OF DEFAULT.................................................33
ARTICLE 16: ASSIGNMENT........................................................37
ARTICLE 17: NOTICES...........................................................38
ARTICLE 18: AMENDMENT AND MODIFICATION........................................39
ARTICLE 19: DISPUTES..........................................................39
ARTICLE 20: MISCELLANEOUS.....................................................40
APPENDIX A - DESCRIPTION OF FACILITY
APPENDIX B - INTERCONNECTION FACILITIES
APPENDIX C - TRANSMISSION OPERATION INTERCONNECTION REQUIREMENTS
APPENDIX D - SYSTEM PROTECTION AND CONTROL INTERCONNECTION REQUIREMENTS
APPENDIX E - INTERCONNECTION INSTALLATION AGREEMENT
GENERATION FACILITY
TRANSMISSION INTERCONNECTION AGREEMENT
THIS AGREEMENT, made and entered into this 27th day of April, 1999,
by and between Jersey Central Power & Light Company d/b/a GPU Energy
("Company"), a corporation and a public utility organized and existing under the
laws of the State of New Jersey, and AES Red Oak, L.L.C., an entity organized
and existing under the laws of the State of Delaware ("Power Producer"), both
Company and Power Producer hereinafter sometimes referred to collectively as the
"Parties", or individually as a "Party". The Parties acknowledge that GPU
Service, Inc., shall act as agent for the Company concerning the administration
of this Agreement.
RECITALS
WHEREAS, the Company is a public utility engaged in the production,
transmission, distribution and sale of electric energy; and
WHEREAS, the Company is a member of the PJM Interconnection, L.L.C.
("PJM") operated under the PJM Agreement; and
WHEREAS, the Company is a member of the Mid-Atlantic Area Council
("MAAC"), a reliability council under Section 202 of the Federal Power Act
established pursuant to the Mid-Atlantic Coordination Agreement, dated December
26, 1967, and as amended and restated as of August 1, 1994 by the MAAC Executive
Board, and as may be further amended from time to time thereafter; and
WHEREAS, the Power Producer is an entity engaged or intending to be
engaged in
1
the production and sale of electric energy and/or capacity from an electric
power generation facility to be located in the State of New Jersey, and more
fully described in Appendix A; and
WHEREAS, in order for the Power Producer to sell electric energy
and capacity generated from the Facility, it must be interconnected with the
Transmission System; and
WHEREAS, the Parties are willing to enter into this agreement under
which the Facility will be interconnected with the Transmission System, subject
to terms and conditions hereinafter set forth.
NOW, THEREFORE, in consideration of the mutual representations,
covenants, promises, and agreements hereinafter set forth, the Parties hereto,
intending to be legally bound, hereby covenant, promise and agree as follows:
ARTICLE 1
DEFINITIONS
1.1 Any capitalized or abbreviated term not elsewhere defined in this
Agreement shall have the definition set forth below:
(a) Affiliate - With respect to a corporation, partnership or other
entity, each such other corporation, partnership or other entity that directly
or indirectly, through one or more intermediaries, controls, is controlled by,
or is under common control with, such corporation, partnership or other entity.
(b) Agreement - This Generation Facility Transmission
Interconnection Agreement including all appendices attached hereto, and all
amendments and supplements.
(c) BPU - The New Jersey Board of Public Utilities or any successor
agency thereto.
2
(d) Capacity - The maximum generating capability of the Facility,
measured in megawatts at a defined ambient air temperature, as set forth in
Appendix A.
(e) Company Interconnection Facilities - All structures,
facilities, equipment, devices and apparatus owned or leased by, or under
contract to, the Company or its Affiliates, as identified in Appendix B, which
facilities are necessary, together with the Power Producer Interconnection
Facilities, to allow the interconnection of the Facility to the Transmission
System.
(f) Emergency - A condition or situation which the PJM OI, the
Company or the Power Producer deem imminently likely to (i) endanger life or
property; (ii) adversely affect or impair the Transmission System, or imminently
will affect or impair, the Company's electrical system or the electrical or
transmission systems of others to which the Company's electrical system is
directly or indirectly connected; or (iii) adversely affect or impair the
Facility. Such a condition or situation includes, but is not limited to,
overloading or potential overloading of or excessive voltage drop on the
Company's or regional transmission and/or distribution circuits, unusual
operating conditions on either the Company's, regional or the Power Producer's
electrical system or conditions such that the output of the Power Producer's
Facility must be adjusted to avoid jeopardizing the Facility, the Company's
electrical system or the electrical systems of others to which the Company's
electrical system is directly or indirectly connected.
(g) Facility - The real and personal property owned by the Power
Producer at the electric power generating facility including, but not limited
to, the following assets: (a) the real property (including all buildings,
structures and other improvements thereon); (b) the turbines
3
machinery, equipment, vehicles, furniture, and other personal property located
on the Power Producer's property, and shall include any additions, modifications
or replacements thereto, as further defined in Appendix A.
(h) FERC - The Federal Energy Regulatory Commission or any
successor agency thereto.
(i) Force Majeure - Shall mean an event or occurrence or
circumstance beyond the reasonable control of and without the fault or
negligence of the Party claiming Force Majeure, including, but not limited to,
acts of God, labor dispute (including strike), acts of public enemy, war, civil
disturbance, riot, fire, storm, flood, explosion, earthquake, lightning,
epidemic, sabotage, breakage or accident to machinery or equipment, electric
system disturbance, change in law or applicable regulation subsequent to the
date hereof and action or inaction by any federal, state or local legislative,
executive, administrative, military, or judicial agency or body which, in any of
the foregoing cases, by exercise of due foresight such Party could not
reasonably have been expected to avoid, and which, by the exercise of due
diligence, is unable to overcome, and which wholly or in substantial part
prevents such Party from performing its obligations under this Agreement. The
settlement of strikes and labor disturbances shall be wholly within the
discretion of the Party experiencing the event. Economic hardship of either
Party shall not constitute a Force Majeure under this Agreement.
(j) Generator Forced Outage - Shall have the meaning given that
term in the PJM Agreement.
(k) Generator Maintenance Outage - Shall have the meaning given
that term in the
4
PJM Agreement.
(l) Generator Planned Outage - Shall have the meaning given that
term in the PJM Agreement.
(m) Good Utility Practice - (i) Any of those practices, methods and
acts engaged in or approved by a significant portion of the electric utility
industry in North America during the relevant time period, or any of the
practices, methods and acts which, in the exercise of reasonable judgment in
light of the facts known at the time the decision was made, could have been
expected to accomplish the desired result at a reasonable cost consistent with
good business practices, reliability, safety and expedition; and (ii) any of
those practices, methods, standards and equipment commonly used, from time to
time, in electrical engineering and operations to operate electrical equipment
lawfully and with safety, dependability and efficiency and in accordance with
the National Electrical Safety Code and the National Electrical Code and
Standards of the Institute of Electrical and Electronic Engineers, and standards
established by the National Electrical Manufacturers Association, the PJM OI,
the Mid-Atlantic Area Council ("MAAC"), the American National Standards
Institute and any such other standards practiced by the industry and electrical
equipment manufacturers in North America in a manner sufficient to provide safe
and reliable service. Good Utility Practice is not intended to be limited to the
optimum practice, method, or act to the exclusion of all others, but rather to
be acceptable practices, methods or acts generally accepted and consistently
adhered to in the MAAC region.
(n) Interconnection Facilities - The Company Interconnection
Facilities and the Power Producer Interconnection Facilities, together.
5
(o) Lenders - Those entities, including their successors and
assigns and any trustee or agent acting on their behalf, who have advanced or
who will advance to the Power Producer, directly or indirectly, the economic
resources (whether on a senior or unsubordinated basis) for the development and
construction of the Facility or the Interconnection Facilities. The Power
Producer shall notify the Company of the name and addresses of the Lenders for
the purposes of this Agreement.
(p) NERC - The North American Electric Reliability Council or any
successor thereto.
(q) PJM Agreement - Shall mean the Amended and Restated Operating
Agreement of PJM Interconnection, L.L.C., dated as of June 2, 1997, and revised
as of December 31, 1997, January 30, 1998, and March 17, 1998, and as may be
further amended or superseded from time to time.
(r) PJM Control Area - The control area recognized by NERC as the
PJM Control Area.
(s) PJM Interconnection, L.L.C. - The entity formerly known as the
PJM Interconnection Association, converted into a limited liability company
pursuant to the Delaware Limited Liability Company Act, Title 6, Sections 18-101
et seq. of the Delaware Code, by virtue of the filing of both the Certificate of
Formation and Certificate of Conversion with the Recording Office, effective as
of March 31, 1997. The L.L.C. operates in accordance with the FERC requirements
as an Independent System Operator, comprised of the PJM Board, the PJM OI, and
the PJM Members Committee.
6
(t) PJM OI - The Office of the Interconnection as supervised by the
Board of Managers of the PJM Interconnection, L.L.C., acting pursuant to the PJM
Agreement. The PJM OI has the responsibility for the continued operation of the
PJM Control Area and the administration of the PJM Tariff, subject to regulation
by the FERC.
(u) PJM Tariff - The PJM Open Access Transmission Tariff filed by
the PJM Interconnection L.L.C. with FERC on July 14, 1997, in Docket
No. OA97-261-000 as amended and effective April 1, 1998, and as may be further
modified, amended or superseded from time to time, under which transmission
service is provided within the PJM Control Area.
(v) Point of Interconnection - Each ownership point of demarcation
on the Transmission System where capacity, energy, and ancillary services each
are transferred between the Facility and the Transmission System. The Point of
Interconnection shall be located as shown on the interconnection one line
diagram attached hereto as Appendix A.
(w) Power Producer Interconnection Facilities - All structures,
facilities, equipment, devices and apparatus owned or controlled by Power
Producer, as identified in Appendix B, and as may be amended from time to time.
(x) Protective Apparatus - All equipment and apparatus included in
the Interconnection Facilities, including but not limited to protective relays,
circuit breakers and the like, as set forth in Appendix B, necessary to isolate
the Facility from the Company's electrical system consistent with Good Utility
Practice.
(y) Revenue Meters - All MWh, MVARh meters, pulse isolation relays,
pulse conversion relays and transducers used by the PJM OI or the Company for
billing purposes, and
7
associated totalizing equipment and appurtenances (including voltage
transformers and current transformers) used to measure the transfer of energy
and the applicable ancillary services between the Parties.
(z) Transmission System - The electric transmission facilities
owned, controlled, or operated by the Company at or above 34.5 kV delta for
purposes of providing transmission service, including services under the PJM
Tariff and the PJM Agreement.
1.2 Unless a different interpretation arises from the context: (a) the
reference to any article, section, paragraph or appendix is a reference to an
article, section, paragraph or appendix of this Agreement, (b) with respect to
the definitions set forth in Article 1, whenever applicable the singular shall
include the plural and vice-versa; and (c) the words "includes" or "including"
mean "including, but not limited to" and are not limiting. Any conflict between
an article or section of the Agreement and any provision of an appendix shall be
resolved by reference to the article or section of this Agreement.
ARTICLE 2
EFFECTIVE DATE AND TERM
2.1 This Agreement shall become effective on the effective date
established by the FERC, and shall continue in full force and effect until a
mutually agreeable termination date not to exceed the retirement date for the
Facility, unless terminated on an earlier date by mutual agreement of the
Parties or otherwise in accordance with the terms set forth in this Agreement.
2.2 The applicable provisions of this Agreement shall continue in
effect after cancellation or termination hereof to the extent necessary to
provide for final xxxxxxxx, billing adjustments, and
8
the determination and enforcement of liability and indemnification obligations
arising from acts or events that occurred while this Agreement was in effect.
2.3 In the event that the FERC (i) fails to accept this Agreement
without suspension or (ii) finds that this Agreement is not just and reasonable
or imposes conditions that are not acceptable to either Party, the Parties will
use commercially reasonable efforts to agree upon amendments or modifications of
this Agreement that would eliminate any such condition or result in a just and
reasonable finding by the FERC. If the Parties are unable to mutually agree upon
such amendment or modification within a reasonable period of time, the Parties
agree to proceed pursuant to Article 19 in order to attempt to resolve any
impasse or dispute.
2.4 In the event that this Agreement is terminated the Power Producer
agrees that it will reimburse the Company for all unpaid costs and expenses
expended by the Company in the installation of the Company's Interconnection
Facilities, up to the date of termination, plus actual removal costs and less
actual salvage value. The Company agrees not to order any equipment or to incur
any significant expenditure on Power Producer's behalf prior to receiving a
"notice to proceed" from the Power Producer. The Power Producer shall deliver
the "notice to proceed" in accordance with Article 17 hereof.
2.5 In the event of a changing law or regulation or the issuance of an
order or other directive by a regulatory authority with jurisdiction over either
Party that affects or may reasonably be expected to affect either Party's
performance under this Agreement, the Parties will negotiate in good faith any
amendment or amendments to this Agreement necessary to adapt the terms of this
Agreement to such change, order, or directive provided that the Parties are not
9
obligated to agree to such amendment which may adversely affect their current
economic positions as of the effective date of this Agreement. In the event that
the Parties are unable to mutually agree to such an amendment within a
reasonable time period, the Parties agree to proceed pursuant to Article 19 in
order to attempt to resolve any impasse or dispute. Nothing in this Agreement
shall limit the rights of the parties or the FERC under Section 205 or 206 of
the Federal Power Act and FERC's Rules and Regulations thereunder.
ARTICLE 3
RESPONSIBILITIES OF THE COMPANY
3.1 The Company shall:
(a) Install all Company Interconnection Facilities at the Power
Producer's sole cost and expense in accordance with the terms and conditions and
the schedule set forth in Appendix E which is attached hereto and made a part
hereof. Payment of such costs and expenses shall be in accordance with the
schedule set forth in Appendix E hereof. The Company shall use reasonable
efforts to install all Company Interconnection Facilities within the estimated
costs set forth in Appendix E and shall inform the Power Producer of the amount
and reason for any increase in such estimated cost promptly after Company learns
of such cost increase.
If the Company is materially delayed in meeting the milestone dates
set forth in Appendix E hereof for any reason, excluding an event of Force
Majeure, the Company, following its receipt of the Power Producer's demand for
adequate assurance, shall promptly take all reasonable steps necessary to
rectify the delay condition
(b) Own, maintain, and operate Company Interconnection Facilities.
The Power
10
Producer shall reimburse the Company for all actual and verifiable costs and
expenses including, but not limited to, overheads and applicable taxes, directly
associated with the maintenance and operation of the Company Interconnection
Facilities.
(c) Operate and maintain all Company Interconnection Facilities and
the Transmission System as part of the single PJM Control Area in accordance
with the provisions of the PJM Agreement and PJM Tariff, using due diligence, in
accordance with Good Utility Practice.
(d) Provide to the Power Producer all design specifications and
equipment characteristics for the interconnection of the Facility with the
Transmission System.
(e) Maintain in full force and effect at the Power Producer's sole
cost and expense all permits, licenses, rights of way and other authorizations
as may be required to maintain and operate the Company Interconnection
Facilities.
(f) Upon the expiration of the Agreement and retirement of the
Facility, remove all Company Interconnection Facilities at the Power Producer's
sole cost and expense less salvage value.
3.2 Unless otherwise required by law, regulation, or Good Utility
Practice, the Company shall not be required at any time, at its expense or
otherwise, to upgrade or otherwise modify the Transmission System in order to
accommodate the interconnection of the Facility with the Transmission System.
3.3 The Company does not guarantee the non-occurrence of, or warrant
against, and the Power Producer releases the Company from, any claims or damages
associated with: (a) any interruption in the availability of Company
Interconnection Facilities or the Transmission
11
System; or (b) damage to the Facility resulting from electrical transients
including, without limitation, short circuits (faults), solar magnetic
disturbances, or events of Force Majeure, except to the extent caused by the
Company's gross negligence or willful misconduct.
ARTICLE 4
RESPONSIBILITIES OF THE POWER PRODUCER
4.1 The Power Producer shall:
(a) Own, maintain and operate the Power Producer Interconnection
Facilities and Protective Apparatus at its sole cost and expense.
(b) Maintain in full force and effect at its sole cost and expense
all permits, licenses, rights of way and other authorizations as may be required
to maintain and operate the Power Producer Interconnection Facilities and
Protective Apparatus unless otherwise required by law or regulation.
(c) Install, at its sole cost and expense, any and all equipment in
order to maintain the reliability of the Facility and all Interconnection
Facilities.
(d) Subject to any right of the Power Producer, or any entity
purchasing the output of the Facility, to schedule and sell ancillary services
under the PJM Agreement or the PJM Tariff, operate the Facility in accordance
with the appropriate voltage schedules and/or reactive schedules developed as
specified in Appendix C. Subject to the foregoing, if the Power Producer fails
to operate the Facility in accordance with Appendix C, the Company will provide
written notice to the Power Producer of the Company's intent to remedy that
failure. If the Power Producer does not promptly commence appropriate action
after receiving such notice, the
12
Company may then take necessary action at the Power Producer's expense to remedy
such failure, including the installation of capacitor banks or other reactive
compensation equipment necessary to ensure the proper voltage or reactive supply
at the Facility. The Company shall take, to the extent feasible, reasonable
efforts to minimize the impact of such action, in accordance with Good Utility
Practice on the operation of the Facility.
(e) Make or assure that all necessary arrangements have been made
under the applicable tariffs for transmission service (i.e., from the Point of
Interconnection to Power Producer's load serving or end use customers), losses,
and ancillary services associated with the delivery of the capacity and/or
energy produced by the Facility, which services shall not be provided under this
Agreement.
(f) Obtain capacity and/or energy for the purpose of satisfying the
Facility station service requirements or for any other uses by the Power
Producer.
(g) Make or assure that all necessary arrangements have been made
under the applicable tariffs for transmission service, losses, and ancillary
services associated with the use of the Transmission System for the delivery of
capacity and/or energy to the Facility for the purpose of supplying generation
station service or for any other service which is available and/or required
under the PJM Tariff or any retail wheeling tariff, including any distribution
service tariff or contract, in each case as may be amended from time to time.
(h) Operate, install and maintain at its sole cost and expense all
equipment required to control the Facility in accordance with Section 6.1.
(i) Maintain or cause to be maintained such records relating to the
Power Producer
13
Interconnection Facilities as may be required by Good Utility Practice or
applicable law.
4.2 The Power Producer acknowledges that this Agreement does not
encompass transmission service for the output of the Facility under the PJM
Tariff and that, to the extent the Company is required under the PJM Tariff or
the PJM Agreement, including any direction of the PJM OI pursuant thereto, to
upgrade, reinforce or otherwise modify its Transmission System (other than the
installation of the Company Interconnection Facilities) to provide such
transmission service on behalf of the Power Producer, the Power Producer will be
responsible for the costs of such upgrades, reinforcements or modifications in
accordance with the terms of the PJM Tariff, the PJM Agreement or any other
applicable PJM agreements.
ARTICLE 5
MODIFICATIONS TO FACILITIES, INTERCONNECTIONS
5.1 In the event the Power Producer plans additions, modifications or
replacements to the Facility, Power Producer Interconnection Facilities or
Protective Apparatus that will increase the Capacity of the Facility, the Power
Producer shall submit to the Company any and all plans and specifications that
the Company may reasonably request related to such additions, modifications or
replacements. Such specifications and plans shall be submitted by the Power
Producer not later than eighteen (18) months prior to the respective commercial
operation date for additions, modifications, or replacements to the Facility,
except as otherwise agreed to by the Company. Any such additions, modifications,
or replacements shall comply with the criteria imposed by the PJM OI, the MAAC
Reliability Principles and Standards, Good Utility Practice, and the criteria
included in Appendix C and Appendix D.
5.2 If the Power Producer plans any additions, modifications or
replacements to the
14
Facility, Power Producer Interconnection Facilities or Protective Apparatus that
in the Company's view will not increase the amount of Capacity to be delivered
to the Company's electrical system, but could reasonably be expected to affect
the Transmission System, the Company Interconnection Facilities, the operation
of the Facility, the availability of Capacity and/or the delivery of electric
energy and capacity from the Facility, the Power Producer shall give the Company
reasonable notice, but not less than sixty (60) days prior written notice
thereof; PROVIDED, however, that the Power Producer shall provide the Company
with at least nine (9) months prior written notice, and shall submit to the
Company any and all plans and specifications which the Company may reasonably
request related to such additions, modifications or replacements which involves
Power Producer Interconnection Facilities or which the Power Producer
anticipates will result in an outage of the Facility for thirty (30) days or
more. All such additions, modifications, or replacements shall: (a) comply with
the criteria imposed by the PJM OI, the PJM Agreement, the MAAC Reliability
Principles and Standards, Good Utility Practice, and the criteria included in
Appendix C and Appendix D; (b) be accompanied by appropriate information and
operating instructions; and (c) be subject to review and approval of the
Company, which review shall be based on Good Utility Practice. Failure by the
Company to object to any such proposed addition, modification or replacement
within thirty (30) days and, in the case of the proviso to the first sentence of
this Section, ninety (90) days following the Company's receipt of notice thereof
shall be deemed acceptance thereof by the Company.
5.3 The Company shall inform the Power Producer of any additions,
modifications, or
15
replacements to the Transmission System or the Company Interconnection
Facilities that are necessary as a result of the addition, modification, or
replacement to the Facility made pursuant to Sections 5.1 or 5.2. The Power
Producer shall reimburse the Company for all costs incurred by the Company
associated with any modifications, additions, or replacements made to the
Company Interconnection Facilities or the Transmission System related to any
proposed additions, modifications, or replacements of the Facility to the extent
reasonably required by the Company including, but not limited to those necessary
to meet different voltage requirements of the Transmission System or to enhance
the Transmission System, regardless of whether the expanded Facility enters into
(or has entered into) service or is interconnected with the Transmission System.
The Company shall provide an estimate as early as practicable.
5.4 The Company's acceptance of the Power Producer's interconnection
plans and specifications for any proposed additions, modifications, or
replacement of the Power Producer's Facility whether pursuant to this Agreement
and the Company's participation in interconnected operations with the Power
Producer are not, and shall not be construed as its: (a) confirmation or
endorsement of the design of the Facility, Power Producer Interconnection
Facilities or Protective Apparatus; (b) warranty of safety, durability or
reliability of the Facility or equipment appurtenant thereto; (c) assumption of
responsibility for strength, details of design, adequacy, or capability of the
Facility, Power Producer Interconnection Facilities or Protective Apparatus; or
(d) endorsement or warranty.
5.5 The Power Producer shall modify, at its sole cost and expense (only
to the extent responsibility for such costs and expenses are not allocated to
the Company or a third party
16
consistent with FERC policy), the Interconnection Facilities and/or Protective
Apparatus as may be reasonably required to conform with changes to Good Utility
Practice or to conform with additions, modifications, or replacements required
by PJM Interconnection L.L.C.
5.6 The Power Producer shall compensate the Company for all reasonable
costs and fees required to enable the Company to fulfill its obligations under
this Agreement including any tax liability, any costs of acquiring land
necessary for the Interconnection Facilities, the costs and fees of all permits,
licenses, franchises or regulatory or other approvals necessary for the
construction, maintenance and operation of any Interconnection Facilities.
5.7 The Company may undertake additions, modifications, or replacements
of its Transmission System or Company Interconnection Facilities. If such
additions, modifications, or replacements might reasonably be expected to affect
the Power Producer's operation of the Facility, the Company shall provide
written notice to the Power Producer in a manner consistent with FERC Order No.
889 prior to undertaking such additions, modifications, or replacements. Any
such additions, modifications, or replacements shall comply with Good Utility
Practice. The Company shall use reasonable efforts with respect to such
addition, modification, or replacement to minimize any adverse impact on the
Facility.
ARTICLE 6
OPERATION
6.1 The Facility, all Interconnection Facilities and Protective
Apparatus shall be operated and maintained in accordance with Good Utility
Practice, including, without limitation, those with regard to synchronization,
voltage and reactive power control, and in compliance with all
17
permits, licenses, laws, rules and regulations applicable thereto. Operation and
maintenance of the Facility and all Interconnection Facilities shall at all
times conform to applicable requirements and guidelines adopted by the PJM OI
and the Company as set forth in Appendix C and Appendix D, and modified by the
PJM OI and/or the Company respectively from time to time.
6.2 The Power Producer shall be required to comply with the requests,
orders, and directives of the Company to the extent such requests, orders or
directives are (a) necessary to comply with Good Utility Practice, and (b) in
accordance with applicable tariffs and the PJM Agreement.
6.3 In the event the Power Producer believes that a request, order, or
directive of the Company exceeds the limitations in Section 6.2, it shall
nevertheless comply with the request, order, or directive of the Company pending
resolution of the dispute under Article 19. The Parties agree to cooperate in
good faith to expedite the resolution of any disputes arising under Sections 6.2
and 6.3.
6.4 If it appears to the Company at any time, in the reasonable
exercise of its judgment in accordance with Good Utility Practice, that the
operation of the Facility or any Interconnection Facility is adversely affecting
or may adversely affect the quality of service rendered by the Company
(including transmission or distribution services and services provided to end
users), or is interfering or may interfere with the safe and reliable operation
of the Transmission System or the regional transmission system, the Company may,
upon such notice specified below, disconnect the Facility from the Transmission
System and/or curtail, interrupt, or reduce energy
18
deliveries from the Facility until the condition has been corrected. In the
event of an Emergency, the Company may immediately take any and all steps it
reasonably believes to be necessary to mitigate or cure the Emergency condition
including, without limitation, disconnecting the Facility from the Transmission
System. The Company shall use reasonable efforts to (i) minimize, to the extent
practicable under the circumstances, any such disconnection, curtailment,
interruption, or reduction, (ii) provide the Power Producer with prior
notification of any such disconnection, curtailment, interruption, or reduction,
to the extent practicable, (iii) resume acceptance of electric energy as
promptly as practicable following elimination of the condition causing the
disconnection, curtailment, interruption, or reduction, and (iv) confer with the
Power Producer regarding the interfering conditions that gave rise to the
disconnection, curtailment, or reduction.
ARTICLE 7
MAINTENANCE NOTIFICATION AND COORDINATION
7.1 The Power Producer shall maintain, at its own expense, the Power
Producer Interconnection Facilities and Protective Apparatus. The Company shall
maintain the Company Interconnection Facilities. The Power Producer shall
reimburse the Company for all actual and verifiable costs and expenses
including, but not limited to, overheads and applicable taxes directly
associated with the maintenance and operation of the Company Interconnection
Facilities.
7.2 In accordance with Good Utility Practice, the Company may remove
the Interconnection Facilities from service as necessary, in the reasonable
exercise of the Company's
19
judgment, to perform maintenance or testing or to install or replace equipment
on the Company Interconnection Facilities or the Transmission System. Unless an
Emergency exists or the risk of one in the Company's view is imminent, the
Company shall, if practical, give the Power Producer prior notice of the
removal. The Company shall use due diligence to restore the Interconnection
Facilities to service as promptly as practicable.
7.3 If the Company determines, in its sole judgment, that the Power
Producer is maintaining the Power Producer's Interconnection Facilities and
Protective Apparatus in a manner which may lead to an Emergency condition, the
Power Producer, within thirty (30) days of notification thereof from the
Company, shall take all reasonable steps to conform its maintenance practices to
the requirements of Good Utility Practice and this Agreement.
7.4 At any reasonable time upon advance notice, each Party shall permit
the representatives of the other Party access to the records for its
interconnection facilities in order to examine, inspect and test such records.
In the event of an Emergency, the Power Producer shall ensure that Company
representatives have immediate and unimpeded access to the Power Producer
Interconnection Facilities as necessary to address the Emergency in accordance
with Good Utility Practice working with the Power Producer. The Power Producer
hereby grants to the Company the right to enter upon the Power Producer's
property for such purposes.
ARTICLE 8
REVENUE METERING
8.1 The Company shall utilize Revenue Meters to measure the electrical
energy on an hour-by-hour basis, or such shorter intervals as may be agreed
upon, at the Point of
20
Interconnection in order to determine the transfer of energy between the
Parties.
8.2 All Revenue Meters shall be of advanced meter design that have an
internal recorder and a communications capability that the Company can utilize
to retrieve diagnostic messages, the recorded transfer of energy between the
Parties, and any other information deemed necessary by the Company. The Power
Producer may, at its sole cost and expense, install telemetering or other
communications equipment to retrieve such information as is deemed necessary by
the Power Producer.
8.3 The Parties shall agree that, if the Revenue Meters and analog
equipment and the Point of Interconnection are not at the same location
electrically, the metering data shall be adjusted, or the Revenue Meters shall
be compensated, as the Company shall deem appropriate, to record delivery of
electricity in a manner that accounts for the total (load plus no-load)
electrical energy losses occurring between the metering point and the Point of
Interconnection, both when the Power Producer is delivering energy to the
Company and when the Company is delivering station service energy to the
Facility, or for any other use.
8.4 In the event that the Company's Revenue Meters at any time fail to
register, or should their registration be so erratic so as to be meaningless,
the hourly energy transferred between the Parties shall be determined from the
best information available, including, but not limited to, the Power Producer's
meters, operator's logs and real-time communications data of the meter results.
8.5 If at any time, any Revenue Meters and analog equipment is found to
be inaccurate by a margin greater than that allowed under the applicable
criteria, rules, and standards, the Company shall cause the Revenue Meters and
analog equipment to be made accurate or replaced
21
at the Power Producer's expense. Meter readings for the period of inaccuracy
shall be adjusted insofar as the extent of the inaccuracy can be reasonably
ascertained; provided, however, no adjustment shall be made for meter readings
made prior to the point in time halfway between the time of the last test that
showed the Revenue Meters and analog equipment in question to be functioning
accurately and the time the subsequent inaccuracy is corrected, except by
agreement of the Parties.
8.6 The Company shall read and report Revenue Meter data to the Power
Producer. The Power Producer shall have the right to read the Revenue Meters
upon reasonable notice to the Company.
8.7 The Parties shall each keep and maintain accurate and detailed
records relating to the Revenue Meters for a period of not less than seven (7)
years. Such records shall be made available for inspection by either Party or
any governmental agency having jurisdiction with respect thereto during normal
business hours upon reasonable notice.
8.8 The Company shall at the Power Producer's expense (i) install, own,
maintain, and repair and have the right to change the location of all Revenue
Meters, instrument transformers and appurtenances associated with the Revenue
Meters, and analog equipment (transducers and telemetry) and (ii) install, own,
maintain, and repair all additional or updated metering and associated
equipment, as mutually agreed upon by the Parties, needed to update its metering
facilities, in accordance with Good Utility Practice.
8.9 The Company shall, at the Power Producer's expense, test all
Revenue Meters and analog equipment at such time as Company deems reasonably
necessary in accordance with all
22
applicable regulatory requirements or standards. However, all Revenue Meters and
analog equipment shall be tested at least once every two (2) years.
8.10 Upon written request by the Power Producer, the Company shall test
designated Revenue Meters and analog equipment more frequently than once every
two (2) years. In the event a test requested by the Power Producer establishes
such Revenue Meters to be registering inaccurately by more than one (1%) percent
of full scale, the cost of said test shall be borne by the Company. In all other
instances, the cost of any such test, regardless of which Party requests it or
the results thereof, shall be paid by the Power Producer.
8.11 The Company shall give reasonable notice to the Power Producer of
the time when any Revenue Meters and analog equipment test shall take place, and
the Power Producer may have representatives present at said test. Any Revenue
Meters found to be inaccurate by more than one (1%) percent of full scale or
defective shall be adjusted, repaired or replaced, at the sole cost and expense
of the Power Producer.
8.12 The Company shall install, own, and maintain, at the Power
Producer's expense, equipment, except for associated telephone link(s) which
shall be the sole responsibility of the Power Producer, for real-time
communications, real-time reactive power, hourly MWh information, interval
revenue data and such other information as the Company or the PJM OI may
require. The Power Producer shall install, operate, maintain and repair, at its
own expense, an operating telephone link(s) to provide information deemed
necessary by the Company or the PJM OI, or as reasonably deemed necessary by the
Company, to integrate operation of the Facility with the Transmission System.
23
ARTICLE 9
LAND RIGHTS AND ACCESS
9.1 The Power Producer hereby grants, or confirms its prior grant to
the Company, for nominal consideration, all necessary rights of way, easements,
and licenses as the Company may require to install, operate, maintain, replace
and remove the Company's metering equipment and other Company Interconnection
Facilities, including adequate and continuing access rights to the Power
Producer's property for any purpose reasonably related to this Agreement. The
Power Producer hereby agrees to execute such grants, deeds, licenses,
instruments and other documents as the Company may require to enable it to
record such rights of way, easements and licenses.
ARTICLE 10
INSURANCE
10.1 The Power Producer shall keep the Facility continuously insured
against loss or damage in amounts and for risks that property of similar
character is usually so insured by entities owning and operating like
properties.
10.2 The Power Producer, the operator of the Facility, and their
respective successors and assigns shall procure or cause to be procured and
shall maintain in effect continuously during the term of the Agreement the
following minimum insurance coverages:
TYPE OF COVERAGE LIABILITY LIMITS
---------------- ----------------
Worker's Compensation Statutory
24
Employer's Liability $500,000 per occurrence/injury
Comprehensive/General $1,000,000 combined single limit,
Liability including: each occurrence
$2,000,000 aggregate limit
applicable for the Facility
Bodily Injury
Property Damage
Blanket Contractual
Underground Explosion and Collapse Hazard
Products and Completed Operations Hazard
Broad Form Property Damage
Personal Injury
Automobile Liability
(Owned, Hired, Non-Owned)
Bodily Injury $1,000,000 combined single limit
Property Damage
Commercial Umbrella Liability $9,000,000 per occurrence
following form of
Commercial General Liability,
Automobile Liability and
Employers Liability
10.3 In order to meet changed circumstances or changes in industry
practice in a manner consistent with the requirements of Section 10.1, the
Company may notify the Power Producer of a proposed change to the types of
coverage or the liability limits set forth in Section 10.2. The Parties agree to
negotiate in good faith to revise the provisions of Section 10.2 within ninety
(90) days of such notice or such other time period as the Parties agree upon for
such negotiations.
10.4 All insurance policies identified in Section 10.2, except Worker's
Compensation Insurance, shall name the Company as an additional insured.
25
10.5 The Power Producer's liability insurance (other than its Worker's
Compensation Insurance) shall include provisions or endorsements (i) stating
that such insurance is primary insurance with respect to the interest of the
Company and that any insurance maintained by the Company is excess and not
contributory insurance with the insurance required hereunder, and (ii) providing
that such policies shall not be canceled or their limits of liability reduced
except upon thirty (30) days prior written notice to the Company.
10.6 The Power Producer shall provide and shall continue to provide to
the Company during the term the Agreement (including any extensions), by
delivering to its corporate office at 0000 Xxxxxxxxxx Xxxx, X.X. Xxx 00000,
Xxxxxxx, Xxxxxxxxxxxx 00000-0000, Attention: Manager - Transmission Investment
Planning, properly executed and current certificates of insurance relative to
insurance policies. Certificates of insurance shall provide the following
information:
(i) Name of insurance company, policy number and expiration date.
(ii) The coverage required and the limits on each, including the
amount of deductibles or self-insured retentions, which shall
be for the account of the Power Producer.
(iii) A statement indicating that the Company shall receive at least
thirty (30) days prior written notice of cancellation or
reduction of liability limits with respect to said insurance
policies, and
(iv) To the extent applicable, a statement indicating that the
Company has been named as an additional insured.
10.7 A copy of each insurance policy, certified as a true copy by an
authorized representative of the issuing insurance company, or in lieu thereof
or in addition thereto, at the
26
Company's discretion, a certificate in form satisfactory to the Company
certifying to the issuance of such insurance, shall be furnished to the Company
not less than ten (10) days prior to the interconnection of the Facility and
fifteen (15) days prior to the expiration date of each such policy and/or
certificate.
10.8 The Company shall have the right to inspect the original policies
of insurance applicable to this Agreement at the Power Producer's place of
business during regular business hours.
ARTICLE 11
PERFORMANCE
11.1 If at any time the Power Producer fails to operate, maintain,
administer, or insure the Facility, the Power Producer Interconnection
Facilities or Protective Apparatus, the Company may, following prior written
notice and the right of the Power Producer to cure such condition within thirty
(30) days after the Power Producer's receipt of notice, immediately disconnect
the Facility from the Transmission System or otherwise refuse to accept electric
energy and capacity for delivery.
11.2 If, in the sole judgment of the Company exercised in accordance
with Good Utility Practice, operation of the Facility, the Power Producer
Interconnection Facilities or Protective Apparatus endangers the safety of the
Company's personnel or the safe operation of the Company's electrical system or
the electrical systems of others to which the Company's electrical system is
directly or indirectly interconnected, the Company may immediately disconnect
the Facility from the Transmission System or otherwise refuse to accept electric
energy and capacity
27
for delivery therefrom until such condition has been corrected to the Company's
satisfaction in a manner consistent with Good Utility Practice.
11.3 The Power Producer shall be solely responsible for correcting any
condition necessitating such disconnection. If the condition is corrected in
accordance herewith, the Company shall use reasonable efforts to promptly
reconnect the Facility.
11.4 The Parties shall use due diligence to perform their respective
obligations under this Agreement. However, in the event that either Party is
delayed in or prevented from performing or carrying out its obligations under
this Agreement by reason of Force Majeure as defined herein, such Party shall
not be liable to the other Party for or on account of any loss, damage, injury
or expense resulting from or arising out of such delay or prevention; provided,
however, that the Party encountering such delay or prevention shall use due
diligence to remove the cause or causes thereof.
ARTICLE 12
LIABILITY AND DEDICATION
12.1 Nothing in this Agreement shall be construed to create any duty to,
standard of care with respect to, or any liability to any person not a Party to
this Agreement.
12.2 Neither the Company nor the Power Producer, nor their respective
officers, directors, partners, agents, employees, or Affiliates, shall be liable
to the other Party or its Affiliates, officers, directors, partners, agents,
employees, successors or assigns, for claims for incidental, special, indirect
or consequential damages of any nature connected with or resulting from
performance or non-performance of this Agreement or the inability of Power
Producer to
28
transmit power from the Facility to the Transmission System for delivery to its
load when the Company Interconnection Facilities are not in service, including
without limitation, claims in the nature of lost revenues, income or profits or
losses, damages or liabilities under any financing, lending, construction, or
maintenance contracts, back-up power or such other agreements or arrangements to
which the Power Producer may be party irrespective of whether such claims are
based upon warranty, negligence, strict liability, contract, operation of law or
otherwise. Further, the Power Producer releases and holds the Company harmless
for any and all damages associated with the inability to transmit power from the
Facility to the Transmission System when any of the Company Interconnection
Facilities are not in service, other than any damages that are ultimately
determined to be based upon the gross negligence or willful misconduct of the
Company, including but not limited to, Power Producer's or any third party's
lost revenues, income or profits or losses, damages or liabilities under any
financing, lending, agreements or arrangements to which the Power Producer's or
third party may be a party irrespective of whether such claims are based upon
warranty, negligence, strict liability, contract, operation of the law or
otherwise. The provisions of this section 12.2 shall survive the termination,
cancellation, suspension, completion or expiration of this Agreement.
12.3 No undertaking by either Party under any provision of this
Agreement shall constitute the dedication of that Party's electrical system,
equipment or facilities, or any portion thereof, to the other Party or to the
public, nor affect the status of the Company as a public utility corporation.
12.4 The Company does not, by acceptance of the Power Producer's
interconnection plans
29
and specifications or by engaging in interconnected operations with the Power
Producer, assume any responsibility or liability for damage or physical injury
to (a) Company property or electrical equipment; (b) the real or personal
property of third persons or corporations not a party to this Agreement; (c) the
Facility, real property, equipment and/or facilities and/or any appurtenances
thereto of the Power Producer; and (d) any persons who may come into contact
with or upon the Facility, real property, equipment and/or facilities(electric
or gas) and/or any appurtenances thereto.
ARTICLE 13
INDEMNIFICATION
13.1 The Power Producer shall indemnify, hold harmless and defend the
Company, and its Affiliates, as the case may be, and their respective officers,
directors, employees, agents, partners, subcontractors, invitees and successors,
from and against any and all claims, liabilities, costs, damages, losses, and
expenses (including, without limitation, reasonable attorney and expert fees,
and disbursements incurred by the Company in any action or proceeding between
the Company and a third party, the Power Producer, or any other party) for
damage to property, injury to or death of any persons, including the Company's
employees or any third parties (collectively, "Company's Damages"), to the
extent caused wholly or in part by any act and/or omission, negligent or
otherwise, relating to the design, construction, ownership, operation, or
maintenance of the Facility, Power Producer Interconnection Facilities and
Protective Apparatus used in connection with this Agreement and provided,
however; that Power Producer, or its respective Affiliates, and successors, and
their respective officers, agents, directors, partners or
30
employees shall not be liable to the Company, its Affiliates, and successors,
and their respective agents, officers, directors, partners or employees for
incidental, special indirect or consequential damages of any nature connected
with or resulting from performance or non-performance of this Agreement. Company
hereto will furnish the Power Producer with written notification after the
Company becomes aware of any event or circumstances, or the threat thereof (but
in no event later than ten (10) days prior to the time any response is required
by law), which might give rise to such indemnification. At the Company's
request, the Power Producer shall defend (with counsel reasonably acceptable to
the Company) any suit asserting a claim covered by this indemnity and shall pay
all costs and expenses (including the cost of investigation and attorney's fees
and expenses) that may be incurred in enforcing this indemnity. The Company may,
at its own expense, retain separate counsel and participate in the defense of
any such suit or action.
13.2 The indemnity in Section 13.1 shall apply to all claims against the
Company including, but not limited to, all claims made or threatened by, or in
the name of or on behalf of the Company's employees for personal injuries
(including death) which arise in the course of their employment; provided,
however that said indemnity shall not apply to any liability ultimately
determined to be based upon the negligence of the Company. The Power Producer
hereby waives any defense it may otherwise have under applicable workers'
compensation laws.
13.3 In addition to Sections 13.1 and 13.2 above, the Power Producer
shall indemnify, hold harmless and defend the Company from and against any and
all liability, loss, cost, damage and expense, associated with any and all
Federal, State and/or local tax liability, arising out of, resulting from or in
connection with Power Producer's payment (or failure to pay) to the
31
Company, of the costs associated with the purchase and installation of any
portion of the Company's Interconnection Facilities, Protective Apparatus and/or
any and all associated and/or related structures, equipment, facilities and
devices in performance of, pursuant to or in connection with this Agreement,
including any expense resulting from such payment being deemed to be a
Contribution In Aid of Construction ("CIAC") pursuant to U.S. Internal Revenue
Service Notices 88-129 and 90-60 (and any future applicable U.S. Internal
Revenue Service notices), which Notices are incorporated by reference herein.
The foregoing indemnification obligations of the Power Producer shall not,
however, apply with respect to any of the equipment or facilities referred to
immediately above which the Company has included in its rate base and is
collecting revenues from its customers. The Parties expressly acknowledge and
agree that Sections 13.1, 13.2 and 13.3 shall survive the termination or
expiration of this Agreement.
13.4 Power Producer shall provide the Company with an Independent
Engineering Certification (i.e., the professional engineer's seal shall be
affixed), as specified in IRS Notice 88-129, attesting that the anticipated
power flows through the Interconnection Facilities to the Power Producer for the
first ten years commencing with the taxable year in which the Interconnection
Facilities are placed in service, (or alternatively, for the first nine years
ignoring the year such facilities are placed in service) will comprise no more
than 5% of the projected total power flows over the Interconnection Facilities.
This engineering certification will be provided to the Company within forty-five
days of the execution of this Agreement. In the event this certification is not
provided to the Company, the Company retains the right to include the tax
gross-up in the final billing for the actual costs of the Interconnection
Facilities. In the event the
32
5% test, as specified in IRS Notice 88-129, is exceeded during any measuring
period, described in section 4(A) of Notice 88-129 (a "disqualifying event"),
Power Producer agrees to make the Company whole for any increase in the
Company's Federal and State income tax liabilities arising from this condition.
This increase in the Company's Federal and State income tax liabilities will be
determined in accordance with the requirements of IRS Notice 90-60, as amended
or supplemented.
ARTICLE 14
REPRESENTATIONS, WARRANTIES AND COVENANTS
14.1 The Power Producer hereby represents and warrants as follows:
(a) The Power Producer is a limited liability company duly
organized validly existing and in good standing under the laws of the State of
Delaware and is duly registered and authorized to do business and in good
standing in the State of New Jersey;
(b) The Power Producer has all requisite power and authority to
carry on the business to be conducted by it and to enter into and perform its
obligations under this Agreement;
(c) The execution and delivery of this Agreement and the Power
Producer's performance of its obligations hereunder have been duly authorized by
all necessary action on the part of the Power Producer and do not and will not
conflict with or result in a breach of the Power Producer's charter documents or
by-laws or any indenture, mortgage, other agreement or instrument subject to
receipt of all necessary regulatory approval, or any statute or rule,
regulation, order, judgment or decree of any judicial or administrative body to
which the Power Producer is a party or by which the Power Producer or any of its
properties is bound or subject.
33
14.2 The Company hereby represents and warrants as follows:
(a) The Company is a corporation duly incorporated, validly
existing and in good standing under the laws of the State of New Jersey.
(b) The Company has the corporate power and authority to own its
properties, carry on its electric utility business as now being conducted, enter
into this Agreement and the transactions contemplated hereby, and perform and
carry out all covenants and obligations on its part to be performed under and
pursuant to this Agreement.
(c) The execution and delivery of this Agreement by the Company and
the performance of its obligations hereunder have been duly authorized by all
necessary corporate action on the part of the Company.
(d) This Agreement is the valid and binding obligation of the
Company, enforceable with its terms except that, in the Company's view, (i) such
enforceability may be limited by applicable bankruptcy, insolvency or similar
laws from time to time in effect that affect creditors' rights generally or by
general principles of equity, and (ii) contracts entered into by the Company may
be subject to the power and authority of state and/or federal regulatory
agencies.
ARTICLE 15
EVENTS OF DEFAULT
15.1 Any one of the following shall constitute an event of default under
this Agreement:
(a) A breach of any material term or condition of this Agreement,
including but not limited to any material breach of a representation, warranty
or covenant made in this Agreement, including the Appendices. Failure by a Party
to provide any required schedule, report or notice
34
hereunder may constitute a material breach hereof if such failure is not cured
within sixty (60) days after notice to the defaulting Party.
(b) The failure or refusal of a Party to permit the representatives
of the other Party access to the maintenance records, or its Interconnection
Facilities or Protective Apparatus in order to examine, inspect and test such
records.
(c) A receiver or liquidator or trustee of either Party or of any
of its property shall be appointed by a court of competent jurisdiction, and
such receiver, liquidator or trustee shall not have been discharged within sixty
(60) days; or by decree of such a court, a Party shall be adjudicated bankrupt
or insolvent or any substantial part of its property shall have been
sequestered, and such decree shall have continued undischarged and unstayed for
a period of sixty (60) days after the entry thereof; or a petition to declare
bankruptcy or to reorganize a Party pursuant to any of the provisions of the
Federal Bankruptcy Code, as now in effect or as it may hereafter be amended, or
pursuant to any other similar state statute as now or hereafter in effect, shall
be filed against a Party and shall not be dismissed within (60) days after such
filing; or
(d) A Party shall file a voluntary petition in bankruptcy under
any provision of any federal or state bankruptcy law or shall consent to the
filing of any bankruptcy or reorganization petition against it under any
similar law; or, without limiting the generality of the forgoing, a Party
shall file a petition or answer or consent seeking relief or assisting in
seeking relief in a bankruptcy under any provision of any federal or state
bankruptcy law or shall consent to the filing of any bankruptcy or
reorganization petition against it under any similar law; or, without
limiting the generality of the foregoing, a Party shall file a petition or
answer or consent seeking
35
relief or assisting in seeking relief in a proceeding under any of the
provisions of the Federal Bankruptcy Code, as now in effect or as it may
hereafter be amended, or pursuant to any other similar state statute as now
or hereafter in effect, or an answer admitting the material allegations of a
petition filed against if in such a proceeding; or a Party shall make an
assignment for the benefit of its creditors; or a Party shall admit in
writing its inability to pay its debts generally as they become due; or a
Party shall consent to the appointment of a receiver, trustee, or liquidator
of it or of all or any part of its property.
(e) The failure of either Party to provide the other Party
reasonable written assurance of its ability to perform fully and completely any
of its material duties and responsibilities under this Agreement within sixty
(60) days of any reasonable request for such assurances by a Party hereto.
15.2 (a) Upon the occurrence of an event of default, the Party not in
default may give written notice of the default to the defaulting Party. Such
notice shall set forth, in reasonable detail, the nature of the default and,
where known and applicable, the steps necessary to cure such default. The
defaulting Party shall have sixty (60) days following receipt of such notice
either to (i) cure such default or (ii) commence in good faith all such steps as
are appropriate to cure such default in the event such default cannot, in the
reasonable judgment of such non-defaulting Party, be completely cured within
such sixty (60) day period.
(b) If the defaulting Party fails to cure such default or take such
steps as provided under subparagraph (a) above, this Agreement may be terminated
by written notice to the Party in default hereof. This Agreement shall thereupon
terminate and the non-defaulting Party may
36
exercise all such rights and remedies as may be available to it to recover
damages caused by such default.
(c) Notwithstanding the foregoing, upon the occurrence of any such
event of default, the non-defaulting Party shall be entitled (i) to commence an
action to require the defaulting Party to remedy such default and specifically
perform its duties and obligations hereunder in accordance with the terms and
conditions hereof and (ii) to exercise such other rights and remedies as it may
have at equity or at law subject however to the provisions of Article 12.
15.3 The Company shall be entitled to operate and/or purchase from the
Power Producer such DC power systems, protection and metering circuit
components, Supervisory Control and Data Acquisition ("SCADA") equipment,
transformers, secondary systems, communications equipment, building facilities,
software, documentation, structural components; and other facilities and
appurtenances that are necessary for the Company to operate and maintain the
Transmission System if: (a) the Power Producer shall commence any case under
federal bankruptcy laws or other proceeding under any similar law or any
jurisdiction for the relief of debtors, or shall petition or apply for the
appointment of a trustee or other custodian, liquidator, or receiver for the
Power Producer or for any substantial part of the Power Producer's Facilities;
(b) a decree or order for relief shall be entered in respect of the Power
Producer in an involuntary case under federal bankruptcy laws or in any other
proceeding under any similar law of any jurisdiction for the relief of debtors
or a decree or order shall be entered appointing a trustee or other custodian,
liquidator, or receiver for the Power Producer or for any substantial part of
the Power Producer's Facilities and such a decree or order is not dismissed
within sixty (60) days
37
after it is entered; or (c) the Power Producer shall cease its operations for
more than thirty (30) consecutive days without having an assignee, successor, or
transferee in place.
Upon the occurrence of any of the foregoing events, the Company
shall give the Power Producer or the Power Producer's assignee, successor or
transferee written notice, pursuant to Article 17, of its intent to implement
its rights under this Section 15.3, which notice shall specify the actual or
alleged failure of the Power Producer to comply with its obligations or duties.
If the failure endangers life or property, or impairs or creates a significant
risk to the safety, reliability, stability, or integrity of the Transmission
System, the Company may implement this Section 15.3 without such prior notice as
necessary in its judgment to avert such condition.
ARTICLE 16
ASSIGNMENT
16.1 No Party may assign, transfer or otherwise encumber or dispose of
this Agreement or any rights, duties, interests or obligations hereunder without
the prior written consent of the other Party; PROVIDED, however, that the
Company may at any time and without the consent of the Power Producer, assign
this Agreement together with its rights, interests, duties or obligations
hereunder to any Affiliate of the Company or any successor entity; PROVIDED,
further, that in any event the assignee shall agree to be bound by all of the
terms and conditions hereof to the same extent as the Company. Notwithstanding
the foregoing, the Power Producer may assign and encumber its respective rights
under this Agreement in favor of the Lenders without the consent of the Company.
The Lenders may further assign this Agreement to other persons following the
prior consent of the Company which shall not be unreasonably withheld. PROVIDED,
further, that
38
in any event the assignee shall agree to be bound by all of the terms and
conditions hereof to the same extent as the Power Producer. Each Party shall
give its consent to assignments made in accordance with this Article in the form
reasonably requested by the interested Party. In the event of an assignment
without consent as set forth above, the assigning Party agrees to provide the
other Party with prompt notice of such assignment.
16.2 In the event of any sale, transfer, assignment, lease or any other
disposition of the Facility or any substantial portion thereof by the Power
Producer, or upon termination of the Agreement, or termination of any operation
at the Facility, the Power Producer hereby agrees to indemnify and hold harmless
the Company for any and all costs, expenses, liabilities and damages (including
reasonable attorneys' fees) for which the Company may be obligated in order to
comply with any applicable requirements of the federal, state, or local
regulations.
ARTICLE 17
NOTICES
17.1 All notices required or permitted under this Agreement shall be in
writing and shall be personally delivered or sent by certified United States
mail, postage prepaid, telex, facsimile transmission, or overnight express mail
or courier service addressed as follows:
If to the Power Producer to: Xxxxx X. Xxxxxxxxx
Vice President
AES Red Oak, L.L.C.
0000 Xxxxx 00xx Xxxxxx
Xxxxxxxxx, XX 00000
If to the Company to: Manager - Transmission Investment Planning
39
GPU Energy
0000 Xxxxxxxxxx Xxxx
Xxxx Xxxxxx Xxx 00000
Xxxxxxx, XX 00000-0000
and
GPU Energy
Legal Department
0000 Xxxxxxxxxx Xxxx
Post Office Box 16001
Reading, PA 19640-0001
or to such other person at such other address as a Party shall designate by like
notice to the other Party.
17.2 Unless otherwise provided herein, all notices hereunder shall be
deemed to be given when sent pursuant to Section 17.1 mailed or personally
delivered.
ARTICLE 18
AMENDMENT AND MODIFICATION
18.1 This Agreement may not be amended or modified except by a written
instrument signed by each of the Parties hereto.
18.2 Nothing contained in this Agreement shall be construed as affecting
in any way the right of the Company to unilaterally make application to FERC for
a change in rates, terms and conditions, charges, classification of service,
rule or regulation under Section 205 of the Federal Power Act or applicable laws
and requirements.
18.3 Nothing contained in this Agreement shall be construed as affecting
in any way the ability of the Power Producer to exercise its rights under the
applicable rules and requirements of the Federal Power Act and pursuant to
FERC's rules and regulations promulgated thereunder.
40
ARTICLE 19
DISPUTES
19.1 Any claim or dispute, which either Party may have against the
other, arising out of the Agreement shall be submitted in writing to the other
Party not later than thirty (30) days after the circumstances which gave rise to
the claim or dispute have taken place. The submission of any claim or dispute
shall include a concise statement of the question or issue in dispute, together
with relevant facts and documentation to fully support the claim.
19.2 If any such claim or dispute arises, the parties shall attempt to
resolve the claim or dispute, initially through good faith negotiations or upon
the failure of such negotiations, through Alternative Dispute Resolution ("ADR")
techniques in accordance with the Model Procedure for Mediation of Business
Disputes as published by the Center for Public Resources; however, either Party
may terminate its participation in ADR during any stage of ADR and proceed under
section 19.3.
19.3 If any claim or dispute arising hereunder is not resolved pursuant
to section 19.2, either Party may, upon giving the other Party at least ten (10)
days prior written notice, initiate litigation to submit such claim or dispute
for decision by a court of competent jurisdiction of the Commonwealth of
Pennsylvania in accordance with the laws of the State of New Jersey.
19.4 Nothing in this Article 19 shall restrict the rights of any Party
to file a complaint with FERC under relevant provisions of the Federal Power
Act.
41
ARTICLE 20
MISCELLANEOUS
20.1 Except as may be otherwise provided herein, the duties, obligations
and liabilities of the Parties hereto are intended to be several and not joint
or collective. Nothing contained in this Agreement shall ever be construed to
create an association, trust, partnership, or joint venture or impose a trust or
partnership duty, obligation or liability or agency relationship on or with
regard to either Party. Each Party shall be individually and severally liable
for its own obligations under this Agreement.
20.2 Any waiver at any time by either Party of its rights with respect
to a default under this Agreement, or with respect to any other matters arising
in connection with this Agreement, shall not be deemed a waiver with respect to
any subsequent default or any other matter.
20.3 All indexes, titles, subject headings, section titles and similar
items are provided for the purpose of reference and convenience only and are not
intended to be inclusive, definitive or to affect the meaning of the contents or
scope of this Agreement.
20.4 The Company shall prohibit its employees from using their official
position for personal financial gain, or from accepting any personal advantage
from anyone under circumstances which might reasonably be interpreted as an
attempt to influence the recipients in the conduct of their official duties. The
Power Producer and its employees and representatives shall not, under
circumstances which might reasonably be interpreted as an attempt to influence
the recipients in the conduct of their duties, extend any gratuity or special
favor to employees of the Company.
20.5 This Agreement shall be governed by and construed in accordance
with the laws of the
00
Xxxxx xx Xxx Xxxxxx applicable to contracts made and to be performed in that
State, irrespective of the application of any conflicts of laws provisions.
20.6 This Agreement supersedes any and all oral or written agreements
and understanding heretofore made relating to the subject matter hereof.
20.7 (a) Upon the Power Producer's written request, the Company shall
maintain and not disclose to any Party, except Authorized Parties, as defined
below, Confidential Information, as defined below, which is disclosed to the
Company by the Power Producer hereunder.
(b) For purposes hereof, "Confidential Information" means
contracts, insurance policies, documents, plans, drawings, specifications and
other information which the Power Producer maintains as confidential and which
is clearly so marked or identified when it is disclosed to the Company, except
that Confidential Information shall not include information which (i) is
available to the public, (ii) becomes available to the public other than as a
result of a breach by the Company of its obligations hereunder, (iii) was known
to the Company prior to its disclosure to the Company by the Power Producer, or
(iv) is required to be disclosed pursuant to statute, rule, regulation or order
or any court, governmental authority or regulatory body.
(c) For purposes hereof, "Authorized Party" means any officer,
employee, representative, agent or attorney of the Company or any officer,
employee, representative, agent or attorney of any Affiliate of the Company
whose duties include the negotiation, evaluation, approval, performance or
administration of this Agreement and who needs to know the Confidential
Information in order to perform his duties.
20.8 No information relating to this Agreement may be published or
released for
43
publication by the Power Producer without the prior written approval of the
Company, which shall not be unreasonably withheld; PROVIDED, however, that the
foregoing shall not restrict the Power Producer from making any filing or public
disclosure with respect to this Agreement which may be required by applicable
law.
20.9 This Agreement may be executed in any number of counterparts, and
all such counterparts executed and delivered, each as an original, shall
constitute but one and the same instrument.
20.10 Should any provision of this Agreement be held invalid or
unenforceable, such provisions shall be invalid or unenforceable only to the
extent of such invalidity or unenforceability without invalidating or rendering
unenforceable any other provision hereof.
20.11 The Company shall furnish such information, certificates, opinions
of counsel, consents to assignment or pledge and other documents and assistance
as may be reasonably requested by the Lenders in connection with the financing
of the Facility. The Company agrees to negotiate in good faith concerning any
reasonable amendment or addition to this Agreement required by any Lender in
connection with the financing of the Facility. The Power Producer shall
reimburse the Company for any and all costs associated with furnishing such
information including reasonable attorneys fees.
44
IN WITNESS WHEREOF, the Parties by their authorized representatives
have executed this Agreement as of the day and year first set forth above.
ATTEST: AES RED OAK, L.L.C.
/s/ Xxxxxxx Xxxxxx By: /s/ Xxxxx X. Xxxxxxxxx
------------------------------- -------------------------------
ATTEST: JERSEY CENTRAL POWER & LIGHT
COMPANY d/b/a GPU ENERGY
/s/ Xxxxxxx X. Xxxxxxxx By: /s/ X.X. Xxxxxxx
------------------------------- -------------------------------
45
APPENDIX A
DESCRIPTION OF FACILITY
1. Written Description of the Facility to include the location, type, size
and capacity of the Facility
2. Topographical Map to locate the facility
3. One-Line Interconnection Diagram that includes a description of the
Company and Power Producer Interconnection Facilities
A1
RED OAK FACILITY DESCRIPTION
Net Facility Capacity at 92F = 760.5 MW plus/minus 10%
Expected Capacity at ISO conditions (59F) = 815.8 MW plus/minus 10%
The Site is located off Jernee Mill Road, in the Borough of Sayreville,
Middlesex County, NJ. The Site elevation ranges from 25 to 75 feet above sea
level. With the exception of the multi-flue stack and the HRSG drums, all
buildings and structures comprising the Facility are not more than 65 feet tall.
The Facility main power block consists of three Siemens Westinghouse Power
Corporation (SWPC) 501F combustion-turbine generators with their associated heat
recovery steam generators and ancillary plant, and a single 290 MW steam turbine
generator. The four turbine generators are arranged in the turbine building,
which is connected to the control building. The heat recovery steam generators
are located outside of the turbine house. Other plant buildings and structures
outside of the main power block include the following:
Water Treatment facility
Cooling towers
Gas metering station
Administration building
Warehouse and maintenance shop
Switchyard
Pumphouse
The turbine generators will be nominally rated at 342 MVA, 0.85 power factor
lagging and can operate at approximately 0.95 power factor leading (as measured
at the generator), 18KV at 60Hz.,0.53 short circuit ratio, and 60 psi rated
hydrogen pressure.
The Facility will be capable of operation with a voltage range of plus/minus 5%
on the 230KV system.
The Facility will be supplied with four generator step-up transformers, three
rated at 200MVA and one rated at 324MVA, 10% impedance, with offline tap
changing, and two auxiliary transformers.
Interconnection with the GPU system will be via a 230KV single bus, single
breaker out door substation for each of the two transmission lines.
The Facility has no black start capability.
A2
TOPOGRAPHICAL MAP
AES RED OAK
TOPOGRAPHICAL MAP SHOWING THE
LOCATION OF THE AES RED OAK SITE
LOCATION MAP
A3
INTERCONNECTION ONE LINE DIAGRAM
AES RED OAK
AES RED OAK/JCP&L INTERCONNECTION DIAGRAM
POINT OF INTERCONNECTION
A4
APPENDIX B
INTERCONNECTION FACILITIES
The following information is included in Appendix B:
1. Detailed one-line diagram
2. List of equipment
3. Design characteristics
It is understood by the Parties that the information contained in Appendix B is
preliminary and included to show the general concepts of the Interconnection
Facilities. Additional items for interconnection and reinforcement may be
identified, the interconnection configuration may change, and specific material
items and quantities may change.
B1
INTERCONNECTION ONE LINE DIAGRAM
AES RED OAK
AES RED OAK/JCP&L INTERCONNECTION DIAGRAM
SYSTEM AROUND INTERCONNECTION
B2
EQUIPMENT TO BE PROVIDED BY THE POWER PRODUCER
DESCRIPTION
230 KV Switchyard (including but not limited to the following):
One 324 MVA Generator Step-up Transformer
Three 200 MVA Generator Step-up Transformers
Two Station Auxiliary Transformers
Power Circuit Breakers
Disconnect Switches
Surge Arrestors
Instrument Transformers
Control and Protective Relay Panels
Switchyard Storage Battery
Switchyard Battery Charger
Low Voltage Switchyard
Miscellaneous Switchyard Equipment
Switchyard Equipment Installation
Design and Fabrication of Substation Structures
Cast in place concrete for substation structures
Excavation and Fill
Aggregate Surfacing
Chain Link Fence
Revenue Metering System
Backup Metering System
Voice and Data Telephone circuits
SCADA system equipment
Protective Relaying as required by Appendix D to this Agreement
B3
EQUIPMENT TO BE PROVIDED BY THE COMPANY
QUANTITY DESCRIPTION
RED OAK 230 KV SUBSTATION
2 230 kV 3000A 40kA 2-cycle Breakers w/12 CT's/Annunciator/TravelCheck
1 Days Breaker Field Services (Pre-Installation Check-Out)
12 Doble Test Links & Adapter Plates, 3000A (for 230-kV breakers)
4 230 kV 3000 A GOAB Switches (for visual disconnect for breakers)
4 230 kV Switch Stand 2 230kV CCVT, w/Carrier Acc., 1200/2000:1, 0.01 mfd
2 230kV CCVT, w/o Carrier Acc., 1200/2000:1, 0.01 mfd
3 230kV Line Trap, 3000A
2 230kV CCVT/Wave Trap Rack (Steel) + shipping
2 230kV CCVT Rack (Steel) + shipping
2 Line Tuning Unit, Dual Frequency
1 Lot 4" Bus Tubing (approx. 700') and 3-Phase Bus Stands (approx 24)
2 230 kV Line Xxxxxxxxxxx/Xxxxxxxxxx
0 Xxx Xxxx Xxxxxxxx
0 Xxxxxxxx, 00x00, +Installation, w/Heat Pump
1 Building general wiring and lighting
1 Lot Telephone Protection Equipment
1 125 Vdc Charger (12A)
1 125Vdc Battery and Rack (60 Cells, 100Ah)
1 AC Panel & associated equipment
1 DC Panel & associated equipment
2 HV Line Panels
1 XXX
0 Xxxxxxx Service Transformer & Associated Equipment
1 Miscellaneous Purchases
RED OAK REMOTE TERMINALS
4 230 kV CCVT, w/Carrier Acc., 1200/2000:1, 0.01 mfd
4 230 kV Line Trap, 3000A
4 Line Tuning Unit, Dual Frequency
4 1 230 kV CCVT/Wave Trap Rack (Steel) + shipping
4 New HV Line Relay Panel
4 Miscellaneous Purchases
B4
APPENDIX C
TRANSMISSION OPERATION
INTERCONNECTION REQUIREMENTS
C1
GPU ENERGY'S
TRANSMISSION OPERATION
INTERCONNECTION REQUIREMENTS
FOR GENERATION FACILITIES
I. DEFINITIONS
The definitions set forth in the Generation Facility Transmission
Interconnection Agreement are incorporated herein by reference. In
addition, the following definitions apply:
PJM MANUALS - The instructions, rules, procedures and guidelines
established by the PJM OI for the operation, planning, and accounting
requirements of the PJM Control Area and PJM interchange energy
market.
SUPERVISORY CONTROL AND DATA ACQUISITION (SCADA) - A system of remote
control and real-time communications used to monitor and control the
Transmission System.
TRANSMISSION OPERATOR - The Company person(s), who coordinates the
day-to-day interconnection and operation of the Facility with the
Transmission System.
II. POLICY
Every Facility which is interconnected with and synchronized to the
Transmission System shall at all times coordinate its operation with
the assigned Company control center and provide all necessary and
requested information and equipment to assure that the Company can
operate its electrical system in a safe and reliable manner.
Continuous cooperation and communication between the Power Producer
and the Company are essential to assure that the Transmission System
is operated in a safe and reliable manner.
The Power Producer shall develop the operating principles and
procedures which shall be coordinated with the Company's requirements,
provide the necessary training for all employees, and provide for the
necessary communication of information between the Power Producer and
the Company. This includes the following:
(a) Provide the following information necessary to ensure the safe
and reliable operation of the Company's electrical system: (i)
a copy of the Power Producer's switching procedures; (ii) a
completed Generator Data Form (Attachment 1) for each
generating unit, unit step-up transformer and auxiliary
transformer.
(b) Implement Facility practices and procedures which are
consistent with the Company and PJM OI transmission
requirements as defined in the PJM Manuals and/or herein.
(c) Implement operating principles and procedures which shall be
coordinated with
C2
the Company's and the PJM OI's requirements for normal
operating conditions as defined in the PJM Manuals and/or
herein.
(d) Implement operating principles and procedures which shall be
coordinated with the Company's and the PJM OI's requirements
for emergency operating conditions as defined in the PJM
Manuals and/or herein.
(e) Provide data to the Company regarding the operation and
maintenance of the Facility in accordance with the Operating
Agreement of PJM Interconnection, L.L.C.
III. SYSTEM REQUIREMENTS
A. RELIABILITY
The Power Producer shall deliver the electric energy generated
by the Facility to the Company at the point(s) of
interconnection in the form of 3 phase, 60 Hertz alternating
current at the nominal system voltage at the point of
interconnection.
At no time shall the operation of the Facility, including the
associated generators or any of their auxiliary devices,
result in an electrical output in which individual harmonic
distortion exceeds 1% of the Company's voltage wave form or
the sum of all harmonics exceeds 1.5% of the Company's wave
form, as measured at the point of interconnection.
The Facility shall be operated with all of the Power
Producer's Protective Apparatus in service whenever the
Facility is connected to or operating in parallel with the
Company's electric system.
B. SWITCHING
The Power Producer shall be responsible for switching all
equipment it owns, operates or controls. A specified device(s)
to isolate the Facility from the Transmission System shall be
switched by the Power Producer whenever requested by the
Company, and locked and tagged by the Company to provide
safety clearance.
The Power Producer's switching procedures shall at all times
be followed precisely by the Power Producer and be closely
coordinated between the Power Producer and the Transmission
Operator. The Company shall provide a copy of its written
switching procedures to the Power Producer upon request.
If requested by the Power Producer, specified Company devices
shall be operated and tagged by the Company according to the
Company's switching and tagging practices and safety rules.
Company switching and tagging practices and safety rules shall
apply to (i) all situations involving the Company and (ii) any
Power Producer personnel involved with Company switching and
tagging.
C3
C. RELAYING
The Facility relaying systems shall be consistent with the PJM
OI and Company relaying practices as defined in the PJM
Manuals and Appendix D of the Generation Facility Transmission
Interconnection Agreement. Any changes to the design and/or
setting of the protective relay system shall be subject to the
prior review and acceptance by the Company.
The relaying system for the Facility shall be sufficient to
prevent or limit equipment damage for contingencies (i) within
the facility and (ii) external to the Facility and on the
Company system.
D. REAL-TIME COMMUNICATIONS
The Power Producer shall provide data via a SCADA system and
an associated, dedicated communications channel to the
Company's Energy Management System computer. Data shall
include, but is not limited to: MW; MVAR; MWh; voltage; 3
phase amps; and equipment status (i.e., open/close, on/off,
etc.).
SCADA system and metering shall be consistent with the
Company's practices, and compatible with the Company's
computer and communication systems. In addition, the Company
may require the ability to disconnect the Facility from the
Company's system via the SCADA system.
It is required that data shall be sent to the Company
automatically. In the event that the data is not automatically
received by the Company on a temporary basis, the Power
Producer shall call the Company with the operating data at
intervals specified by the Company. The Power Producer shall
correct any problems associated with the failure of equipment
within a reasonable time.
E. COMMUNICATIONS OF INFORMATION
The Power Producer and Transmission Operator shall promptly
exchange all information relating to all conditions which
affect (or could affect) the operations of the Facility and/or
the Company's electrical system and facilities.
The Power Producer shall provide adequate and reliable
telephone communication channels, manned by responsible
personnel, to integrate the Facility operation with the system
under both normal and emergency conditions.
The Power Producer shall communicate the outage of any
electrical equipment connecting the Facility to the Company's
system in accordance with the following requirements:
C4
a. Each Facility will be assigned one of the Company
operations centers as its primary contact. This
assignment is based upon the voltage level of the
connection to the Transmission System and the
geographic location of the Facility.
b. All planned and maintenance outages of electrical
equipment requiring Company personnel involvement
must be requested by the Power Producer, providing
the appropriate information in a format as defined by
the Company and shown on Attachment 2.
c. Advance notifications of planned and maintenance
outages shall conform to the requirements as defined
in the PJM Manuals.
The Power Producer shall keep and maintain accurate and
complete records for Power Producer Interconnection Facilities
containing such information regarding the operation and
maintenance of all equipment as is appropriate and consistent
with industry practice and as may be necessary for the Company
to comply with its applicable requirements. The Company will
advise the Power Producer of such requirements as in effect
from time to time. The Power Producer shall make such records
available to the Company for inspection and copying from time
to time as the Company may reasonably request.
IV. NORMAL OPERATION REQUIREMENTS
A. GENERATOR GOVERNOR CONTROL
For any Facility engaged in parallel operation with the
Company, the Facility shall:
1. Operate on automatic governor control, except for the
periods immediately before generating equipment is
being removed from service and immediately after it
has been placed in service, and
2. Minimize governor outages during periods of
operation.
B. SYNCHRONIZATION AND DISCONNECTION PROCEDURES
When synchronizing the Facility to or disconnecting the
Facility from the Company's electrical system:
1. The Power Producer shall obtain the Transmission
Operator's prior approval (i.e., at least 30
minutes), EXCEPT THAT EQUIPMENT MAY BE DISCONNECTED
FROM THE SYSTEM WITHOUT COMPANY APPROVAL TO PREVENT
INJURY TO PERSONNEL OR EQUIPMENT DAMAGE. If for any
reason the disconnection occurs without prior Company
approval, the Power
C5
Producer shall immediately notify the Transmission
Operator as to the energy reduction and the expected
return time.
2. In order to support the Transmission Operator's
responsibility to plan and operate the normal and
emergency operations of the transmission system, the
Power Producer shall keep the Transmission Operator
informed at all times of the Facility's availability
or any change(s) to its status.
C. VOLTAGE AND REACTIVE CONTROL PROCEDURES
1. The Power Producer shall operate the Facility with
automatic voltage regulation equipment in service at
all times, except for outages of the regulator for
maintenance or equipment failure. Such operation will
normally involve a prescribed voltage limited to +/-
1% of schedule. The Power Producer, at the option of
the Company, shall operate the Facility either (i)
according to a predefined voltage schedule provided
by the Company or (ii) according to a reactive power
schedule as provided by the Company, consistent with
the Facility's generation capability and the
Company's electrical system. From time to time, the
Company may request alternate schedules consistent
with the Facility's generation capability and the
Company's electrical system.
2. The Power Producer shall notify the Transmission
Operator prior to performing all voltage regulator
maintenance. The Power Producer shall notify the
Company of the outage with as much lead time as
possible. The Power Producer shall minimize the
duration of regulator equipment outages. The Power
Producer shall notify the Transmission Operator at
least 30 minutes prior to removing the voltage
regulator from service, or returning the voltage
regulator to service.
3. The Power Producer may be requested by the Company to
deviate from prescribed voltage or reactive power
schedules if, in the Company's sole judgment,
conditions warrant such changes including, without
limitation, operating the Facility in the leading,
lagging, or unity power factor mode, but within the
capability of the machine.
4. The Power Producer shall operate automatic voltage
regulation to a tolerance of +/- 1% of scheduled
voltage, except for regulator maintenance outages or
equipment failures, or conditions prevailing on the
system and/or the Power System which necessitate
other voltage levels.
5. The Power Producer shall provide manual voltage
regulation to maintain the prescribed voltage
schedule or reactive power schedule during voltage
regulator equipment outages.
C6
6. Momentary voltage fluctuations shall be permitted,
provided that they neither disturb service provided
by the Company or the Power Producer on their
respective systems nor hinder the Company from
maintaining proper voltage conditions on their
respective systems.
D. MAINTENANCE SCHEDULING
1. The Power Producer shall provide the Company with at
least thirty (30) days prior written notice of its
intent to take a Generator Planned Outage or
Generator Maintenance Outage of the Facility,
including turbine, generator, and boiler overhauls or
inspections, testing, and nuclear refueling.
2. The Power Producer shall provide the Company with at
least thirty (30) days prior written notice of its
intent to test Protective Apparatus associated with
Power Producer Interconnection Facilities, including
circuit breakers, relays and auxiliary equipment.
Company personnel may observe such testing.
3. The Power Producer shall notify the Transmission
Operator of its intent to remove electrical equipment
from service by 10:00 a.m. five (5) working days
prior to, and again 30 minutes before the Generator
Planned Outage or Generator Maintenance Outage
begins. The Transmission Operator may request the
Power Producer to delay or reschedule the Generator
Planned Outage or Generator Maintenance Outage if
system reliability conditions warrant.
To the extent practical, the Company shall provide to the
Power Producer not less than one week advance notice of its
intention to perform planned maintenance on its facilities
that may affect the Facility's operations. The Company shall
notify the Power Producer when any changes occur.
E. POWER PRODUCER GENERATOR FORCED OUTAGES
The Power Producer may remove any of its equipment from
service without prior notification to the Transmission
Operator due to a Generator Forced Outage. However, if the
Power Producer has advance knowledge of a Generator Forced
Outage, the Power Producer shall notify the Transmission
Operator with as much lead time as practical. For reliability
reasons the Power Producer shall notify the Transmission
Operator as soon as reasonably possible of the following:
- the starting time of the Generator Forced Outage
- the energy reduction resulting (or expected to
result) from the Generator Forced Outage
- the estimated time the equipment incurring the
Generator Forced Outage
C7
is expected to return to service
- the time the Power Producer equipment is actually
returned to service.
F. FACILITY EQUIPMENT AND CONTRACT DATA
In order to ensure that all Company personnel responsible for
the design and operation of the Company's system affected by
the Facility are familiar with its equipment configurations,
capabilities and operating parameters, the Company may from
time to time request, and the Power Producer shall provide in
a timely manner to the Company, detailed information about the
type, nature, and operating characteristics of the Facility
and all related equipment.
V. EMERGENCY OPERATION REQUIREMENTS
THE POWER PRODUCER AND COMPANY SHALL MAINTAIN COMMUNICATIONS AND
CONTACT DURING ALL COMPANY OR PJM EMERGENCY OPERATIONS.
A. SYSTEM EMERGENCY CONDITIONS
During an Emergency, as determined/declared by the Company or
the PJM OI, the Power Producer shall respond as promptly as
possible to all directives from the Transmission Operator with
respect to all matters affecting the operation of the Facility
including, without limitation, the following:
a. Thermal overload of electrical circuits (actual or
contingency)
b. High or low voltage conditions (actual or contingency)
The Transmission Operator may also direct the Power Producer
to (i) adjust (increase or decrease) the Facility energy
and/or reactive output (ii) connect or disconnect the Facility
from the Company's electrical system and/or (iii) deviate from
the prescribed voltage or reactive schedules. If safety or
system reliability conditions warrant, the Transmission
Operator may isolate the Facility from the Company's
electrical system without prior notice to the Power Producer
or upon such notice as is possible under the circumstances.
The Transmission Operator shall advise the Power Producer as
soon as possible of any forced outages of the Company's
electrical system which affect the Facility's operations.
When the Transmission Operator has determined that the
emergency conditions have been alleviated, he/she shall inform
the Power Producer and allow the Facility to return to normal
operations consistent with Good Utility Practice.
In order to safely and rapidly restore the Transmission System
following an outage of any or all of that system, a Facility
that has been isolated from the Company's electrical system
shall be allowed to reconnect only under the direction of the
Transmission Operator. In all cases, the Facility shall be
made
C8
ready to return to service and provide energy to the Company
as soon as possible.
Unless the Company requests a manual adjustment, the Power
Producer shall maintain the Facility automatic voltage
regulator in service during an Emergency.
The Power Producer shall participate in any voltage reduction
declared by the Company at any time, and operate the Facility
at the voltage level then requested by the Transmission
Operator.
C9
APPENDIX C
ATTACHMENT 1
GENERATOR DATA FORM
Station Name ________________________ Unit No. __________
Generator ____________________ Rated Capacity __________ MVA
Operating Limits: Minimum KV _________ Maximum KV _________
Alarm Limits: Minimum KV _________ Maximum KV _______
Alarm Action: Minimum: ___________________________
Maximum: ___________________________
Max. Output (Installed Capacity) ________ MW
Max. Gross Output ________ MW
Capability LAG Curve Breakpoint __________ MW __________ MVAR
Rated Stator Voltage _______ Rated Stator Current _______ Amps
Generator Terminal Voltage - High Limit ______ Low Limit ______
Rated Field Current _________ Amps D.C. @ _________ Volts D.C.
Rated Hydrogen Pressure _______ PSIG Power Factor _________
Field Current High Limits: Rated ________ Amps D.C.
Field Voltage High Limits:
Rated ________ Volts D.C. Maximum: _______ Volts
Field Limit Alarms: Volts _______ Amps _______ Temp. _______
Alarm Action: Volts _______________________________________
Amps _______________________________________
Temperature _____________________________________
Line Drop Compensation: Type ________________________________
Setting _______________________________
Generator Stator Current High Limit _________
C9
SYSTEM VOLTAGE: Nominal KV _______ Min. _______ Max. _______
Alarm Limits: Minimum _____________ Maximum ________________
Alarm Action: Minimum _______________________________________
Maximum _______________________________________
Other Limitations ___________________________________________________
Misc. Important Information ________________________________________
___________________________________________________________________
GENERATOR UNIT STEP-UP TRANSFORMER DATA
Station Name ________________________ Unit No. __________
Unit Step-Up Transformer __________________________
Phase ________________ Connection _____________ __________
Class ________________
Rated Capacity ________ MVA at __________ C Rise
________ MVA at __________ C Rise
Rated Winding Voltage: (Primary) _________ KV
(Secondary) _________ KV
AVAILABLE TAPS/IMPEDANCE (XT AT RATED MVA)
POSITION PRIMARY KV SECONDARY KV IMPEDANCE % MAX. AMPS
-------- ---------- ------------ ----------- ---------
-------- ---------- ------------ ----------- ---------
-------- ---------- ------------ ----------- ---------
-------- ---------- ------------ ----------- ---------
-------- ---------- ------------ ----------- ---------
-------- ---------- ------------ ----------- ---------
-------- ---------- ------------ ----------- ---------
-------- ---------- ------------ ----------- ---------
-------- ---------- ------------ ----------- ---------
-------- ---------- ------------ ----------- ---------
Alarm Limits: KV _______________________
C10
Amps _______________________
MVA _______________________
Temperature _______________________
Primary Tap Setting ___________
Secondary Tap Setting ___________
Voltage Limits (if applicable) Primary ____________
Secondary ____________
Loading Limitations (if any)
________________________________________________________________________________
________________________________________________________________________________
AUXILIARY TRANSFORMER DATA
Station Name __________________________ Unit No. __________
Auxiliary Transformer ________________ Connection _______ _______
Class ________________
Rated Capacity ________ MVA at __________ C Rise
________ MVA at __________ C Rise
Rated Winding Voltage: (Primary) _________ KV
(Secondary) _________ KV
AVAILABLE TAPS/IMPEDANCE (XT AT RATED MVA)
POSITION PRIMARY KV SECONDARY KV IMPEDANCE % MAX. AMPS
-------- ---------- ------------ ----------- ---------
-------- ---------- ------------ ----------- ---------
-------- ---------- ------------ ----------- ---------
-------- ---------- ------------ ----------- ---------
-------- ---------- ------------ ----------- ---------
-------- ---------- ------------ ----------- ---------
-------- ---------- ------------ ----------- ---------
-------- ---------- ------------ ----------- ---------
-------- ---------- ------------ ----------- ---------
-------- ---------- ------------ ----------- ---------
C11
Alarm Limits: KV _______________________
Amps _______________________
MVA _______________________
Temperature _______________________
Primary Tap Setting ___________
Secondary Tap Setting ___________
Automatic Tap Changer Range ______________ to _____________ Volts
Raise Positions _____________
Lower Positions _____________
Voltage Limits (if applicable) Primary High ____________
Low ____________
Secondary High ____________
Low ____________
Load at Max. Generation _________ MW _________ Amps (Avg)
_________ MVAR _________ Volts
Load at Min. Generation _________ MW _________ Amps (Avg)
_________ MVAR _________ Volts
Loading Limitations (if any) ___________________________________________________
________________________________________________________________________________
C12
MISCELLANEOUS INFORMATION REQUIRED
1. A copy of the Generator Reactive Capability Curve
2. A copy of the Generator VEE Curve
3. A copy of the Generator Saturation Curve
4. A report of any special Operating Restrictions
- such as vibration or field problems
5. A report of any Environmental Restrictions
- such as SO2 emissions or river flow or temperature
6. A report of any known limiting facilities
C13
APPENDIX C
ATTACHMENT 2
APPLICATION FOR PROTECTIVE TAGGING ON LINES OR EQUIPMENT
DATE SUBMITTED ________________ W.O. NO. ________________________ APPLICATION NO.________________
APPLICANT:
SWITCH-HOURS ______________ DATE _________ DAY ___________ FINISH-HOURS A________ DATE _________DAY _______
START-HOURS ______________ DATE _________ DAY ___________ FINISH-HOURS A________ DATE _________DAY _____
APPARATUS/LINE REQUESTED:__________________________________________________________________________________
LOCATION:__________________________________________________________________________________________________
___________________________________________________________________________________________________________
WORK TO BE DONE:___________________________ _________________________________________ _____________________
___________________________________________________________________________________________________________
SWITCHES REQUIRED:_________________________________________________________________________________________
___________________________________________________________________________________________________________
___________________________________________________________________________________________________________
REMARKS:___________________________________________________________________________________________________
___________________________________________________________________________________________________________
___________________________________________________________________________________________________________
EMERGENCY CLEARANCE TIME ______________________________________ TRUCK OR PHONE NO. ________________________
TAGS PLACED FOR ________________________________________________ SIGNED____________________________________
CAN DO THE REQUIRED SWITCHING? YES NO COUNTER SIGNED________________________
OUT OF SERVICE OVERNIGHT? YES NO
SYSTEM OPERATOR:
SWITCHES TO BE TAGGED:_____________________________________________________________________________________
___________________________________________________________________________________________________________
___________________________________________________________________________________________________________
SYSTEM OPERATOR APPROVAL (1) __________________________________ (2) _______________________________________
DATE ______________ CLEARANCE @ ______________ BY ______________ CLEAR @ ______________ BY ________________
DATE ______________ CLEARANCE @ ______________ BY ______________ CLEAR @ ______________ BY ________________
DATE ______________ CLEARANCE @ ______________ BY ______________ CLEAR @ ______________ BY ________________
DATE ______________ CLEARANCE @ ______________ BY ______________ CLEAR @ ______________ BY ________________
DATE ______________ CLEARANCE @ ______________ BY ______________ CLEAR @ ______________ BY ________________
APPLICATION COMPLETED @ _________________ DATE _______________
DATE ______________ TIME _____________ PARTY NOTIFIED ________________ BY _______________ REMARKS _________
DATE ______________ TIME _____________ PARTY NOTIFIED ________________ BY _______________ REMARKS _________
DATE ______________ TIME _____________ PARTY NOTIFIED ________________ BY _______________ REMARKS _________
DATE ______________ TIME _____________ PARTY NOTIFIED ________________ BY _______________ REMARKS _________
C14
APPENDIX D
SYSTEM PROTECTION AND CONTROL
INTERCONNECTION REQUIREMENTS
D1
GPU ENERGY'S
SYSTEM PROTECTION AND CONTROL
INTERCONNECTION REQUIREMENTS
Revised: November 17, 1997
A. DEFINITIONS
GPU Energy - The trade name used individually and collectively by
the three operating electric utilities in the GPU System (i.e.,
Jersey Central Power and Light Company, Metropolitan Edison
Company, and Pennsylvania Electric Company).
GPU System - The transmission and distribution facilities owned
by GPU Energy.
Generation Facility - A facility for generating electricity which
is connected to the GPU system.
Generation - The electrical energy being produced by: rotating
generators driven by steam turbines, internal combustion engines,
hydraulic turbines, windmills, etc; fuel cells, photovoltaic or
battery arrays with a DC or AC inverter; or any other electric
generating device.
Power Producer - The owner or operator of the Generation
Facility.
B. OBJECTIVES
This document was prepared to assist GPU Energy engineers and
Power Producers when planning protection and control requirements
for interconnection between GPU Energy and the Generation
Facility.
To ensure all proposed installations are handled uniformly and to
minimize the possibility of misinterpreting GPU Energy`s
requirements, this document outlines the MINIMUM PROTECTION
REQUIREMENTS for the safe and effective operation of this
interconnection, and provides technical and administrative
guidelines.
C. GENERAL POLICY
The minimum protection requirements stated in this document are
intended to achieve the following goals:
- Insure the safety of the general public and GPU
Energy personnel.
- Minimize the possible damage to the property of the
general public, GPU
D2
Energy , GPU Energy customers, and neighboring
utility systems.
- Minimize adverse conditions on the GPU System.
- Permit the Power Producer to operate its generating
equipment in parallel with the GPU System in a safe
and reliable manner.
In order to achieve these goals, certain protective devices
(relays, circuit breakers, etc.) must be installed to promptly
disconnect the Generating Facilities from the GPU System whenever
a fault or abnormality occurs. The determination of what type of
protective devices are required depends primarily on three (3)
major factors:
1) The type and size of the Generation Facility.
2) The location of the Generation Facility on the GPU
System.
3) The manner in which the installation will operate.
In addition to the protective devices, certain modifications
and/or additions may be required to be made to the GPU System due
to the addition and/or modification of the Generation Facility.
EACH REQUEST WILL BE HANDLED INDIVIDUALLY, and the final
determination of the protective devices, modifications, and/or
additions required will be made by GPU Energy. Any modifications
to the GPU Energy distribution or transmission systems
necessitated by these changes to the Generation Facility will be
specified, purchased, and installed by GPU Energy at the expense
of the Power Producer.
GPU Energy will work with the Power Producer to achieve an
installation which meets the requirements of both the Power
Producer and GPU Energy.
GPU Energy cannot assume any responsibility for protection of the
Generation Facility's generating equipment, or any portion of the
Generation Facility's equipment. The Power Producer is solely
responsible for protecting its equipment in such a manner that
faults, imbalances or other disturbances on the GPU System do not
cause damage to the Generation Facility's equipment.
It is the responsibility of the Power Producer to comply with all
applicable Federal, State, and Local Regulatory Agencies and all
electrical and safety codes. Further, the Power Producer may be
required, in GPU Energy's sole and exclusive judgement, to
retrofit its interconnection protection systems due to
obsolescence, operational problems, enhancements in
microprocessor/solid state technology leading to improved
sensitivity, modifications to the GPU system or the Generation
Facility, and in accordance with the most recently published
industry standards and practices.
Any interconnection of a Generation Facility to the GPU System
must not impair the quality and quantity of transmission or
distribution service available to its customers, create
reliability problems, or interfere with the operation and
economic dispatch of power sources in which GPU Energy has
entitlement or with GPU Energy's ability to carry out its
obligations under pre-existing agreements.
A Generation Facility will not be permitted to be connected to
the GPU Energy low voltage ( LESS THAN 1 kV) looped network
system.
A GPU Energy controlled disconnecting device is required on the
GPU Energy side of all Generation Facility interties.
A Generation Facility's disconnecting device used to isolate the
facility's generation from the GPU System shall be blocked from
closing in on a de-energized utility circuit.
D3
The Power Producer is responsible for properly synchronizing its
generation with the GPU System.
D. REVIEW PROCESS
In order to process all Power Producer requests in an efficient
and consistent manner, the following Review Process for
Protection Requirements must be followed.
1. PRELIMINARY PROTECTION REQUIREMENTS REVIEW
The GPU Energy System Relay and Control Engineering
Department will have primary responsibility for the review
and comment of all required protection design and
associated settings.
The following information shall be supplied to GPU Energy :
a) Detailed One-Line Diagram of entire Generation
Facility system.
b) A potential schematic of Generation Facility.
c) A current schematic of Generation Facility.
d) A control schematic of Generation Facility.
e) A connection diagram indicating all external
connections to individual components of the
protective scheme.
f) A three-line diagram of Generation Facility.
g) Instruction manuals for all protective equipment.
Component specifications and internal wiring diagrams
shall be included if not provided in manuals.
h) All protective equipment ratings.
i) Generator data, complete Attachment 2.
j) Equipment specifications and details of transformers,
circuit breakers, current transformers, voltage
transformers, and any other major equipment or
special items.
k) Specific setting information on all the Generation
Facility's protective relays associated with the
generator protection and generator step-up
transformer protection or auxiliary transformer
protection.
One set of all the above information is required. GPU Energy may
in its discretion require that meeting(s) be held between GPU
System Relay and Control Engineering personnel and the Power
Producer's Consulting Engineer, Contractor, etc. during this
process.
Upon completion of the Preliminary Protection Requirements Review
process, the Power Producer's representative will be notified of
any modifications and/or additions, required to the GPU System or
to the Generation Facility. The Power Producer's representative
shall also be notified by GPU Energy that the Preliminary
Protection Requirements Review process is to be accomplished in a
timely manner and that it must represent an as accurate as
possible determination of protection requirements, however the
Power Producer's representative shall be notified that the
information submitted will be subject to change modification
and/or addition by GPU Energy, in its sole and exclusive
discretion.
2. FINAL PROTECTION REQUIREMENTS REVIEW
The Final Protection Requirements Review process will
proceed in the same manner as the Preliminary Protection
Requirements Review process outlined in Section D-1 above.
D4
The information identified in Section D-1, including any
modifications and/or additions made by GPU Energy during
the Preliminary Protection Requirements Review process,
will be required in triplicate. The Instruction manuals for
all protective equipment required pursuant to Section
D.1.(g) must contain at least one vendor original copy. All
information supplied for this review process shall be
Final\As-Built submittal information.
Upon GPU Energy's completion of its initial review of the
Power Producer's final submittal, the Power Producer's
representative will be notified of any final modifications
and/or additions required to the GPU System or to the
Generation Facility. Upon the Generation Facility's
satisfactory completion, as determined by GPU Energy in its
sole and exclusive judgement, of any required final
modifications and/or additions, GPU Energy will notify the
Power Producer's representative that the Final Protection
Requirements Review process has been completed.
E. DESIGN CONSIDERATION
1. AUTOMATIC RECLOSING
The need for automatic reclosing modifications is directed
towards protection of the GPU System and the equipment of
GPU Energy customers from potential damage. It is the Power
Producer's responsibility to evaluate the potential effect
of GPU Energy's reclosing practices on its generator and to
provide suitable protection.
GPU Energy normally provides automatic multiple shot
reclosing with no intentional time delay on the first shot
on all distribution line circuit breakers. Additionally,
automatic sectionalizing for faults is provided on the
distribution system with electronic and hydraulic reclosers
that reclose in approximately 2 seconds following a trip
operation. To protect both GPU Energy and GPU Energy
customers' equipment from possible damage due to
out-of-phase reclosing, the substation distribution line
circuit breaker and the line reclosers may have to be
modified, at the expense of the Power Producer, with
voltage check relays unless the size and characteristics of
the generator indicate that immediate reclosing would not
be hazardous to the GPU System. These relays will block
reclosing until the parallel generation on a line or line
section is de-energized.
Lines operated at 34.5 kV Delta and above also utilize
multi-shot automatic reclosing with the first shot delayed
approximately 20 cycles. Reclosing logic for these lines
must be modified, at the expense of the Power Producer, to
include synchronism checking.
2. PROTECTION REQUIREMENTS
Typical protection is illustrated in Appendix A Figures 1
and 2 inclusive.
The design of the Isolation and Fault Protection shall be
based upon a single failure philosophy, i.e., the failure
of any single component shall not render the protection
inoperative.
Isolation and fault protective relays shall be purchased,
installed and owned by the Power Producer. The required
fault and isolation protection shall be utility grade and
conform to the most recent ANSI Standard C37.90. Only solid
state/microprocessor based relay models are acceptable.
D5
ISOLATION PROTECTION
All relay settings associated with the Isolation Protection
shall be specified by GPU Energy .
GPU Energy shall have exclusive control and access to the
Isolation Protection.
a) UNDERVOLTAGE (27) WITH TIME DELAY (62). Relay to be
set at approximately 90% of nominal voltage (108
secondary volts on a 120 volt base). Time delay to be
set at approximately 2.0 seconds in order to provide
coordination with motor starting and system faults.
b) OVERVOLTAGE (59) WITH TIME DELAY (62). Relay to be
set at approximately 110% of nominal voltage (132
secondary volts on a 120 volt base). Time delay to be
set at approximately 2.0 seconds to over-ride relay
response to transients and external fault clearing
which may cause nuisance operations.
c) OVERFREQUENCY (81O). Relay to be set at 60.5 Hertz
with no intentional time delay in its operation.
d) UNDERFREQUENCY (81U) WITH TIME DELAY (62). Relay to
be set at 57.5 Hertz with a 5.0 second time delay.
This setting is necessary in order to coordinate with
GPU Energy 's system loadshedding underfrequency
relaying. GPU Energy , as a member of the
Pennsylvania- New Jersey-Maryland Interconnection
(PJM) agreement, has agreed to trip generators
connected to its system at a frequency of 57.5 Hertz
after a delay of 5.0 seconds. Therefore, the Power
Producer must also comply with this agreement. The
Power Producer is responsible to insure that setting
is compatible with all equipment purchased, installed
and operated at the Generation Facility.
FAULT PROTECTION
Generation Facility's fault protection shall coordinate
with GPU System protective devices for faults. All fault
protection settings are to be specified by the Power
Producer and approved by GPU Energy for COORDINATION
PURPOSES ONLY.
e) OUT-OF-STEP RELAYING (21 ZOS). Relays maybe required
to isolate the generator from the GPU System during
unstable conditions. The need for out-of-step
relaying will be based on the results of stability
studies. The Power Producer will be responsible for
providing the appropriate relay and settings.
f) SYNCHRONISM CHECK (25). A synchronism check relay
will be required on all breakers that may be used to
synchronize the generator to the system. The
synchronism check relay shall be capable of being set
for an angular difference of 10-60 degrees and have
an internal timer function allowing a time delay
setting between 0.5-5 seconds. The relay chosen must
also have an optional hot-bus dead-line; dead-bus
hot-line accessory.
g) NON-DIRECTIONAL PHASE OVERCURRENT (50/51),
NON-DIRECTIONAL GROUND OVERCURRENT (50/51G), AND
NON-DIRECTIONAL NEUTRAL OVERCURRENT (51N) RELAYS.
Where high-side of transformer (GPU System side) is
connected to the GPU System via a device other than
a fuse, the above mentioned protective relays are
required.
D6
Current transformers for the 50/51 and 50/51G relays
shall be located on the high-side of the transformers
protective device (breaker, circuit switcher, etc.)
If high-side grounding of the transformer is
provided, the 51N relay shall be connected to a
current transformer installed in the neutral
connection of the transformer.
h) VOLTAGE CONTROLLED TIME OVERCURRENT RELAYS (51V). In
applications where the Generation Facility is
interconnected to GPU Energy's distribution system
(34.5 kV Wye and below), voltage - controlled time
overcurrent relays must be provided. These relays
shall be connected to current transformers located on
the generator or its associated breaker. These relays
shall receive potential from the generator voltage
transformers.
i) SYSTEM BACKUP IMPEDANCE (21) RELAY(S). In
applications where the Generation Facility is
interconnected to GPU Energy's transmission system
(34.5 kV Delta and above), an impedance relay must be
provided as a backup function to clear faults on the
GPU Energy System. This relay(s) shall be connected
to current transformers located on the generator or
its associated breaker. These relays shall receive
potential from the generator voltage transformers. An
external timer (0.1 - 5.0 sec) must be provided if
not provided internal to the impedance relay design.
Time delay will be typically set between 1.0 and 2.0
seconds.
F. CONTROL SYSTEMS
The Power Producer has the option to use either an AC or DC
control system, as described below.
1. AC SYSTEM
The AC control system supply must use 60 Hz power derived
from the GPU Energy line. The system must be designed to be
fail-safe and the failure of any SINGLE component must
result in a trip of the generator breaker.
NOTE: In AC powered schemes, the generator breaker will
probably be a contactor. In such cases, a latching
contactor is not acceptable. The AC System shall use
continuously energized auxiliary relays with contacts
arranged to trip the generator circuit breaker whenever the
relays drop out. If a molded case circuit breaker (or
equal) is used, it MUST be equipped with an undervoltage
trip option.
All installations must isolate (trip) the generator in such
a manner that:
a manual operation
or
a time-delayed automatic synchro-check or voltage
check supervised operation
is required to close the generator or point-of-contact
breaker (contactor) after the GPU Energy source has
returned to normal.
D7
Under no circumstances is the generator contactor (breaker)
to close immediately upon restoration of the GPU Energy
source.
A white lamp should be provided to monitor the AC source
and shall have a nameplate.
2. DC SYSTEM
This system must use a battery of 48 or 125 VDC to supply
tripping energy to the generator circuit breaker.
All such installations must isolate (trip) the generator in
such a manner that:
a manual operation
or
a time-delayed automatic synchro-check or voltage
check supervised operation
is required to close the generator or point-of-contact
breaker (contactor) after the GPU Energy source has
returned to normal.
Under no circumstances is the generator contactor (breaker)
to close immediately upon restoration of the GPU Energy
source.
An amber or yellow lamp shall provided to monitor the DC
source and shall have a nameplate.
G. TARGETS
All protective relays shall be equipped with targets that
indicate operation. These targets are to be arranged in the
control circuit to operate only when the associated relays trip
the generator or point-of-contact circuit breaker.
H. REMOTE TERMINAL UNIT (RTU)
For all Generation Facility installations, a Remote Terminal Unit
(RTU) will be purchased and installed by GPU Energy at the
expense of the Power Producer. This RTU will utilize the CDC II
protocol and provide the necessary point counts required by the
Energy Management System (EMS) of GPU Energy to operate and
monitor the generation and interconnection facilities at the
Generation Facility site. Point count will include, but not be
limited to, analog, MWH, control, and status.
The Power Producer will provide an indoor weather controlled
location to mount an RTU and supply a four (4) wire data
telephone circuit in order for the RTU to communicate with the
GPU Energy EMS. Furthermore, a telephone and telephone circuit
must be provided in the location of the RTU in order that GPU
Energy personnel may communicate with the distribution or
transmission operator for installation and maintenance purposes.
D8
If necessary, provisions shall be made at the bottom of each
enclosure to allow all cables to be wired to the RTU. The Power
Producer must also supply the power necessary for the RTU. The
supply power can be, but not limited to, 125 VDC, 120 VAC, and 48
VDC.
I. GROUNDING
Neutral and ground are not to be confused. ALL current and
potential NEUTRALS are to be isolated from all other circuits.
Each neutral is to be grounded at ONE point only. The preferred
grounding location will be at the protective relay cabinet, on
the internal side of the States links.
J. WIRING
All wiring must agree exactly with schematics and wiring
drawings.
All wires must be anchored to the cabinet or bundled when running
between devices. Bundling is permitted but all wiring must be
traceable. Wiring must be installed so that it can be visually
traced and checked. Use of conduit, or equal, wire trough is
generally acceptable but must be verified with GPU Energy.
Wiring shall be installed so as to avoid damage to the cable and
its insulation. Movement of the hinged panel shall not damage the
cable or its insulation or cause stress to the termination points
on the panel or on the door.
Wiring and device location shall not prevent the removal of any
equipment, block access to equipment for inspection and
maintenance, nor block spare space in the cabinet.
All equipment shall be mounted and wired in such a manner that no
energized terminals or connections are exposed or accessible to
personnel with the hinged relay panel in a closed position.
Any protective relay not equipped with internal isolation device
must be connected through an external test device (i.e., ABB FT-1
or sliding link terminal blocks as determined and approved by GPU
Energy .)
All incoming and outgoing cables/conductors will terminate on
sliding link terminal blocks located in the protective relay
cabinet.
Terminal blocks shall be the States Company Type NT or
equivalent.
The incoming side shall have one (1) nut, for mounting incoming
cables.
The internal panel side shall have double nuts for mounting of
internal wires and marker tags. Marker tags should carry wire or
cable conductor identification.
Terminal blocks shall be mounted such that the connections and
lines are accessible and not blocked by projecting equipment.
D9
Terminal blocks shall be mounted a minimum of 6" from side walls
and adjacent equipment and a minimum of 4" above the bottom of
the housing.
Terminal blocks shall be mounted such that the sliding link:
Falls closed when loosened, if mounted in horizontal rows;
Moves toward the front of the cabinet when opened, if
mounted in vertical rows on side panels;
Moves away from the panel centerline when opened, if
mounted on the rear panel.
There shall be a minimum of 10% or 2, whichever is greater, spare
terminals included in the cabinet for modifications.
Pressure type connections with insulated sleeves shall be used.
Ring tongue lugs which completely encircle the screw or the stud
shall be used.
The crimping tool must be one approved by the Manufacturer for
use on the connector.
No soldered terminals or connections shall be used.
K. DRAWINGS CONTENT
1. ONE-LINE DIAGRAM
This drawing shows the functional arrangement, using single
line and standard symbol notations (per ANSI 432.2-1970,
41.1-1972) for the following equipment and accompanying
information:
a) Equipment Names and/or Numerical Designations for all
circuit breakers, contactors, switches, transformers,
generators, transmission lines, etc., associated with
the generation as required by GPU Energy to
facilitate switching.
b) Power Transformers - Name or designation, nominal
KVA, nominal primary, secondary, tertiary voltages,
vector diagram, impedance and tap settings.
c) Station Service/Operating Transformers - Designate
phase(s) connected to, and estimated KVA load.
D10
d) Instrument Transformers - Voltage and current, used
to supply the Protective Relay cabinet and phase
connections.
e) Lightning Arresters/Spill Gaps/Surge Capacitors -
Ratings.
f) Capacitor Banks - kvar rating.
g) Switches - Indicate status normally open with a
(N.O.) and type of operation manual or motor.
h) Safety Switch - Continuous ampere and interrupting
ratings.
i) Circuit Breakers and/or Contactors - Interrupting
rating, continuous rating, operating times.
j) Generator(s) - Include type, connection, KVA,
voltage, current, rpm, PF, etc.
k) Point of interconnection to the GPU System and phase
identification.
l) Fuses - Size, type location.
m) Grounding.
n) Relay Nomenclature - A "1" outside a relay function
shall indicate a single phase relay and a "3" shall
indicate a three phase relay or three individual
relays.
2. CONTROL SCHEMATIC
Control schematics are to be functionally complete
schematics. They shall be as simple and uncluttered as
possible, and shall contain the following information:
a) Terminal designation of all devices - relay coils and
contacts, switches, transducers, etc. If a device is
not supplied with terminal numbers, the cabinet
supplier shall number the device terminals clearly
and use those numbers on all drawings.
b) Relay functional designation - per latest ANSI
Standard. The same functional designation shall be
used on all drawings showing the relay.
c) Complete relay type, manufacturer, style number, and
relay range.
d) Numbers or wire designations for all cable
connections.
D11
e) Switch contacts shall be referenced to the switch
development if development is shown on a separate
drawing.
f) Switch developments and escutcheons shall be shown on
the drawing where the majority of contacts are used.
Where contacts of a switch are used on a separate
drawing, that drawing shall be referenced adjacent to
the contacts in the switch development. Any contacts
not used shall be referenced as spare. All switch
developments shall include the manufacturer name,
complete style number and notations indicating spring
return to normal operation, when appropriate.
g) All switch contacts are to be shown open with each
labeled to indicate the positions in which the
contact will be closed.
h) Explanatory notes defining switch coordination and
adjustment where misadjustment could result in
equipment failure or safety hazard.
i) Auxiliary relay contacts shall be referenced to the
coil location drawing if coil is shown on a separate
drawing. All contacts of auxiliary relays must be
shown and the appropriate drawing referenced adjacent
to the respective contacts.
j) Device auxiliary switches (circuit breakers,
contactor) must be referenced to the drawing where
they are used.
k) Any interlocks electromechanical, key, etc.,
associated with the generation.
l) Ranges of all timers, and setting if dictated by
control logic.
m) All target ratings (on dual ratings underline the
appropriate tap setting).
n) Complete internal for all protective relays.
Solid-state relays may be shown as a "black box" but
manufacturers instruction book number shall be
referenced, and terminal connections shown.
o) Isolation points (States links or FT-1 blocks)
including terminal identification.
p) All circuit elements and components, with device
designation, rating and setting where applicable.
Coil voltage is shown only if different from nominal
control voltage.
q) Size, type, rating and designation of all fuses.
3. CURRENT SCHEMATIC
NOTE: This drawing is a primary three line and shall
contain the following information:
D12
a) Relay functional designation per latest ANSI
Standard. The same functional designation shall be
used on all drawings showing the relay.
b) Terminal designations of all devices - relay coils
and contacts, switches, transducers, etc.
c) Numbers or wire designations for all cable
connections.
d) Phases shall be designated as A, B, C, N and rotation
(sequence) indicated as ABC or CBA.
e) Switch developments and escutcheons shall be shown on
the drawing where the majority of contacts are used.
Where contacts of a switch are used on a separate
drawing, that drawing shall be referenced adjacent to
the contacts in the switch development. Any contacts
not used shall be referenced as spare. All switch
developments shall include the manufacturer name,
complete style number and notations indicating spring
return to normal operation, where appropriate.
f) Auxiliary relay contacts shall be referenced to the
coil location drawing if coil is shown on a separate
drawing. Switch contacts shall be referenced to the
switch development drawing if development is shown on
a separate drawing.
g) Current transformers (CT) - polarity marks, rating,
tap, ratio and connection.
h) Auxiliary CT ratios, connection, winding current
rating and arrows to indicate assumed current flow.
I) Grounding of cables, CT's, etc.
j) Isolating points (States links, test switches, etc.).
k) Complete relay type, manufacturer, style number and
relay range.
l) All circuit elements and components, with device
designation, size, rating and setting where
applicable.
4. POTENTIAL SCHEMATIC
This drawing is a primary three line SCHEMATIC with only
switching devices shown and shall contain the following
information:
a) Terminal designations of all devices - relay coils
and contacts, switches, transducers, etc.
b) Relay functional designation - per latest ANSI
Standard. The same functional
D13
designation shall be used on all drawings showing
the relay.
c) Complete relay type, manufacturer, style number and
relay range.
d) Numbers or wires designations for all cable
connections.
e) Phases shall be designated as A, B, C, N and rotation
(sequence) indicated as ABC or CBA.
f) Auxiliary relay contacts shall be referenced to the
coil location drawing if coil is shown on a separate
drawing. All contacts of auxiliary relays shall be
shown with each referenced to the appropriate
drawing.
g) Switch developments and escutcheons shall be shown on
the drawing where the majority of contacts are used.
Where contacts of a switch are used on a separate
drawing, that drawing must be referenced adjacent to
the contacts in the switch development. Any contacts
not used shall be referenced as spare. All switch
developments shall include the manufacturer name,
complete style number and notations indicating spring
return to normal operation, when appropriate.
h) Switch contacts shall be referenced to the switch
development drawing if development is shown on a
separate drawing.
I) All switch contacts are to be shown in the open
position, and labeled to indicate closed position(s).
j) Explanatory notes defining switch coordination and
adjustment where misadjustment could result in
equipment failure.
k) Ranges of all timers, and setting if dictated by
control logic.
l) Isolating points (States links, test switches, etc.).
m) Grounding of cables, VTs, etc.
n) Potential transformers (PTs, VTs), nameplate ratio,
polarity marks, rating, primary and secondary
connections.
o) All circuit elements and components, with device
designation, rating and setting where applicable.
Coil voltage is shown for all auxiliary relays.
p) Size, type, designations of all fuses.
5. PANEL WIRING DRAWING
D14
NOTE: Wiring diagrams shall follow the physical equipment
layout. The following equipment must be identified on
this drawing.
a) Front view sketch with functional designation and
device type for all components and nameplates.
b) External cables, wire designations (number,
destination and drawing number). Each wire
designation shall be unique.
c) Terminal block location and number.
d) Equipment identification - functional designation and
device wiring designation (ratings shall appear by
components only when required for specific
identification and clarity).
e) Reference to relay internals, schematic, and
Instruction Book(s).
f) Current transformer tap ratio tables where
applicable.
g) Ground bus and connections.
h) Current circuits must be identified with asterisks.
i) Reference to switch developments.
j) Complete panel wiring details for all equipment
included on panel.
k) When external devices are connected to the protective
relaying cabinet, wiring drawings must be supplied
for those devices.
6. THREE-LINE DIAGRAM
This drawing must include all the equipment shown on the
one line diagram and all information necessary for correct
phasing.
a) Phases shall be designated as A, B, C, N and rotation
(sequence) indicated as ABC or CBA.
b) Both GPU Energy and Generation Facility phase
designations, rotation (sequence), as well as
necessary interconnections shall be designated.
c) Terminal numbers shall be identified for all primary
equipment (i.e., breakers, transformers, generators,
etc.) shown on the one-line diagram.
D15
d) Bushing designations shall be identified for all
circuit breakers and transformers.
L. PROTECTIVE RELAY TEST REQUIREMENTS
1. Commissioning as well as periodic and functional testing of
required fault protection (21 ZOS, 25, 50/51, 50/51G, 51N,
51V, 21, 62, 27, 59, 81, etc.) shall be performed and
documented by the Power Producer at intervals specified by
GPU Energy and to specifications established by the
manufacturer.
All required testing of the fault protection shall be
performed and certified by a qualified testing organization
acceptable to GPU Energy. See Attachment 3.
A maintenance and test log will be developed and maintained
by the Power Producer. This log will detail all maintenance
information recommended by the manufacturers and then
instruction manuals. This log will contain specific
information pertinent to the equipment maintained, e.g.
location, manufacturer, year, type, serial number, date and
type of test (functional trip test calibration test
results, etc.) and any corrective action taken due to
test/maintenance findings. This log shall be available for
inspection by GPU Energy at any reasonable time. Each year,
a letter indicating that all required testing and
maintenance has been completed with acceptable results
shall be submitted to GPU Energy. GPU Energy has the right
upon request to inspect all required protective equipment
associated with the Generation Facility's
interconnection(s).
2. GPU Energy shall reserve the right to specify settings of
all isolation devices which are part of the Generation
Facility's system.
3. GPU Energy shall require initial inspection and testing as
well as subsequent inspection and testing of the Generating
Facility's isolation and fault protection systems (27-62,
59-62, 81o, 81u-62, etc.) at the Generation Facility's
expense on an annual basis. All required testing shall be
performed and certified by a qualified testing organization
acceptable to GPU Energy (Attachment 3). GPU Energy
reserves the right to observe any tests performed.
Maintenance of these systems must be performed and
documented by the Power Producer at specified intervals to
the satisfaction of GPU Energy. GPU Energy shall reserve
the right to disconnect the Generation Facility and/or the
cogeneration equipment from the GPU system for failure to
comply with these inspections, testing and maintenance
requirements.
M. FINAL INTERCONNECTION APPROVAL
Final interconnection approval will be given upon:
1. Positive engineering review of the Generation Facility's
Electrical Plans (See Section C2).
2. Receipt of all information required in Section C1 in
triplicate.
3. Written certification from an approved relay testing
organization (Attachment 3) that all fault protection
relays have been successfully acceptance tested,
commissioned, set, and functionally trip tested.
X00
0. Settings, acceptance testing, commissioning and functional
trip testing of all Isolation Protection Relays shall have
been successfully completed by the relay testing
organization and approved by GPU Energy.
D17
Attachment 1
PROTECTION REQUIREMENTS
FIGURE
1 Generation Connected to System Voltages 34.5 kV Wye and Below
2 Generation Connected to System Voltages 34.5 kV Delta and Above
with Wye-Wye and Delta-Wye Transformer Connections
3 Generation Connected to System Voltages 34.5 kv Delta and Above
with Wye-Delta and Delta-Delta Transformer Connections
D18
FIGURE 1
Diagram of
Generation Connected to System Voltages
34.5 kV Wye and Below
D19
FIGURE 2
Diagram of
Generation Connected to System Voltages
34.5 kV Delta and Above
D20
FIGURE 3
Diagram of
Generation Connected to System Voltages
34.5 kV Delta and Above
D21
Attachment 2
GENERATOR DATA
FOR STABILITY CALCULATIONS
Machine MVA base for each machine: __________
__________
__________
Step-up transformer percent impedance and MVA base
_________ % R + J _________ % X _________ MVA
_________ % R + J _________ % X _________ MVA
Value* Description (for each machine)
----------- -------------------------------------------------------------------------------------
T'do (sec. 0)
----------
T'do (sec. 0)
----------
T'do (sec. 0)
----------
T'do (sec. 0)
----------
Inertia H Total Shaft Inertia (Turbine, exciter, generator)
----------
Speed Damping D If unavailable, program defaults to 0.0
----------
Xd
---------- -----------------------------------------
EXCITATION SYSTEM
Xq
Brand Name
---------- --------------------
Type
-------------------------
X'd
---------- -----------------------------------------
X'q
----------
X"d = X"q
----------
X1 If unavailable, program defaults to 0.05Xd
----------
S(1.0) Saturation values 1.0 p.u. voltage; if unavailable, program defaults to 0.11
----------
S(1.2) Saturation values 1.2 p.u. voltage; if unavailable, program defaults to 0.48
----------
* Xd, Xq, X'd, X'q, X"d, X"q, X1, H, and D are in p.u. machine base.
X"q must be equal to X"d.
D22
Attachment 3
ACCEPTED RELAY TESTING ORGANIZATIONS
GPU ENERGY
ABB Power T&D Company
Xxx Xxxx Xxxxx
Xxxx Xxxxxx, Xxxxxxxxxxxx 00000
Doble Engineering Company
00 Xxxxxx Xxxxxx
Xxxxxxxxx, Xxxxxxxxxxxxx 00000
General Electric Company
000 Xxxxx Xxxxxx Xxxxxxx
Xxxxxxx, Xxxxxxxxxxxx 00000
GPU Energy Company
0000 Xxxxxxxxxx Xxxx
Xxxx Xxxxxx Xxx 00000
Xxxxxxx, XX 00000-0000
MET Electrical Testing Company, Inc.
000 X. Xxxxxxxx Xxxxxx
Xxxxxxxxx, Xxxxxxxx 00000
Multi-Amp Corporation
0000 Xxxxxx Xxx
Xxxxxx, Xxxxx 00000
Addresses identified above are GPU Energy's regional contacts for relay
testing services. Other regional contacts may be more appropriate for
THE consulting engineer.
D23
REFERENCES
1. Guide for Interconnection Requirements and Parallel Operation of
Customer-Owned Generation Georgia Power Company - Electric
Operations Bulletin No. 51
2. Protection Requirements for Parallel Operation of Non-Utility
Generation, Pennsylvania Power & Light Company - Revision #5 dated
June 20, 1988
D24
APPENDIX E
INTERCONNECTION INSTALLATION AGREEMENT
BETWEEN
JERSEY CENTRAL POWER & LIGHT COMPANY
d/b/a GPU ENERGY
AND
AES RED OAK, L.L.C.
TABLE OF CONTENTS
ARTICLE TITLE OF ARTICLE PAGE NO.
------- ---------------- --------
I Scope of Work E2
II Schedule of Work E2
III Payment E3
IV Bonus/Liquidated Damages E4
V General Provisions E5
VI Notices E5
VII Authorization for Changes and
Approvals E6
VIII Entire Agreement E6
Attachment I Scope of Work
Attachment II Schedule of Work
Attachment III General Provisions
INTERCONNECTION INSTALLATION AGREEMENT
THIS AGREEMENT ("Installation Agreement"), entered into this 27th day
of April, 1999, between Jersey Central Power & Light Company d/b/a GPU Energy,
(hereinafter referred to as the "Company") and AES Red Oak, L.L.C., (hereinafter
referred to as "Power Producer"), collectively "Parties". The Parties
acknowledge that GPU Service, Inc., shall act as agent for the Company
concerning the administration of this Installation Agreement.
RECITALS
WHEREAS, Power Producer desires to build the Red Oak power plant and
interconnect with the Transmission System; and
WHEREAS, the Company is willing to design, furnish, install and own
certain facilities required to interconnect Power Producer's Facility with the
Transmission System, as more fully defined and described in the Generation
Facility Transmission Interconnection Agreement between the Parties ("Company
Interconnection Facilities").
WHEREAS, Power Producer has placed a high priority on the Schedule of
Work and desires that the Company accept Bonus/Liquidated Damages provisions
relating to this Installation Agreement.
WHEREAS, the Company is willing to accept Bonus/Liquidated Damages
provisions relating to this Installation Agreement.
NOW, THEREFORE, in consideration of the mutual representations,
covenants, promises and agreements hereinafter set forth, the Parties hereto,
intending to be legally bound, hereby covenant and agree as follows:
ARTICLE I - SCOPE OF WORK
The Company shall, in accordance with the provisions set forth herein,
provide all labor, supervision, materials and equipment necessary to perform the
interconnection installation as more fully described in Attachment I, attached
hereto and made a part hereof, entitled "Scope of Work".
ARTICLE II - SCHEDULE OF WORK
The Company shall use reasonable efforts to perform the Scope of Work
on a timely basis, completing the installation within 18 months of the date
Power Producer issues a notice to proceed, all in accordance with the milestone
schedule set forth in Attachment II, which is attached hereto and made a part
hereof, entitled "Schedule of Work". The Company and Power Producer shall
conduct monthly informational meetings to update the status of the project,
scheduled events in the upcoming months, all monies previously committed by
Company on behalf of the Power Producer's Project, and all monies to be
committed in the upcoming months. The Company will provide and update a list of
all interconnection equipment (as identified in Appendix B) already ordered, all
equipment received, the actual delivery date or estimated delivery date if still
outstanding, and the return/restocking fee prior to delivery. Notwithstanding
the foregoing, if the Power Producer does not issue a notice to proceed prior to
December 31, 1999, the Company shall be entitled to revise the milestone
schedule set forth in Attachment II by extending the date for completing the
installation by up to four (4) months, and adjusting the milestones accordingly,
as may be necessary to permit the completion of the installation consistent with
the maintenance and outage schedule approved by PJM for the Transmission System.
The Company agrees that if extension of the schedule or adjustment of the
milestones is necessary, as stated above, the Company will use all reasonable
E2
methods to mitigate the length of the extension. Furthermore, the Company will
not extend the schedules or adjust the milestones to achieve the bonus described
in Article IV of this Installation Agreement.
ARTICLE III - PAYMENT
Power Producer shall pay the Company for the actual costs of all
services performed by the Company, as specified in Attachment I - Scope of Work.
Costs shall include, but not be limited to, all labor charges, expenses,
materials and equipment charges, subcontractor costs, overheads and all
applicable permits, fees and sales, use or any other taxes.
Power Producer shall provide an advanced payment of $100,000 at the
time this Installation Agreement is executed, a second payment of $200,000 at
the time of the issuance of the notice to proceed, and a third payment of $1.7
million within 60 days of the notice to proceed. The Company agrees that it will
not exceed $200,000 in expenditures during said 60 day period. The total amount
shall be used by the Company during the execution of the work first to offset
AFUDC charges, then to offset the final invoiced costs.
The Company shall submit monthly invoices for work performed. Each
invoice shall include supporting documentation and shall state the dates of
performance covered by the invoice. Invoices in the final stages of the project
will be adjusted to credit for the application of advance payment.
Terms of payment shall be net 30 days from the date of invoice
issuance. Interest shall be assessed on payments received after their due date
at the interest rate applied to prime commercial loans then in effect at the
main office of Citibank N.A., located in New York, N.Y. or its successor,
calculated from the due date to the date of payment.
Power Producer may, at any time, assign its payment obligations in this
Installation
E3
Agreement to the purchaser of the output of the Red Oak facility. Power Producer
shall provide the Company with such notice of such assignment, identifying the
assignee. Following receipt of such notice, the Company shall direct its
invoices under this Installation Agreement to the assignee with a copy to Power
Producer. No such assignment, however, shall release or in any way discharge
Power Producer from the performance of its obligations (including any or all
payment obligations) under this Installation Agreement.
ARTICLE IV - BONUS/LIQUIDATED DAMAGES
If the actual completion date for the installation varies from the date
shown in the Schedule of Work Attachment II, the following provisions shall
apply:
1. If the actual completion date is later than the scheduled completion
date (i.e., 540 days from the notice to proceed), the Company will pay Power
Producer Liquidated Damages in the amount of $5,000 per day for each day by
which the installation of the work is not complete for up to and including 45
days.
2. If the actual completion date is earlier than the scheduled
completion date (i.e., 540 days from the notice to proceed), Power Producer will
pay the Company a Bonus for early completion in the amount of $5,000 per day for
each day by which the installation of the work is completed early, for up to and
including 30 days. It is understood by the Parties that the Company will utilize
overtime from time to time during the installation of the Interconnection
Facilities for the purpose of properly scheduling the work. Examples of this are
the use of overtime when working in active substations as required to minimize
the duration of substation outages or to complete work activities which are
better completed in one day rather than extending the work into a second day. It
is also understood by the parties that overtime is not intended to be used
purely for
E4
the benefit of accelerating schedule to achieve the Bonus. If overtime is used
for this purpose, the premium portion of overtime cost will be deducted from the
Bonus amount.
If it becomes apparent at any time that the Company will not complete
the installation of the work within 45 days after the scheduled completion date
(i.e., 540 days from the notice to proceed), and the Company cannot within 30
days (of the delay becoming known) propose a recovery plan reasonably acceptable
to Power Producer, then Power Producer shall have step in rights to complete the
work in accordance with Company's specifications and pursuant to Good Utility
Practice, provided that Power Producer can demonstrate that they could complete
more quickly than the Company.
ARTICLE V - GENERAL PROVISIONS
The terms and conditions contained in Attachment III, attached hereto
and made part hereof, entitled "General Provisions", dated March 18, 1999 shall
apply to all services performed under this Installation Agreement. The terms not
otherwise defined in the Installation Agreement shall have the meanings set
forth in the Generation Facility Transmission and Interconnection Agreement
between the Parties.
ARTICLE VI - NOTICES
Any notice required under this Installation Agreement shall be deemed
to have been given at the time it is received in writing by the party being
notified. The designees authorized to give and receive such notices are as
follows:
1. The Company designees authorized to give and receive such notices are
as follows:
Xxxxxxx X. Xxxxxxxxxx
Manager - Transmission Investment Planning
0000 Xxxxxxxxxx Xxxx
Xxxxxxx, XX 00000
Or Xxxx Xxxxxx Xxx 00000
Xxxxxxx, XX 00000-0000
E5
2. The Power Producer designees authorized to give and receive such
notices are as follows:
Xxxxx X. Xxxxxxxxx
Vice President
AES Red Oak, L.L.C.
0000 Xxxxx 00xx Xxxxxx
Xxxxxxxxx, XX 00000
ARTICLE VII - AUTHORIZATION FOR CHANGES AND APPROVALS
A. This Installation Agreement may not be amended or modified except by
a written instrument signed by each of the Parties hereto.
B. The Company designated representatives listed below are the only
persons authorized to bind the Company under this Installation Agreement,
including any written direction or amendment hereto:
Xxxxxx X. Xxxxxxx
VP - Engineering & Operations
ARTICLE VIII - ENTIRE AGREEMENT
This Installation Agreement, together with that certain Generation
Facility Transmission Interconnection Agreement between the Parties of even date
herewith, constitute the entire agreement between the Company and the Power
Producer with respect to the performance by the Parties of the interconnection
installation described herein. They supersede all prior or contemporaneous
communications, representations, or agreements, representations, statements, or
agreements other than those herein expressed, whether oral or written, with
respect to the subject matter hereof and has been induced by no representations,
statements, or agreements other than those herein expressed.
E6
IN WITNESS WHEREOF, the Parties hereto have executed this Agreement by
the undersigned thereunto duly authorized as of the date first written above.
ATTEST: AES RED OAK, L.L.C.
BY: /s/ Xxxxxxx Xxxxxx BY: /s/ Xxxxx X. Xxxxxxxxx
---------------------------------- -------------------------------
TITLE: TITLE: VP
------------------------------- ----------------------------
DATE: DATE: 4-27-99
-------------------------------- -----------------------------
JERSEY CENTRAL POWER & LIGHT
COMPANY d/b/a GPU ENERGY
ATTEST:
BY: /s/ Xxxxxxx X. Xxxxxxxx By: /s/ X. X. Xxxxxxx
---------------------------------- ------------------------------
TITLE: TITLE: Vice-President
------------------------------- ----------------------------
DATE: DATE: April 27, 1999
-------------------------------- -----------------------------
Executed in duplicate.
E7
Attachment I
Page 1
INTERCONNECTION INSTALLATION AGREEMENT
SCOPE OF WORK
Services to be performed by the Company:
The Company will provide all labor, supervision, materials, equipment and tools
needed to design, furnish and install the Company Interconnection Facilities for
the Red Oak project. It is understood by the Parties, additional items for
interconnection and reinforcement may be identified, the interconnection
configuration may change, and the actual costs will differ from the estimated
costs shown below. In addition, it is understood by the Parties that the Power
Producer will pay for all actual costs incurred by the Company under this
installation Agreement.
AES RED OAK - RADIAL TAP
ITEM DESCRIPTION ESTIMATED COST
---- ----------- --------------
1 Transmission Tap $ 325,000
2 Terminals 4 @ $422,000 $1,688,000
3 New 230 kV Switching Station $2,569,000
4 Wave Trap at Freneau $ 38,000
5 Fiber Optic Line (4 miles) $ 200,000
SUB TOTAL $4,820,000
Return (8.64%) $ 416,448
TOTAL $5,236,448
Note: In developing this estimate no subsoil samples have been taken and
evaluated. If the subsoil proves unstable, steel pole foundation costs may
rise and increase the total cost.
Attachment II
Page 1
INTERCONNECTION INSTALLATION AGREEMENT
SCHEDULE OF WORK
GPU ENERGY COMMITMENTS:
INSTALLATION - MILESTONES
SUBSTATION NOTICE TO PROCEED DATE PLUS
---------- ---------------------------
Requisition Circuit Breakers 47 DAYS
Complete Design & Engineering 309 DAYS
Finish Foundations 324 DAYS
Receive Materials 331 DAYS
TAP INTERCONNECTION
-------------------
Complete Design & Engineering 272 DAYS
Finish Foundations 345 DAYS
Receive Materials 391 DAYS
Complete Structures & Electrical Construction 451 DAYS
Provide those Company Interconnection Facilities 540 DAYS (18 MONTHS)*
necessary to permit the Power Producer to energize
the switchyard and commence commissioning of the
Facility.
*Completion of installation.
NOTES: 1) If the notice to proceed occurs after December 31, 1999, the
Company shall be entitled to extend the date for completing the
Scope of Work by up to four (4) months and adjust the milestones
accordingly.
2) The Power Producer must provide the area for the GPU Substation
in a final sub-grade condition ready for the start of
construction within seven (7) months of the issue of the notice
to proceed, plus provide an easement and continuous access to
that area and the area over which the transmission line travels
to the edge of the existing GPU right-of-way. Any delay on
behalf of the Power Producer will delay the Company in meeting
their commitment dates on a day-for-day basis.
Attachment III
Dated March 18, 1999
Page 1
INTERCONNECTION INSTALLATION AGREEMENT
GENERAL PROVISIONS
INSURANCE
The Company shall, at its sole expense, obtain and maintain in effect at
all times on and after the date hereof the insurance described below,
with insurers reasonably acceptable to Power Producer, and shall provide
Power Producer with evidence of such insurance upon request. All
insurance policies identified herein, except Worker's Compensation
Insurance, shall name the Power Producer as an additional insured:
(a) workers' compensation insurance in forms and within statutory limits
and employer's liability with limits of not less than $1,000,000;
(b) comprehensive general liability insurance (excluding automobile
liability) covering personal injury and property damage to third parties
and having a limit of not less than $1,000,000 per occurrence and
$1,000,000 in the aggregate; and
(c) automobile liability insurance covering owned and leased vehicles
used in the performance of services pursuant to this Installation
Agreement, covering personal injury and property damage to third parties,
with a limit of not less than $1,000,000 per occurrence.
LIMITATION OF LIABILITY
A. Notwithstanding any other provisions of this Installation Agreement, in
no event shall the Company nor its respective officers, directors,
partners, agents, employees or Affiliates, be liable to the Power
Producer or its Affiliates, officers, directors, partners, agents,
employees, successors or assigns, for claims for incidental, special,
indirect or consequential damages of any nature connected with or
resulting from performance or non-performance of this Installation
Agreement, including without limitation, claims in the nature of lost
revenues, income or profits or losses, damages or liabilities under any
financing, lending, construction, or maintenance contracts, agreements or
arrangements to which the Power Producer may be party irrespective of
whether such claims are based on warranty, negligence, strict liability,
contract, or operational loss or otherwise. Provisions of this Section A
shall survive the termination, cancellation, suspension or completion or
expiration of this Installation Agreement.
B. The total liability of the Company under this Installation Agreement for
all claims of any kind, whether based on contract, indemnity, warranty,
tort (including negligence), strict liability, duty to warn, or
otherwise, for all damages or losses relating to or resulting from the
performance of services by the Company pursuant to this Installation
Agreement, or the performance of or failure to perform the services
described more fully under
Attachment III
Dated March 18, 1999
Page 2
the Scope of Work within this Installation Agreement is limited to the
amount of money paid to the date of the claim. For purposes of this
Installation Agreement the Company includes Metropolitan Edison
Company, its parent and affiliates and officers, directors, employees,
representatives, associates, agents, successors and assigns of all such
companies. Also, the remedies expressed in this Installation Agreement
are the only remedies for any claims made in connection with this
Installation Agreement.
C. The provisions of this paragraph and any other provisions of this
Installation Agreement providing for limitation of or protection against
liability shall apply to the full extent permitted by law.
D. The provisions of this paragraph and any other provisions of this
Installation Agreement providing for limitation of or protection against
liabilities between the Parties hereto shall survive termination of this
agreement or completion of the work as described herein.
GRATUITIES
The Company prohibits their employees from using their official position
for personal financial gain, or from accepting any personal advantage from
anyone under circumstances which might reasonably be interpreted as an
attempt to influence the recipients in the conduct of their official
duties. Power Producer or its employees shall not, under circumstances
which might reasonably be interpreted as an attempt to influence the
recipients in the conduct of their duties, extend any gratuity or special
favor to employees of the Company.
CLAIMS/DISPUTES/GOVERNING LAWS
A. Any claim or dispute which either party may have against the other party,
arising out of this Installation Agreement or the Scope of Work, shall be
presented by the claimant in writing to the other party no later than
Thirty (30) Days after circumstances which give rise to the claim or
dispute have taken place. The claim or dispute shall contain a concise
statement of the question or dispute, together with relevant facts and
data to fully support the claims.
B. In the event of any such claim or dispute, the Parties shall use their
best effort to resolve the claim or dispute, initially, through good faith
negotiations or upon the failure of such negotiations, through Alternative
Dispute Resolution (ADR) techniques in accordance with the Model Procedure
for Mediation of Business Disputes as published by the Center for Public
Resources; provided however, that nothing therein contained shall prohibit
either party from terminating its participation in ADR during any stage of
ADR or if either party believes that the dispute is not suitable for ADR
techniques or if such techniques do not produce results satisfactory to
the Parties from proceeding in accordance with Paragraph C hereof.
C. If any claim or dispute arising hereunder is not resolved in accordance
with Paragraph B above, either party may, upon giving the other party at
least ten (10) days prior written notice, initiate litigation to submit
such
claims or disputes for decision by a court of competent jurisdiction of
the Commonwealth of Pennsylvania in accordance with and governed by the
laws of Pennsylvania.
Attachment III
Dated March 18, 1999
Page 3
ACCESS
The Power Producer will allow access to any premises under the Power
Producer's immediate control and obtain appropriate permission to allow
the Company's employees or subcontractor's access to premises not under
the Power Producer's control that the Company finds necessary to access in
order to perform the services more fully described herein.
WORKMANSHIP
A. The Company represents to the Power Producer that it will perform the
services as described in this agreement, in a good and workmanlike manner
and in accordance with all applicable laws, rules, regulations, orders and
policies.
B. POWER PRODUCER ACKNOWLEDGES THAT THERE ARE NO IMPLIED WARRANTIES FROM THE
COMPANY AND/OR WAIVES ANY WARRANTIES THAT MAY ARISE BY OPERATION OF LAW,
CUSTOM, USAGE, INCLUDING AMONG OTHER THINGS, THE IMPLIED WARRANTIES OF
MERCHANTABILITY AND FITNESS FOR A PARTICULAR PURPOSE.
C. Damages resulting from any and all causes whatsoever, including but not
limited to, breach of contract, breach of warranty, negligence, or strict
product liability, will be exclusively limited to this paragraph and the
Limitation of Liability paragraph contained herein.
