1
Exhibit 10.2
--------------------------------------------------------------------------------
PROJECT COMPLETION AGREEMENT
AMONG
CLOSED JOINT-STOCK COMPANY
"FOREST STARMA",
THE PIONEER GROUP, INC.,
INTERNATIONAL JOINT-STOCK COMPANY
"STARMA HOLDING"
AND
OVERSEAS PRIVATE INVESTMENT CORPORATION
DATED AS OF DECEMBER 21, 1995
--------------------------------------------------------------------------------
2
PROJECT COMPLETION AGREEMENT
TABLE OF CONTENTS
Page
Section 1. Definitions ...................................................1
Section 2. Interpretation ................................................2
Section 3. Project Completion ............................................2
Section 4. Nature of Obligations .........................................6
Section 5. Waiver ........................................................8
Section 6. Reinstatement of Guaranty .....................................8
Section 7. Payments Free and Clear of Taxes, Etc .........................8
Section 8. Representations and Warranties ................................9
Section 9. Covenants of the U.S. Sponsor ................................10
Section 10. Subrogation and Subordination ...............................11
Section 11. Payments ....................................................11
Section 12. Remedies; No Waiver .........................................12
Section 13. Arbitration ................... .............................12
Section 14. Time of Essence .............................................12
Section 15. Jurisdiction and Consent to Suit ............................12
Section 16. Arbitration .................................................12
Section 17. Successors and Assigns ......................................13
Section 18. Benefits of Agreement .......................................13
Section 19. Notices .....................................................14
Section 20. Governing Law ...............................................15
Section 21. Jury Trial Waiver ...........................................15
Section 22. Severability ................................................15
Section 23. Amendments ..................................................15
Section 24. Waiver of Litigation Payments ...............................15
Section 25. Indemnity ...................................................15
Section 26. Counterparts ................................................15
Section 27. Termination .................................................16
3
PROJECT COMPLETION AGREEMENT
PROJECT COMPLETION AGREEMENT ("Agreement"), dated as of December 21, 1995,
by and among CLOSED JOINT-STOCK COMPANY "FOREST STARMA", a joint stock company
of the closed type, organized and existing under the legislation of the Russian
Federation (the "Company"), THE PIONEER GROUP, INC., a corporation organized and
existing under the laws of the state of Delaware (the" U.S. Sponsor"),
INTERNATIONAL JOINT-STOCK COMPANY "STARMA HOLDING", a closed joint stock
company, organized and existing under the legislation of the Russian Federation
(the "Russian Sponsor") and OVERSEAS PRIVATE INVESTMENT CORPORATION, an agency
of the United States of America ("OPIC").
WITNESSETH:
----------
WHEREAS, the Sponsors together own beneficially and of record seventy-three
percent (73%) of the shares of capital stock of the Company and the U.S. Sponsor
owns beneficially additional shares of capital stock of the Company through its
32% holding of the capital stock of the Russian Sponsor;
WHEREAS, under a Finance Agreement with the Company, dated as of the date
hereof (the "Finance Agreement"), OPIC will guarantee a loan of up to $9,300,000
(the "Loan") to the Company upon condition, among other things, that the
Sponsors enter into and perform this Agreement;
WHEREAS, the Sponsors desire to induce OPIC to consent to the advance of the
Loan, and, therefore, are willing to cause the Company to achieve Project
Completion (as defined below) and in the interim to guarantee (on the terms set
forth herein) the Company's obligations and the repayment of the Loan; and
WHEREAS, all things have been done that are necessary to constitute this
Agreement a valid contract;
NOW, THEREFORE, in consideration of the premises and of the agreements
contained herein, it is hereby agreed as follows:
SECTION 1. DEFINITIONS.
(a) Terms of this Agreement beginning with capital letters shall have the
definitions given in the Finance Agreement, unless the context otherwise
requires or specifies.
4
-2-
(b) In addition, as used herein, the following terms shall have the
following meanings:
"COMPLETION CERTIFICATE" shall have the meaning ascribed thereto in Section
3(b)(vi).
"COMPLETION DATE" shall have the meaning ascribed thereto in Section 3(b).
"INDEMNIFIED PERSONS" shall have the meaning ascribed thereto in Section 24.
"NET OPERATING CASH FLOW" shall mean, during the relevant Fiscal Year, (1)
the aggregate of all gross revenues of the Company, plus (or minus) (2) any
net foreign exchange transaction gains (or losses) and any net capital gains
(or losses) realized by the Company, minus (3) the aggregate of (without
duplication): (a) operating costs of the Company; (b) interest, fees and
other amounts payable by the Company (other than amounts payable on the OPIC
Loan), including transfers by the Company to the Cash Collateral Account;
(c) interest payable by the Company with respect to capital leases or
similar arrangements; (d) Taxes payable by the Company; (e) fees and
commissions payable by the Company, pursuant to applicable laws, in
connection with any mandatory conversion of Dollars or other currencies into
Roubles or re-conversion of such Roubles into Dollars or other currencies
(and unavoidable currency exchange losses in connection with such
re-conversion), all in the ordinary course of business and at the optimal
exchange rate.
"PCA CALL" shall have the meaning ascribed thereto in Section 3(c)(i).
"PCA CALL AMOUNT" shall have the meaning ascribed thereto in Section
3(c)(i).
"PCA SUBORDINATED LOAN" shall have the meaning ascribed thereto in Section
3(d).
"POSITIVE CASH FLOW" shall mean, with respect to a Fiscal Year, a positive
Net Operating Cash Flow.
"PROJECT COMPLETION" shall have the meaning ascribed thereto in Section
3(b).
"SPONSORS" means the U.S. Sponsor and the Russian Sponsor, together, and the
term "Sponsor" means either of the U.S. Sponsor or the Russian Sponsor,
individually.
"TEST" shall have the meaning ascribed thereto in Section 3(b)(ii)(A).
5
-3-
SECTION 2. INTERPRETATION.
The rules of interpretation for this Agreement and the Exhibits hereto set
forth in Section 1.02 of the Finance Agreement shall apply mutatis mutandis to
this Agreement and the Exhibits hereto as if set forth in full in this Section
2.
SECTION 3. PROJECT COMPLETION.
(a) SPONSORS' OBLIGATIONS. Subject to the terms and conditions hereof, each
of the Sponsors hereby agrees, jointly and severally, (i) to cause the Company
to fulfill all of the requirements needed to achieve Project Completion, (ii) up
to the Completion Date, to unconditionally and irrevocably guarantee the payment
of all of the Company's financial obligations as they become due and payable,
including, without limitation, the Company's obligations under the Finance
Agreement and the Notes, and (iii) upon a PCA Call from OPIC at any time or from
time to time prior to the Completion Date, to make payment in full of the PCA
Call Amount demanded from the Sponsors under the terms and conditions specified
herein.
(b) PROJECT COMPLETION DEFINED. "PROJECT COMPLETION" shall be deemed to mean
and to occur on the date (the "COMPLETION DATE") that OPIC notifies the Sponsors
and the Escrow Agent that the following conditions have been accomplished to the
reasonable satisfaction of OPIC as of the date of the Completion Certificate:
(i) PHYSICAL COMPLETION TESTS: all buildings, jetties, equipment,
physical facilities, and necessary infrastructure for the Project shall have
been procured, constructed, and installed utilizing first-class standards of
workmanship and materials and in accordance with the Project plans and
specifications, shall be operational and in good working condition, and shall
meet manufacturers' specifications and the terms of applicable construction
agreements;
(ii) OPERATIONAL COMPLETION TESTS: following commencement of its timber
logging operations and the giving of notice to OPIC by the Company of the date
of commencement of a time period (the "Test Period"), the Company shall have
achieved one of the following tests:
(A) during a Test Period of 90 consecutive days, the Company shall have
produced a minimum of 25,000 cubic meters of timber, shipped and invoiced the
timber to clients and deposited the proceeds therefrom in the Timber Proceeds
Account; or
(B) in the event that the Company has failed to meet the test set forth in
(A) above, after electing to continue the Test Period for an additional 90
consecutive days, the Company shall have produced, during a period of 180
consecutive days (including the initial 90 day period), a minimum of 55,000
cubic meters of timber from its operations, shipped and invoiced the timber to
clients and deposited the proceeds therefrom in the Timber Proceeds Account.
6
-4-
(iii) Legal conditions:
----------------
(A) the Company shall have valid surface rights to the forestry tract
covered by its cutting license, a valid Harvesting Plan, and valid leasehold
interests free and clear of all Liens and encumbrances (except for security
interests permitted by the Finance Agreement) to all of the land and all
buildings, equipment, and facilities referred to above, and to all other
facilities now or then known to be required for the Project;
(B) the Company shall have granted Liens in favor of OPIC with respect to
all of the assets required to be pledged pursuant to the Finance Agreement, and
in accordance with the requirements thereof;
(c) all obligations of any kind of the Company through the Completion Date,
including, without limitation, payment of all amounts at any time to become due
up to Project Completion under contracts for construction, procurement,
installation, and improvement of land, buildings, equipment, and facilities for
the Project shall,have been met or waived; and
(D) each Financing Document and each other document identified in the
Finance Agreement as being necessary for the Project, including all relevant
consents, licenses, approvals and authorizations shall be in full force and
effect, to the extent applicable;
(E) the Company shall have obtained all material consents, licenses,
approvals and authorizations necessary for execution of the Financing Documents
and for the construction and operation of the Project; all of which are listed
in Schedule 4.09 of the Finance Agreement and all of which have been obtained
as of the date hereof, with the exception of the following, which shall be
obtained prior to Project Completion:
A license under Article 18 of the Russian Law on Environmental
Protection dated December 19, 1991, and an environmental agreement with the
relevant regulatory authority at the local or regional level (it being
understood that at present no procedures exist whereby such a license or
agreement can be obtained but that the Company will be required to obtain such a
license and agreement if the relevant procedures are put in place by the
regional or local authorities).
(F) no Event of Default (or condition or event that, with the giving of
notice, or lapse of time, or both, could constitute an Event of Default) under
the Finance Agreement shall then exist;
(iv) Financial tests:
---------------
(A) the ratio of the Company's Current Assets to Current Liabilities shall
be no less than 1.5 to 1;
7
-5-
(B) the ratio of the Company's Indebtedness to Adjusted Net Worth shall not
exceed 1.857 to 1;
(c) the Company shall have an Debt Service Ratio of at least 1.2 to 1; and
(D) the Company shall have made at least one principal repayment on the Loan as
and when due from cash flow generated from the Project;
(D) the Company shall have demonstrated a positive cash flow and a ratio of
Net Operating Cash Flow to net sales of at least 30% for a period of six
consecutive months (to be certified by an internationally recognized independent
accounting firm); and
(E) the Company shall have maintained the Cash Collateral Amount.
(v) ENVIRONMENTAL COMPLETION TESTS: The IEAC (as defined in the Finance
Agreement) shall have certified the compliance of the Project and the Company's
Harvesting Plan with Schedule 5.12 of the Finance Agreement, in accordance with
and as set forth in the Finance Agreement.
(vi) COMPLETION CERTIFICATE DELIVERY: (A) the U.S. Sponsor shall have
furnished OPIC with a certificate substantially in the form of Exhibit A (the
"COMPLETION CERTIFICATE") certifying on behalf of the Sponsors that each of the
requirements set forth in clauses (i) through (v) above has been satisfied as of
the date of the Completion Certificate; and
(B) following receipt of the Completion Certificate, OPIC
shall have determined that each of the requirements set forth in clauses (i)
through (vi) above has been satisfied and shall have so notified the Sponsors in
writing; PROVIDED, HOWEVER, that:
(1) OPIC may require confirmation, at the Sponsors' reasonable expense, of
any provision of such Completion Certificate, including by requesting delivery
to OPIC of an independent consultant's report or an opinion of counsel
satisfactory to OPIC; and
(2) OPIC shall have the right to make reasonable requests for additional
information or documents from the Sponsors to substantiate the accuracy or
completeness of the Completion Certificate.
Unless within ninety (90) days following receipt by OPIC of the Completion
Certificate, OPIC notifies the U.S. Sponsor that either OPIC objects to the
Completion Certificate or that such Certificate is inaccurate or incomplete and
sets forth the basis for such objection or determination, as the case may be,
OPIC shall be deemed to have notified the U.S. Sponsor that Project Completion
and the Completion Date occurred on the last day of such ninety (90)-day period.
(c) Calls for Completion Funds.
--------------------------
8
-6-
(i) If, from time to time, prior to the Completion Date, in the opinion
of OPIC, the Company has insufficient funds to achieve Project Completion or to
meet its obligations as they become due and payable, whether at stated maturity,
by acceleration or otherwise (including, without limitation, all obligations due
under or with respect of the Finance Agreement or the Notes, and any expenses
(including reasonable attorneys' fees and expenses) incurred by OPIC in
enforcing any rights under this Agreement), OPIC shall have the right to give
written notice (each such notice shall be referred to herein as a "PCA CALL") to
both of the Sponsors demanding payment of the amount of such deficiency (the
"PCA CALL AMOUNT").
(ii) Each of the Sponsors, jointly and severally, agrees that it shall
make payment, or cause payment to be made, no later than ten (10) Business Days
following the date of a PCA Call sent to it, of the full PCA Call Amount
demanded from it in Dollars in immediately available funds.
(iii) Payment of any PCA Call Amount shall be made as directed by OPIC
in the PCA Call, whether to OPIC, or to the Company, or for application to any
other obligations of the Company as OPIC may specify in its sole discretion. The
Company hereby authorizes OPIC to establish an escrow account, if OPIC in its
reasonable judgment and in good faith considers it necessary, on the Company's
behalf, at a financial institution selected by OPIC for receipt of such funds to
be advanced by any Sponsor, and each Sponsor agrees, if so directed by OPIC, to
deposit the funds to be advanced by it in such escrow account. The Company
hereby irrevocably authorizes and directs OPIC to charge from time to time such
escrow account for amounts deemed necessary or desirable by OPIC, in its sole
discretion, to be expended to cause the Company to achieve Project Completion or
pay any or all debts or liabilities of the Company, including without
limitation, principal, interest, or other amounts due under the Finance
Agreement or the Notes, which have become due and payable (by stated maturity,
acceleration, or otherwise) prior to the Completion Date or to protect OPIC's
Liens. The Company hereby grants OPIC an irrevocable Power of Attorney, coupled
with an interest, to execute all checks, drafts, receipts, instruments,
instructions, or other documents to establish and operate such escrow account.
The Sponsors and the Company agree that OPIC shall not incur any liability in
connection with or arising from its exercise of such Power of Attorney or of the
rights assigned to OPIC pursuant to this paragraph.
(d) Investment of Funds.
-------------------
(i) Each advance of funds directed by OPIC to be made to the Company
hereunder by a Sponsor shall be a subordinated loan (a "PCA SUBORDINATED LOAN").
(ii) All PCA Subordinated Loans shall be subject to the terms of the
Subordination Agreement.
9
-7-
(iii) An advance under a PCA Subordinated Loan shall be: (A) evidenced
by promissory notes or other documents or agreements of the Company satisfactory
to OPIC making express reference to this Agreement and to the subordination
provisions of the Subordination Agreement and dated the date of such advance;
(B) shall be repayable in accordance with the terms of the Subordination
Agreement; (c) shall bear interest, which shall be payable subject to the
provisions of the Subordination Agreement; and (D) shall be junior and
subordinate in right of payment and in liquidation to the prior payment in full
of all amounts due or to become due under the Finance Agreement or the Notes, as
set forth in the Subordination Agreement.
(v) Each of the Sponsors and the Company hereby agree to take all
actions and execute all documents required by OPIC to implement each PCA
Subordinated Loan in accordance with this Agreement.
SECTION 4. NATURE OF OBLIGATIONS.
(a) The obligations of the Sponsors under this Agreement are joint and
several, direct, absolute, unconditional, and irrevocable and shall not to any
extent or in any way be reduced, limited, terminated, discharged, impaired, or
otherwise affected by any of the following:
(i) the Company's failure to pay a fee or provide other consideration
to the Sponsors in consideration of its entering into this Agreement;
(ii) the invalidity, lack of regularity, or unenforceability of any PCA
Call or the absence of any action to enforce the same (except to the extent that
such invalidity, or unenforceability arises is the result of a failure by OPIC
to fulfill its obligations under the OPIC Guaranty);
(iii) the occurrence or continuance of any Event of Default under the
Finance Agreement or the Notes or any acceleration or required prepayment of the
Indebtedness of the Company under or in respect of the Finance Agreement or the
Notes as a result thereof or otherwise;
(iv) any lack of validity or enforceability of, or any
misrepresentation, irregularity, or other defect in, the Finance Agreement, the
Notes, or any other agreement entered into in connection therewith;
(v) any failure by OPIC to take any steps to preserve its rights to any
Lien or in any Security Document securing the Loan, or any failure by OPIC to
perfect or keep perfected its Liens in any collateral relating to the Loan, the
Finance Agreement, or the Notes;
(vi) any right, claim or defense, waiver, surrender, or compromise that
any Sponsor may have under or in respect of this Agreement or otherwise;
10
-8-
(vii) any failure to pay Taxes that may have been payable in respect of
the issuance or transfer of the Notes or to register the same with any
governmental agency or instrumentality or to obtain any governmental order,
license, or permit in connection with such issuance or transfer;
(viii) any modification or amendment (whether material or otherwise)
of, or waiver, or consent, or other action taken with respect to, the Finance
Agreement, the Notes, or any other agreement or document delivered pursuant to
the terms of the Finance Agreement, including, without limitation, any
forbearance, indulgence in, or extension of time for the payment by the Company
of any amount payable under or in connection with the Finance Agreement, or any
Note, or for the performance of any of the other obligations of the Company
thereunder (any of which modifications, amendments, waivers, or consents may be
agreed to or granted without the approval or consent of the Sponsors);
(ix) any law, regulation, decree, or judgment now or hereafter in
effect which may in any manner affect any of the Company's obligations under the
Finance Agreement or any Note or any of OPIC's rights thereunder, whether or not
the Company has a defense valid against OPIC and whether or not other guarantors
of such obligations, if any, contribute to such payments;
(x) the voluntary or involuntary liquidation, sale, or other
disposition of all or any portion of the Company's assets, or the receivership,
insolvency, bankruptcy, reorganization, or similar proceedings affecting the
Company or its assets, or the release or discharge of the Company from any of
its obligations under the Finance Agreement, or any Note, or the consolidation
or merger of the Company;
(xi) the recovery of any judgment against any Sponsor or any action to
enforce the same, the insolvency or bankruptcy of any Sponsor, or any discharge,
stay, injunction, or modification of the obligation to pay a PCA Call;
(xii) any change of circumstances, whether or not foreseeable, and
whether or not any such change does or might vary the risk of any Sponsor
hereunder; or
(xiii) any other circumstances, whether similar or dissimilar to the
foregoing, that might otherwise constitute a defense available to, or a legal or
equitable discharge of, a Sponsor in respect of any of its obligations under
this Agreement, the Company, or any guarantor or surety of any of their
respective obligations under any of the Financing Documents.
(b) This Agreement is a guaranty of payment and not of collection. OPIC may
require payment by the Sponsor jointly and severally and enforce the obligations
of the Sponsors hereunder without first being required to:
11
-9-
(i) enforce OPIC's claims against the Company, any Sponsor
individually, or any other Person, firm, corporation, governmental authority, or
other entity; or
(ii) resort to any security or other guaranty for the Loan or the PCA
Call Amount; or
(iii) take any action except as provided in Section 3(c)(i) prior to
receiving payment hereunder.
(c) Notwithstanding anything to the contrary in this Agreement, each Sponsor
agrees that OPIC may, at any time and from time to time, either before or after
the maturity of the Loan, without notice to or further consent of such Sponsor,
extend the time of payment of, exchange, or surrender any collateral for, or
renew the Loan, and that OPIC may also make any agreement with the Company, the
other Sponsor, or with any other party to or Person liable on the Loan or
interested therein, for the extension, renewal., payment, compromise, discharge
or release thereof, in whole or in part, or for any modification; Waiver,
discharge, release, or settlement of the terms thereof or of any agreement
between OPIC, the Company, and/or the other Sponsor (including, without
limitation, this Agreement) or any other party or Person, without in any way
impairing or affecting the obligations and liabilities of such Sponsor under
this Agreement or requiring the written agreement or consent of such Sponsor and
the Company, as the case may be.
SECTION 5. WAIVER.
Each Sponsor hereby unconditionally waives presentment, demand, diligence,
filing of claims with a court in the event of insolvency or bankruptcy of the
Company, and any right to require a proceeding first against any Sponsor or the
Company, and waives protest, notice (including notice of default of the
Company), and all demands whatsoever of any kind to which such Sponsor might
otherwise be entitled under applicable law with respect to the PCA Call Amounts.
Each Sponsor hereby unconditionally agrees that its guaranty hereunder will not
be discharged except by complete performance of the obligations contemplated
under Section 3 or payment in full of all amounts due and to become due under
the Finance Agreement or the Notes. Each Sponsor also waives all notices of the
existence, creation, or incurring of any new or additional Indebtedness by the
Company under the Financing Documents.
SECTION 6. REINSTATEMENT OF GUARANTY.
The payment obligations of the Sponsors pursuant to this Agreement shall
remain in full force and effect or shall be reinstated, as the case may be, if
and to the extent that at any time any payment by the Company of any amount due
and guaranteed hereunder is rescinded or must be returned, in whole or in part,
in case of the bankruptcy, insolvency, or reorganization of the Company or
otherwise, as if such payment had never been made by the Company.
12
-10-
SECTION 7. PAYMENTS FREE AND CLEAR OF TAXES, ETC.
Any and all sums payable by a Sponsor hereunder shall be paid in full, free
of any deductions or withholdings for any and all present and future Taxes. If a
Sponsor shall be required by law to deduct any Taxes from or in respect of any
sum payable to OPIC (i) the sum payable shall be increased as may be necessary
so that after making all required deductions OPIC receives an amount equal to
the sum it would have received had no such deductions been required, (ii) such
Sponsor shall make such deductions, and (iii) such Sponsor shall pay the full
amount deducted to the relevant taxation authority or other authority in
accordance with applicable law. If OPIC pays any Taxes, such Sponsor, or at the
option of the other Sponsor, the other Sponsor, shall, upon demand from OPIC,
promptly reimburse OPIC in full for such payments.
SECTION 8. REPRESENTATIONS AND WARRANTIES.
A. Each Sponsor represents and warrants to OPIC that:
(a) As of the date hereof, the Sponsors own of record and beneficially, 73 %
(seventy-three percent) of the issued and outstanding shares of capital stock of
the Company and the U.S. Sponsor owns beneficially additional issued and
outstanding shares of capital stock of the Company through its 32% holding of
the capital stock of the Russian Sponsor.
(b) It is a corporation duly organized, validly existing, and in good
standing under the laws of its jurisdiction of incorporation referred to in the
introductory paragraph of this Agreement, and has all requisite power and
authority, corporate, partnership or otherwise, to execute, deliver and perform
this Agreement in accordance with the terms hereof.
(c) All necessary corporate actions to authorize its execution, delivery,
and performance of this Agreement have been taken.
(d) This Agreement has been duly executed and delivered by it and
constitutes its legal, valid, and binding obligation enforceable against it in
accordance with the terms hereof, except as the enforceability hereof may be
limited by bankruptcy, insolvency, reorganization, or other similar laws
affecting the enforcement of creditors' rights generally or general principles
of equity (regardless of whether such enforcement is considered in a proceeding
in equity or at law).
(e) All governmental approvals that are necessary for the execution and
delivery by it of this Agreement and the performance of its obligations
hereunder have been duly obtained and are in full force and effect.
13
-11-
(f) Neither it nor any of its properties has any immunity (or right to claim
that it has any immunity) from the jurisdiction of any court or from any legal
process (whether through service, notice, attachment prior to judgment,
attachment in aid of execution, or otherwise).
(g) The execution, delivery, and performance by it of this Agreement do not
require the consent or approval of any of its creditors and will not conflict
with or constitute a breach or default under or violate any provision of its
Charter Documents or any agreement, law, rule, regulation, order, writ,
judgment, injunction, decree, determination, or award applicable to it.
(h) Each representation and warranty made by the Company to OPIC in the
Finance Agreement is, to the knowledge of the Sponsor, true and correct in all
material respects, and all material constituting the Application is true and
correct in all material respects and accurately and completely describes the
business and financial prospects of the Company and does not contain any
material misstatement of fact or omit to state any material fact necessary to
make the statements contained therein, in light of the circumstances under which
they were made, not misleading.
(i) No Event of Default, and no event or condition that with the passage of
time or the giving of notice, or both, could constitute an Event of Default
under the Finance Agreement or under any agreement or instrument evidencing any
Indebtedness of the U.S. Sponsor that gives the holder thereof the right to
accelerate payment of such Indebtedness prior to its scheduled maturity, has
occurred and is continuing, and no such event will occur upon its execution,
delivery, or performance of this Agreement.
(j) No action, suit, other legal proceeding, arbitral proceeding, or
investigation is pending by or before any domestic or foreign court or
governmental authority or in any arbitral or other forum, or, to its knowledge,
is threatened, against it or any of its properties or rights that (i) relates to
any of the transactions contemplated by this Agreement or any other Financing
Document, or (ii) has, or if adversely determined is reasonably likely to have,
a Material Adverse Effect.
B. The U.S. Sponsor represents and warrants to OPIC that:
(a) Its balance sheet as at December 31, 1994, and the related statement of
its income and retained earnings for the fiscal year then ended, certified by
independent public accountants, copies of which have been furnished to OPIC,
fairly present in all material respects the financial condition of the U.S.
Sponsor as at such date and the results of its operations for the period ended
on such date, all in accordance with U.S. GAAP, and since such date, there has
been no change in its financial condition that is reasonably likely to have a
Material Adverse Effect.
14
-12-
(b) Since the date of the U.S. Sponsor's most recent Financial Statements
delivered to OPIC hereunder, there has been no change in its financial condition
from that set forth in such Financial Statements that is reasonably likely to
have a Material Adverse Effect.
SECTION 9. COVENANTS OF THE SPONSORS.
Unless OPIC otherwise agrees in writing each Sponsor covenants and agrees,
until the Completion Date, as follows:
(a) Each Sponsor shall promptly notify OPIC of each event that constitutes,
or which with the lapse of time or the giving of notice or both could
constitute, an Event of Default under the Finance Agreement, and of the
occurrence of any other condition or event that is reasonably likely to have a
Material Adverse Effect.
(b) The U.S. Sponsor shall, upon request of OPIC, give, or cause to be given
to, any representatives of OPIC access during normal business hours, and permit
them to examine, copy, and make extracts from, any and all records and documents
in the possession or subject to the control of such Sponsor relating to its
operations and financial affairs in connection with the Project.
(c) The U.S. Sponsor shall furnish to OPIC on or before the 60th day after
the close of each quarter of each of its fiscal years, its consolidated and
consolidating balance sheets as at the close of such quarter and its income
statement and statement of changes in financial position for such quarter,
prepared in accordance with U.S. GAAP, certified by its chief financial officer
as being complete and correct and fairly presenting the financial condition of
the U.S. Sponsor as at the close of such quarter and the results of its
operations for such quarter.
(d) The U.S. Sponsor shall furnish to OPIC on or before the 100th day after
the end of each of its fiscal years, its consolidated and consolidating balance
sheets as at the close of such fiscal year and its income statement and
statement of changes in financial position for such fiscal year, prepared in
accordance with U.S. GAAP, certified by a xxxx of independent accountants
(selected by it and acceptable to OPIC) as fairly presenting the financial
condition of the U.S. Sponsor as at the close of such fiscal year and the
results of its operations for such fiscal year.
(e) Each Sponsor agrees to vote or to cause to be voted all of the shares of
the Company presently held by it, as well as any other shares that it may
directly or indirectly acquire or control in the future, in such manner, and
take or cause to be taken any actions, corporate or otherwise, as shall be
necessary to achieve the prompt and effective implementation and performance of
all of the provisions of this Agreement.
(f) The U.S. Sponsor shall furnish to OPIC from time to time such other
statements and information as OPIC may reasonably request.
15
-13-
SECTION 10. SUBROGATION AND SUBORDINATION.
Until all amounts .due or that may become due under or in respect of the
Finance Agreement or the Notes have been paid in full, all PCA Subordinated
Loans shall be subject to the provisions of the Subordination Agreement. In the
event that a Sponsor receives any payment or distribution from the Company with
respect to such interest in contravention of the Subordination Agreement or this
Agreement, such Sponsor shall hold such payment or distribution in trust (as
property of OPIC) and immediately pay over such amount or deliver to OPIC (with
any necessary endorsement), such payment for application against the Loan.
SECTION 11. PAYMENTS.
Any payments hereunder directed by OPIC to be paid (a) to OPIC, shall be
paid to OPIC at the address set forth in Section 2.10(b) of the Finance
Agreement, and for application in accordance with Section 2.10(d) of the Finance
Agreement, or (b) to the Company, shall be made at the address set forth in
Section 18 hereof, or (c) to any other Person, shall be paid as OPIC may
otherwise direct in the PCA Call.
SECTION 12. REMEDIES; NO WAIVER.
(a) OPIC may proceed to protect and enforce its rights hereunder in any
court or other tribunal by an action at law, suit in equity, or other
appropriate proceedings, whether for damages, for the specific performance of
any term hereof, or otherwise, or in aid of the exercise of any power granted
hereby or by law. Each Sponsor hereby agrees, jointly and severally, to pay to
OPIC on demand such amount in Dollars as shall be sufficient to cover OPIC's
reasonable costs and expenses of any action or such remedies, including, without
limitation, reasonable attorneys' fees, expenses, and disbursements.
(b) No failure or delay by OPIC in exercising any right, power or remedy
shall operate as a waiver thereof or otherwise impair any of its rights, powers,
or remedies. No single or partial exercise of any such right shall preclude any
other or further exercise thereof or the exercise of any other legal fight. No
waiver of any such fight shall be effective unless given in writing.
(c) The rights or remedies provided for herein are cumulative and are not
exclusive of any other rights, powers, or remedies provided by law. The
assertion or employment of any right or remedy hereunder, or otherwise, shall
not prevent the concurrent assertion of any other appropriate right or remedy.
SECTION 13. TIME OF ESSENCE.
The parties hereto agree that time shall be of the essence of this
Agreement.
16
-14-
SECTION 14. JURISDICTION AND CONSENT TO SUIT.
(a) Without prejudice to the rights of OPIC to bring suit in any appropriate
domestic or foreign jurisdiction, any proceeding to enforce this Agreement may
be brought by OPIC in any state or federal court of competent jurisdiction in
the District of Columbia of the United States of America or in any other
jurisdiction where a Sponsor or any of its property may be found. Each Sponsor
hereby irrevocably waives any present or future objection to any such venue, and
irrevocably consents and submits unconditionally to the non-exclusive
jurisdiction for itself and in respect of any of its property of any such court.
Each Sponsor hereby further irrevocably waives any claim in any such court that
any such action, suit, or proceeding brought therein has been brought in an
inconvenient foram. Each Sponsor further agrees that final judgment against it
in any such action or proceeding arising out of or relating to this Agreement
shall be conclusive and may enforced in any other jurisdiction within or outside
the United States of America by suit on the judgment, a certified or exemplified
copy of which shall be conclusive evidence of the fact and of the amount of its
obligation.
(b) Prior to the fast Closing Date, each Sponsor shall irrevocably designate
and appoint an agent satisfactory to OPIC for service of process in the District
of Columbia as its authorized agent to receive, accept, and acknowledge on its
behalf service of process in any such proceeding, and shall provide OPIC with
evidence of the prepayment in full of the fees of such agent. Each Sponsor
agrees that service of process upon said agent shall be deemed and held in every
respect to be effective personal service upon it. Each Sponsor shall maintain
such appointment (or that of a successor satisfactory to OPIC) continuously in
effect at all times while the Company is obligated under the Finance Agreement
or any Note. Nothing herein shall affect OPIC's right to serve process in any
other manner permitted by applicable law.
SECTION 15. ARBITRATION.
(a) ARBITRATION: RULES: VENUE: LANGUAGE. Any dispute, controversy, or claim
arising out of, or relating to, or in connection with, this Agreement, and any
dispute concerning the scope of this arbitration clause, may, at the option of
OPIC and upon written notice to the Company and the Sponsors, be referred to for
final settlement by arbitration. Such arbitration proceedings shall be conducted
in accordance with the International Arbitration Rules of the International
Chamber of Commerce ("ICC") in effect on the date on which the arbitration
commences (the "RULES"). The seat of the arbitration shall be the City of New
York, New York, unless OPIC directs that the place of arbitration shall instead
be Washington, D.C. The arbitration shall be conducted in the English language.
Upon the Company's and the Sponsors' receipt of a notice from OPIC of its
election to settle by arbitration any dispute, controversy or claim pursuant to
this Section 7.15, the Company and the Sponsors shall be obligated to settle
such dispute, controversy or claim as provided in this Section 15. If any
dispute, controversy or claim is referred to arbitration by
17
-15-
OPIC, the Company and the Sponsors hereby agree to the jurisdiction of the
arbitral panel with respect to such dispute, controversy or claim to the
exclusion of the courts of the Russian Federation or any other jurisdiction.
(b) ARBITRATORS: SELECTION: QUALIFICATIONS. The arbitration shall be
conducted by three arbitrators. OPIC shall appoint one arbitrator and the
Company and the Sponsors shall appoint one arbitrator, and each shall notify the
other of the name of its appointee within 60 days of the date of OPIC's notice
to the Company and the Sponsors. The two arbitrators appointed by OPIC and the
Company and the Sponsors shall together, within 60 days after the date on which
the first two arbitrators were required to be appointed, appoint the third,
presiding arbitrator. If OPIC and the Company and the Sponsors fail to appoint
any arbitrator within the time limits provided hereunder, such arbitrators shall
upon the written request of OPIC or the Company and the Sponsors, be appointed
by the President of the ICC. Each arbitrator shall be fluent in the English
language, shall be a disinterested person, and shall be an attorney qualified to
practice law in the State of New York or the District of Columbia for a minimum
of 5 years, with experience in representing lenders and borrowers in
international project finance lending to private sector borrowers. OPIC, the
Company or the Sponsors may, within 10 days of notice of an appointment,
challenge the appointment of an arbitrator as lacking the qualifications set
forth in the preceding sentence pursuant to the procedures prescribed by the
Rules. Any determination by the ICC as to qualifications shall be final and
binding and not subject to judicial review. If an arbitrator must be replaced
for any reason, the appointing party shall endeavour to appoint a substitute
arbitrator within a reasonable time.
(c) LAW. Each arbitral panel established hereunder shall make its decisions
entirely on the basis of this Agreement, the governing law provisions provided
herein or therein, and the Rules.
(d) STATEMENTS OF CLAIM AND DEFENSE: Representation: Proceedings. OPIC shall
communicate its statement of claim in writing to the Company and the Sponsors
and the arbitral panel within a period of time to be determined by the panel.
The Company and/or the Sponsors shall file a statement of defense in writing
following receipt of OPIC's statement of claim within a period of time to be
determined by the panel. The parties may be represented or assisted by legal
counsel of their choice. The arbitral panel shall determine a date on which it
shall commence taking evidence, which date shall not be less than 60 days after
the Company's and/or the Sponsors' submission of a statement of defense, unless
OPIC directs otherwise. Where the Rules do not provide for a particular
situation, the arbitral panel shall by a majority, in its absolute discretion,
determine the course of action to be followed and its decision shall be final.
(e) AWARDS. The arbitral panel shall issue a written decision and award
within 60 days after the conclusion of the relevant proceedings. Any award of
the arbitral panel shall be final and binding, and judgment upon any arbitral
award may be entered and enforced by any court or judicial authority of
competent jurisdiction. Any money award shall be made and shall be
18
-16-
payable in Dollars. The award shall be limited to the scope of the submission
and in no circumstance shall the arbitral panel render an award EX AEQUO ET XXXX
or as AMIABLE COMPOSITEUR. If either party wishes to submit a request that the
arbitral panel interpret the award or correct any clerical, typographical or
computation errors, or make an additional award as to claims presented but
omitted from the award, such request shall be submitted to the arbitral panel
and the other party within 10 days after the award. If the panel considers such
request justified, after considering the contention of the parties, the panel
shall promptly comply with such request. The arbitral panel, OPIC, the Company
or the Sponsors shall not be entitled to seek from any judicial authority or
take any interm measures or provide any preaward relief against OPIC, the
Company, or the Sponsors, notwithstanding any contrary provisions in the Rules.
(f) COSTS, FEES AND EXPENSES. Each party shall pay its own costs, fees and
expenses.
(g) NO WAIVER. In invoking any arbitration pursuant to this Section 15, OPIC
shall not be deemed to have waived any rights, immunities or privileges to which
it or any of its directors, officers or employees are entitled. By submitting to
arbitration, OPIC shall not be deemed to have Submitted to the jurisdiction of
any court other than the United States Court of Claims in Washington D.C.
SECTION 16. SUCCESSORS AND ASSIGNS.
This Agreement shall bind the successors and assigns of the Company and the
Sponsors and shall inure to the benefit of OPIC, its successors, and assigns.
Neither the Company nor any Sponsor may assign any of its obligations hereunder
without the prior written consent of OPIC or its successors or assigns.
SECTION 17. BENEFITS OF AGREEMENT.
Nothing in this Agreement, express or implied, shall give to any Person,
other than the parties hereto and their successors and permitted assigns
hereunder and under the Finance Agreement, any benefit or any legal or equitable
right or remedy under this Agreement.
SECTION 18. NOTICES.
Each notice, demand, report, or communication relating to this Agreement
shall be in writing in the English language, shall be hand-delivered or sent by
mail (postage prepaid), telegram, or facsimile transmission (with a copy by mail
to follow, which copy shall not be required to effect notice), and shall be
deemed duly given when sent to the following addresses, or to such other address
or number as each party shall have last specified by notice to the other
parties.
19
-17-
TO THE U.S. SPONSOR
The Pioneer Group, Inc.
00 Xxxxx Xxxxxx,
Xxxxxx, XX 00000-0000
(Attn: Xxxxxx Xxxxxx)
Facsimile: (000)000-0000
with a copy to Xxxxx Xxxxxxxxx, Esq.
Xxxx and Xxxx
Suite 1000
0000 Xxxxxxxxxxxx Xxxxxx, X.X.
Xxxxxxxxxx X.X. 00000
Facsimile: 0-000-000-0000
TO THE COMPANY
XX. XXXXXXXXX, 0
XXXXXXXXXX - XX - XXXXX
000000
RUSSIAN FEDERATION
(Attn: The President)
Facsimile: 0000-00000-00000
with a copy to:
Xxxxx Xxxxxxxxx, Esq.
Xxxx and Xxxx
Suite 1000
0000 Xxxxxxxxxxxx Xxxxxx, X.X.
Xxxxxxxxxx X.X. 00000
Facsimile: 0-000-000-0000
20
-18-
TO THE RUSSIAN SPONSOR
XX. XXXXXXXXX, 0
XXXXXXXXXX - XX - XXXXX
000000
RUSSIAN FEDERATION
(Attn: The President)
Facsimile: 0000-00000-00000
TO OPIC (Attn.: Vice President and Treasurer, with a copy to the Vice
President for Finance):
Overseas Private Investment Corporation
0000 Xxx Xxxx Xxxxxx, X.X.
Xxxxxxxxxx, X.X. 00000
Xxxxxx Xxxxxx of America
Facsimile: 0-000-000-0000
SECTION 19. GOVERNING LAW.
THIS AGREEMENT SHALL BE GOVERNED BY AND CONSTRUED IN ACCORDANCE WITH THE
SUBSTANTIVE LAWS OF THE DISTRICT OF COLUMBIA, UNITED STATES OF AMERICA, WITHOUT
REGARD TO THE CONFLICTS OF LAW RULES THEREOF.
SECTION 20. JURY TRIAL WAIVER.
The Sponsors and OPIC each hereby waives any right to have a jury
participate in resolving any dispute arising out of, in connection with, related
to, or incidental to the relationship established between them in connection
with this Agreement, any other financing document, or any other instrument,
document, or agreement executed or delivered in connection herewith or therewith
or the transactions related thereto.
SECTION 21. SEVERABILITY.
If any provisions of this Agreement shall be invalid, illegal, or
unenforceable in any jurisdiction, the parties hereto agree to the fullest
extent they may effectively do so that the validity, legality, and
enforceability of such provision in other jurisdictions, and the validity,
21
-19-
legality, and enforceability of the other provisions in such jurisdiction, shall
not in any way be affected or impaired thereby.
SECTION 22. AMENDMENTS.
The provisions hereof may be waived, supplemented, or amended only by an
instrument in writing signed by a duly authorized representative of each of the
parties hereto.
SECTION 23. WAIVER OF LITIGATION PAYMENTS.
In the event that any action or lawsuit is initiated by or on behalf of OPIC
hereunder against the Company, any Sponsor, or any other party to any Financing
Document, each Sponsor, to the fullest extent permissible under applicable law,
irrevocably waives its right to, and agrees not to request, plead, or claim that
an OPIC Plaintiff post, pay, or offer, any Litigation Payment, and each Sponsor
further waives any objection it may now or hereafter have to an OPIC Plaintiff's
claim that such OPIC Plaintiff should be exempt or immune from posting, making,
or offering any such Litigation Payment.
SECTION 24. INDEMNITY.
To the extent permitted by law, each Sponsor hereby indemnifies and holds
harmless OPIC and its directors, officers, employees, agents, counsel,
subsidiaries, and Affiliates (the "INDEMNIFIED PERSONS") from and against any
and all losses, liabilities, obligations, damages, penalties, actions,
judgments, suits, costs, expenses, or disbursements of any kind or nature
whatsoever that may be imposed on, incurred by, or asserted against any
Indemnified Person in any way relating to or arising out of this Agreement, the
Financing Documents, or any of them or any of the transactions contemplated
hereby or thereby; PROVIDED, HOWEVER, that (i) no Sponsor shall be liable to any
Indemnified Person for any losses, liabilities, obligations, damages, penalties,
actions, judgments, suits, costs, expenses, or disbursements that resulted from
the gross negligence or willful misconduct of such Indemnified Person and (ii)
to the extent that the loss, claim, damage, liability or other expense results
from a failure by OPIC to fulfill its obligations under the OPIC Guaranty.
Further, the Sponsors' indemnity obligations hereunder (i) shall not apply to
the extent that the loss, claim, damage, liability or other expense arises from
the Company's failure to pay its financial obligations under the Finance
Agreement (with the exception of fraud); (ii) shall not in the aggregate exceed
the amount of the loan; and (iii) shall end on the Project Completion Date.
22
- 20 -
SECTION 25. COUNTERPARTS.
This Agreement may be executed in separate counterparts, each of which when
so executed and delivered shall be deemed an original, and all of which together
shall constitute one and the same instrument.
SECTION 26. TERMINATION.
Notwithstanding anything in this Agreement or elsewhere to the contrary, the
obligations of the Sponsors hereunder shall terminate upon the earlier of the
Completion Date, or the date on which all principal, interest, fees, and
expenses due pursuant to the Finance Agreement or under the Notes have been
indefeasibly paid in full and the Company has no further right to request
Disbursements of the Loan or to cause Notes to be issued.
23
IN WITNESS WHEREOF, each of the parties hereto has caused this Agreement to be
executed and delivered as of the day and year first above written.
THE PIONEER GROUP, INC.
/s/ Xxxx X. Xxxxx, Xx.
----------------------------------
By Xxxx X. Xxxxx, Xx.
-------------------------------
Its President
------------------------------
CLOSED JOINT-STOCK COMPANY
"FOREST STARMA"
/s/
----------------------------------
By
-------------------------------
Its
------------------------------
/s/
----------------------------------
By
-------------------------------
Its
------------------------------
INTERNATIONAL JOINT-STOCK COMPANY
"STARMA HOLDING"
/s/
----------------------------------
By
-------------------------------
Its
------------------------------
/s/
----------------------------------
By
-------------------------------
Its
------------------------------
OVERSEAS PRIVATE INVESTMENT CORPORATION
/s/
----------------------------------
By
-------------------------------
Its Finance Investment Officer
------------------------------
24
- 22-
EXHIBIT A
[FORM OF COMPLETION CERTIFICATE]
COMPLETION CERTIFICATE
DATE: ______________
TO: Overseas Private Investment Corporation ("OPIC")
0000 Xxx Xxxx Xxxxxx, X.X.
Xxxxxxxxxx, X.X. 00000
Attn.: Vice President and Treasurer, and [Finance - Regional Manager]
This Completion Certificate is submitted to OPIC pursuant to Section 3(b)(v) of
the Project Completion Agreement, dated as of , 1995 (the "Project
Completion Agreement"), among Closed Joint-Stock Company "Forest Starma", a
closed joint-stock company, organized and existing under the legislation of the
Russian Federation (the Company"), The Pioneer Group, Inc., a corporation
organized and existing under the laws of the state of Delaware (the "U.S.
Sponsor"), International Joint-Stock Company "Starma Holding", a closed joint
stock company, organized and existing under the legislation of the Russian
Federation (the "Russian Sponsor") and OPIC.
All capitalized terms used herein and not otherwise defined shall have their
respective meanings set forth in the Project Completion Agreement.
[Each of] the undersigned hereby certifies that [he][she] is an Authorized
Officer of the [U.S. Sponsor][the Russian Sponsor], and further certifies that
as of the date hereof each of the requirements set forth below has been
satisfied as of the date hereof:
1. As required by Section 3(b)(i)(PHYSICAL COMPLETION TESTS), all buildings,
jetties, equipment, facilities, and necessary infrastructure for the Project
have been procured, constructed, and installed utilizing first-class standards
of workmanship and materials and in accordance with the Project plans and
specifications, are operational and in good working condition, and meet
manufacturers' specifications and the terms of applicable construction
agreements.
Evidence of the foregoing is attached hereto and made a part hereof as Schedule
1 [attach relevant supporting evidence][NOTE: Relevant supporting evidence may
include an independent consultant's report, accountants' certificate, opinions
of counsel, Authorized Officer's Certificate from the Sponsor(s) and/or the
Company, audited Financial Statements, etc.].
25
- 23 -
2. As required by Section 3(b)(ii)(A)(OPERATIONAL COMPLETION TESTS), the Company
has demonstrated the following: (A) following commencement of its timber logging
operations and the giving of notice to OPIC by the Company of the date of
commencement of a time period (the "Test Period"), the Company has achieved one
of the following tests: (1) during a Test Period of 90 consecutive days, the
Company shall has produced a minimum of 25,000 cubic meters of timber, shipped
and invoiced the timber to clients and deposited the proceeds therefrom in the
Timber Proceeds Account; or (2) after electing to continue the Test Period for
an additional 90 consecutive days, the Company has produced, in the total of 180
consecutive days, a minimum of 55,000 cubic meters of timber from its
operations, shipped and invoiced the timber to clients and deposited the
proceeds therefrom in the Timber Proceeds Account;
(B) the Company has demonstrated a positive cash flow and a ratio of net
operating cash flow to net sales of at least 30% for a period of six consecutive
months; and
(c) the Company has maintained the Cash Collateral Amount.
Evidence of the foregoing is attached hereto and made a part hereof as Schedule
2A [attach relevant supporting evidence].
3. As required by Section 3(b)(iii)(A)(LEGAL CONDITIONS), the Company has valid
surface rights to the forestry tract covered by its cutting license and valid
leasehold interests free and clear of all Liens and encumbrances (except for
security interests permitted by the Finance Agreement) to all of the land and
all buildings, equipment, and facilities referred to above, and to all other
facilities now known to be required for the Project.
Evidence of the foregoing is attached hereto and made a part hereof as Schedule
3A [attach relevant supporting evidence].
As required by Section 3(b)(iii)(B)(LEGAL CONDITIONS), the Company has granted
Liens in favor of OPIC with respect to all of the assets required to be pledged
pursuant to the Finance Agreement, and in accordance with the requirements
thereof.
Evidence of the foregoing is attached hereto and made a part hereof as Schedule
3B [attach relevant supporting evidence].
As required by Section 3(b)(iii)(C)(LEGAL CONDITIONS), all obligations of any
kind of the Company through the Completion Date, including, without limitation,
payment of all amounts at any time to become due up to Project Completion under
contracts for construction, procurement, installation, and improvement of land,
buildings, equipment, and facilities for the Project shall have been met or
waived.
26
- 24 -
Evidence of the foregoing is attached hereto and made a part hereof as Schedule
3C [attach relevant supporting evidence].
As required by Section 3(b)(iii)(D)(LEGAL CONDITIONS), each Financing Document
and each other document identified in the Finance Agreement as being necessary
for the Project, including all relevant licenses, remains in full force and
effect, to the extent applicable.
Evidence of the foregoing is attached hereto and made a part hereof as Schedule
3D [attach relevant supporting evidence].
As required by Section 3(b)(iii)(E)(LEGAL CONDITIONS), no Event of Default (or
condition or event that, with the giving of notice, or lapse of time, or both,
could constitute an Event of Default) under the Finance Agreement exists as of
the date hereof.
Evidence of the foregoing is attached hereto and made a part hereof as Schedule
3E [attach relevant supporting evidence].
4. As required by Section 3(b)(iv)(A)(FINANCIAL TESTS), the ratio of the
Company's Current Assets to Current Liabilities is no less than 1.5 to I; (B)
the ratio of the Company's Indebtedness to Adjusted Net Worth does not exceed
1.857 to 1; and (C) the Company has an Indebtedness Service Ratio of at least
1.2 to 1; and (D) the Company has made at least one principal repayment on the
Loan as and when due from cash flow generated from the Project;
Evidence of the foregoing is attached hereto and made a part hereof as Schedule
4A [attach relevant supporting evidence].
5. As required by Section 3(b)(v)(ENVIRONMENTAL COMPLETION TESTS), the IEAC (as
defined in the Finance Agreement) has certified the compliance of the Project
and the Company's harvesting plan with the Guidelines Schedule in accordance
with and as set forth in the Finance Agreement.
Evidence of the foregoing is attached hereto and made a part hereof as Schedule
5A [attach relevant supporting evidence].
The undersigned further certifies that the documents and materials attached
hereto as Schedules are true, correct, and complete originals or copies.
The undersigned understands that Section 237(n) of the Foreign Assistance Act of
1961, as amended, provides for imprisonment, as well as fines, for knowingly
submitting false statements or reports or willfully overvaluing any land,
property, or security for the purpose of influencing in any way the actions of
OPIC with respect to an OPIC-financial project.
27
- 25 -
IN WITNESS WHEREOF, [each of] the undersigned has hereunto set [his][her] hand
on this ___ day of __________, 199_.
----------------------------------
[PRINTED NAME OF AUTHORIZED OFFICER]
[TITLE OF AUTHORIZED OFFICER]
THE PIONEER GROUP, INC.
----------------------------------
[PRINTED NAME OF AUTHORIZED OFFICER]
[TITLE OF AUTHORIZED OFFICER]
INTERNATIONAL JOINT-STOCK COMPANY
"STARMA HOLDING"
Attachments
