Common Contracts
6 similar Pre-Award Waiver, Release, and Limitation of Liability Agreement contracts
Pre-Award Waiver, Release, and Limitation of Liability AgreementPre-Award Waiver, Release, and Limitation of Liability Agreement • June 3rd, 2021
Purchaser Contractor This PRE-AWARD WAIVER, RELEASE, AND LIMITATION OF LIABILITY AGREEMENT ("Agreement") is entered into as of this day of , between the U.S. Forest Service ("Forest Service") and (" Purchaser ") (together sometimes referred to herein as the "Parties"). Recitals WHEREAS, on or about , the Forest Service declared Purchaser to be the apparent high-bidder on thecontract to operate the Timber Sale , located on National Forest; WHEREAS, the Parties recognize that the Timber Sale may be affected by existing and/or threatenedlitigation ("Litigation") and that, due to such Litigation, the Contracting Officer may instruct Purchaser to delay or suspend operations, and/or modify or terminate the contract for the Timber Sale ; and WHEREAS, Purchaser desires the Forest Service to proceed with the award of the contract, despite the possibility that the Forest Service might delay or suspend operations, and/or modify or terminate the contract; Terms and Conditions 1. Contract Award. Af
Pre-Award Waiver, Release, and Limitation of Liability AgreementPre-Award Waiver, Release, and Limitation of Liability Agreement • June 3rd, 2021
Purchaser Contractor This PRE-AWARD WAIVER, RELEASE, AND LIMITATION OF LIABILITY AGREEMENT ("Agreement") is entered into as of this day of , between the U.S. Forest Service ("Forest Service") and (" Purchaser ") (together sometimes referred to herein as the "Parties"). Recitals WHEREAS, on or about , the Forest Service declared Purchaser to be the apparent high-bidder on thecontract to operate the Timber Sale , located on National Forest; WHEREAS, the Parties recognize that the Timber Sale may be affected by existing and/or threatenedlitigation ("Litigation") and that, due to such Litigation, the Contracting Officer may instruct Purchaser to delay or suspend operations, and/or modify or terminate the contract for the Timber Sale ; and WHEREAS, Purchaser desires the Forest Service to proceed with the award of the contract, despite the possibility that the Forest Service might delay or suspend operations, and/or modify or terminate the contract; Terms and Conditions 1. Contract Award. Af
Pre-Award Waiver, Release, and Limitation of Liability AgreementPre-Award Waiver, Release, and Limitation of Liability Agreement • April 5th, 2021
Purchaser Contractor This PRE-AWARD WAIVER, RELEASE, AND LIMITATION OF LIABILITY AGREEMENT ("Agreement") is entered into as of this day of , between the U.S. Forest Service ("Forest Service") and (" Purchaser ") (together sometimes referred to herein as the "Parties"). Recitals WHEREAS, on or about , the Forest Service declared Purchaser to be the apparent high-bidder on thecontract to operate the Timber Sale , located on National Forest; WHEREAS, the Parties recognize that the Timber Sale may be affected by existing and/or threatenedlitigation ("Litigation") and that, due to such Litigation, the Contracting Officer may instruct Purchaser to delay or suspend operations, and/or modify or terminate the contract for the Timber Sale ; and WHEREAS, Purchaser desires the Forest Service to proceed with the award of the contract, despite the possibility that the Forest Service might delay or suspend operations, and/or modify or terminate the contract; Terms and Conditions 1. Contract Award. Af
Pre-Award Waiver, Release, and Limitation of Liability AgreementPre-Award Waiver, Release, and Limitation of Liability Agreement • August 21st, 2018
Purchaser Contractor This PRE-AWARD WAIVER, RELEASE, AND LIMITATION OF LIABILITY AGREEMENT ("Agreement") is entered into as of this day of , between the U.S. Forest Service ("Forest Service") and (" Purchaser ") (together sometimes referred to herein as the "Parties"). Recitals WHEREAS, on or about , the Forest Service declared Purchaser to be the apparent high-bidder on thecontract to operate the Timber Sale , located on National Forest; WHEREAS, the Parties recognize that the Timber Sale may be affected by existing and/or threatenedlitigation ("Litigation") and that, due to such Litigation, the Contracting Officer may instruct Purchaser to delay or suspend operations, and/or modify or terminate the contract for the Timber Sale ; and WHEREAS, Purchaser desires the Forest Service to proceed with the award of the contract, despite the possibility that the Forest Service might delay or suspend operations, and/or modify or terminate the contract; Terms and Conditions 1. Contract Award. Af
Pre-Award Waiver, Release, and Limitation of Liability AgreementPre-Award Waiver, Release, and Limitation of Liability Agreement • May 15th, 2014
Purchaser Contractor This PRE-AWARD WAIVER, RELEASE, AND LIMITATION OF LIABILITY AGREEMENT ("Agreement") is entered into as of this day of , between the U.S. Forest Service ("Forest Service") and (" Purchaser ") (together sometimes referred to herein as the "Parties"). Recitals WHEREAS, on or about , the Forest Service declared Purchaser to be the apparent high-bidder on thecontract to operate the Timber Sale , located on National Forest; WHEREAS, the Parties recognize that the Timber Sale may be affected by existing and/or threatenedlitigation ("Litigation") and that, due to such Litigation, the Contracting Officer may instruct Purchaser to delay or suspend operations, and/or modify or terminate the contract for the Timber Sale ; andWHEREAS, Purchaser desires the Forest Service to proceed with the award of the contract, despite the possibility that the Forest Service might delay or suspend operations, and/or modify or terminate the contract; Terms and Conditions 1. Contract Award. Af
Pre-Award Waiver, Release, and Limitation of Liability AgreementPre-Award Waiver, Release, and Limitation of Liability Agreement • May 15th, 2014
Purchaser Contractor This PRE-AWARD WAIVER, RELEASE, AND LIMITATION OF LIABILITY AGREEMENT ("Agreement") is entered into as of this day of , between the U.S. Forest Service ("Forest Service") and (" Purchaser ") (together sometimes referred to herein as the "Parties"). Recitals WHEREAS, on or about , the Forest Service declared Purchaser to be the apparent high-bidder on thecontract to operate the Timber Sale , located on National Forest; WHEREAS, the Parties recognize that the Timber Sale may be affected by existing and/or threatenedlitigation ("Litigation") and that, due to such Litigation, the Contracting Officer may instruct Purchaser to delay or suspend operations, and/or modify or terminate the contract for the Timber Sale ; andWHEREAS, Purchaser desires the Forest Service to proceed with the award of the contract, despite the possibility that the Forest Service might delay or suspend operations, and/or modify or terminate the contract; Terms and Conditions 1. Contract Award. Af
