Pre-Award Waiver, Release, and Limitation of Liability AgreementPre-Award Waiver, Release, and Limitation of Liability Agreement • June 3rd, 2021
Purchaser Contractor This PRE-AWARD WAIVER, RELEASE, AND LIMITATION OF LIABILITY AGREEMENT ("Agreement") is entered into as of this day of , between the U.S. Forest Service ("Forest Service") and (" Purchaser ") (together sometimes referred to herein as the "Parties"). Recitals WHEREAS, on or about , the Forest Service declared Purchaser to be the apparent high-bidder on thecontract to operate the Timber Sale , located on National Forest; WHEREAS, the Parties recognize that the Timber Sale may be affected by existing and/or threatenedlitigation ("Litigation") and that, due to such Litigation, the Contracting Officer may instruct Purchaser to delay or suspend operations, and/or modify or terminate the contract for the Timber Sale ; and WHEREAS, Purchaser desires the Forest Service to proceed with the award of the contract, despite the possibility that the Forest Service might delay or suspend operations, and/or modify or terminate the contract; Terms and Conditions 1. Contract Award. Af
Pre-Award Waiver, Release, and Limitation of Liability AgreementPre-Award Waiver, Release, and Limitation of Liability Agreement • June 3rd, 2021
Purchaser Contractor This PRE-AWARD WAIVER, RELEASE, AND LIMITATION OF LIABILITY AGREEMENT ("Agreement") is entered into as of this day of , between the U.S. Forest Service ("Forest Service") and (" Contractor ") (together sometimes referred to herein as the "Parties"). Recitals WHEREAS, on or about , the Forest Service declared Contractor to be the apparent high-bidder on thecontract to operate the Stewardship , located on National Forest; WHEREAS, the Parties recognize that the Stewardship may be affected by existing and/or threatenedlitigation ("Litigation") and that, due to such Litigation, the Contracting Officer may instruct Contractor to delay or suspend operations, and/or modify or terminate the contract for the Stewardship ; and WHEREAS, Contractor desires the Forest Service to proceed with the award of the contract, despite the possibility that the Forest Service might delay or suspend operations, and/or modify or terminate the contract; Terms and Conditions 1. Contract Award
PRE-AWARD WAIVER, RELEASE, AND LIMITATION OF LIABILITY AGREEMENT (TIMBER SALES)Pre-Award Waiver, Release, and Limitation of Liability Agreement • October 22nd, 2019
This PRE-AWARD WAIVER, RELEASE, AND LIMITATION OF LIABILITY AGREEMENT (“Agreement”) is entered into as of this day of , between the U.S. Forest Service (“Forest Service”)
Pre-Award Waiver, Release, and Limitation of Liability AgreementPre-Award Waiver, Release, and Limitation of Liability Agreement • June 3rd, 2021
Purchaser Contractor This PRE-AWARD WAIVER, RELEASE, AND LIMITATION OF LIABILITY AGREEMENT ("Agreement") is entered into as of this day of , between the U.S. Forest Service ("Forest Service") and (" Purchaser ") (together sometimes referred to herein as the "Parties"). Recitals WHEREAS, on or about , the Forest Service declared Purchaser to be the apparent high-bidder on the contract to operate the Kalispel Moon DxP Timber Sale , located on Colville National Forest;WHEREAS, the Parties recognize that the Kalispel Moon DxP Timber Sale may be affected by existing and/or threatenedlitigation ("Litigation") and that, due to such Litigation, the Contracting Officer may instruct Purchaser to delay or suspend operations, and/or modify or terminate the contract for the Kalispel Moon DxP Timber Sale ; andWHEREAS, Purchaser desires the Forest Service to proceed with the award of the contract, despite the possibility that the Forest Service might delay or suspend operations, and/or modify or term
Pre-Award Waiver, Release, and Limitation of Liability Agreement (Timber Sales or Stewardship Contract) Ref FSM 2432.31bPre-Award Waiver, Release, and Limitation of Liability Agreement • July 1st, 2021
This PRE-AWARD WAIVER, RELEASE, AND LIMITATION OF LIABILITY AGREEMENT ("Agreement") is entered into as of this day of , between the U.S. Forest Service ("Forest Service") and (" Contractor ") (together sometimes referred to herein as the "Parties").
Pre-award Waiver, Release, and Limitation of Liability AgreementPre-Award Waiver, Release, and Limitation of Liability Agreement • March 31st, 2021
This PRE-AWARD WAIVER, RELEASE, AND LIMITATION OF LIABILITY AGREEMENT (“Agreement”) is entered into as of this day of , between the U.S. Forest Service (“Forest Service”) and (“Purchaser”) (together sometimes referred to herein as the “Parties”).
Pre-Award Waiver, Release, and Limitation of Liability AgreementPre-Award Waiver, Release, and Limitation of Liability Agreement • June 3rd, 2021
Purchaser Contractor This PRE-AWARD WAIVER, RELEASE, AND LIMITATION OF LIABILITY AGREEMENT ("Agreement") is entered into as of this day of , between the U.S. Forest Service ("Forest Service") and (" Contractor ") (together sometimes referred to herein as the "Parties"). Recitals WHEREAS, on or about , the Forest Service declared Contractor to be the apparent high-bidder on the contract to operate the Spike DxP Stewardship , located on Colville National Forest;WHEREAS, the Parties recognize that the Spike DxP Stewardship may be affected by existing and/or threatenedlitigation ("Litigation") and that, due to such Litigation, the Contracting Officer may instruct Contractor to delay or suspend operations, and/or modify or terminate the contract for the Spike DxP Stewardship ; andWHEREAS, Contractor desires the Forest Service to proceed with the award of the contract, despite the possibility that the Forest Service might delay or suspend operations, and/or modify or terminate the contract;
