Common Contracts
2 similar Limitation of Liability Agreement contracts
Pre-Award Waiver, Release, and Limitation of Liability AgreementLimitation of Liability Agreement • June 3rd, 2021
Purchaser Contractor This PRE-AWARD WAIVER, RELEASE, AND LIMITATION OF LIABILITY AGREEMENT ("Agreement") is entered into as of this day of , between the U.S. Forest Service ("Forest Service") and (" Contractor ") (together sometimes referred to herein as the "Parties"). Recitals WHEREAS, on or about , the Forest Service declared Contractor to be the apparent high-bidder on thecontract to operate the Stewardship , located on National Forest; WHEREAS, the Parties recognize that the Stewardship may be affected by existing and/or threatenedlitigation ("Litigation") and that, due to such Litigation, the Contracting Officer may instruct Contractor to delay or suspend operations, and/or modify or terminate the contract for the Stewardship ; and WHEREAS, Contractor desires the Forest Service to proceed with the award of the contract, despite the possibility that the Forest Service might delay or suspend operations, and/or modify or terminate the contract; Terms and Conditions 1. Contract Award
Pre-Award Waiver, Release, and Limitation of Liability AgreementLimitation of Liability Agreement • November 17th, 2020
Purchaser Contractor This PRE-AWARD WAIVER, RELEASE, AND LIMITATION OF LIABILITY AGREEMENT ("Agreement") is entered into as of this day of , between the U.S. Forest Service ("Forest Service") and (" Contractor ") (together sometimes referred to herein as the "Parties"). Recitals WHEREAS, on or about , the Forest Service declared Contractor to be the apparent high-bidder on the contract to operate the Timbuck Stewardship , located on Idaho Panhandle National Forest;WHEREAS, the Parties recognize that the Timbuck Stewardship may be affected by existing and/or threatenedlitigation ("Litigation") and that, due to such Litigation, the Contracting Officer may instruct Contractor to delay or suspend operations, and/or modify or terminate the contract for the Timbuck Stewardship ; and WHEREAS, Contractor desires the Forest Service to proceed with the award of the contract, despite the possibility that the Forest Service might delay or suspend operations, and/or modify or terminate the contract
