Controllable Operating Expenses means all Operating Expenses except property taxes and assessments, capital expenditures that are reasonably required, costs for repairs and maintenance (excluding preventative maintenance), utility charges, insurance charges, costs of services provided under a union contract, payments under covenants, conditions and restrictions or to an owners’ association and costs associated with repairs due to casualty, vandalism or other cause outside of Landlord’s reasonable control.
Controllable Expenses means all expenses, other than Uncontrollable Expenses, incurred by the Company or any Subsidiary of the Company with respect to the Property.
Uncontrollable Force means any cause beyond the control of the Borrower, including: (a) a hurricane, tornado, flood or similar occurrence, landslide, earthquake, fire or other casualty, strike or labor disturbance, freight embargo, act of a public enemy, explosion, war, blockade, terrorist act, insurrection, riot, general arrest or restraint of government and people, civil disturbance or similar occurrence, sabotage, or act of God (provided that the Borrower shall not be required to settle any strike or labor disturbance in which it may be involved) or (b) the order or judgment of any federal, state or local court, administrative agency or governmental officer or body, if it is not also the result of willful or negligent action or a lack of reasonable diligence of the Borrower and the Borrower does not control the administrative agency or governmental officer or body; provided that the diligent contest in good faith of any such order or judgment shall not constitute or be construed as a willful or negligent action or a lack of reasonable diligence of the Borrower.
Uncontrollable Forces means any event which results in the prevention or delay of performance by a party of its obligations under this Agreement and which is beyond the reasonable control of the nonperforming party. It includes, but is not limited to fire, flood, earthquakes, storms, lightning, epidemic, war, riot, civil disturbance, sabotage, and governmental actions.
Common Area Operating Expenses are defined, for purposes of this Lease, as all costs incurred by Lessor relating to the ownership and operation of the Industrial Center, including, but not limited to, the following: (i) The operation, repair and maintenance, in neat, clean, good order and condition, of the following:
Operating Expense means salaries, wages, cost of maintenance and operation, materials, supplies, insurance and all other items normally included under recognized accounting practices, but does not include allowances for depreciation in the value of physical property.
Operating Costs means the incremental expenses incurred by the Recipient on account of Project implementation, management, and monitoring, including for office space rental, utilities, and supplies, bank charges, communications, vehicle operation, maintenance, and insurance, building and equipment maintenance, advertising expenses, travel and supervision, salaries of contractual and temporary staff, but excluding salaries, fees, honoraria, and bonuses of members of the Recipient’s civil service.
Building Operating Expenses means the portion of “Operating Expenses,” as that term is defined in Section 4.2.7 below, allocated to the tenants of the Building pursuant to the terms of Section 4.3.1 below.
Operating Cost means the costs associated with operating a multifamily development once the project is placed in service.
Operating Expenses is defined to include all expenses necessary or appropriate for the operation of the Fund (or Class, as applicable), including the Advisor’s investment advisory or management fee detailed in the Investment Advisory Agreement and any Rule 12b-1 fees and other expenses described in the Investment Advisory Agreement, but does not include taxes, leverage interest, brokerage commissions, dividend and interest expenses on short sales, acquired fund fees and expenses (as determined in accordance with SEC Form N-1A), expenses incurred in connection with any merger or reorganization, or extraordinary expenses such as litigation expenses.
Operating Expenditures means all Partnership Group expenditures, including, but not limited to, taxes, reimbursements of the General Partner, repayment of Working Capital Borrowings, debt service payments and capital expenditures, subject to the following:
Total Fund Operating Expenses with respect to a Fund is defined to include all expenses necessary or appropriate for the operation of the Fund including the Adviser’s investment advisory or management fee under the Advisory Agreement and other expenses described in the Advisory Agreement that the Fund is responsible for and have not been assumed by the Adviser, but excludes front-end or contingent deferred loads, taxes, leverage expenses, interest, brokerage commissions, expenses incurred in connection with any merger or reorganization, unusual or infrequently occurring expenses (such as litigation), acquired fund fees and expenses, and dividend expenses, if any.
Tenant Delays means (A) Tenant’s request for changes to Landlord’s Work, regardless of whether any such changes are performed, (B) construction of any such changes, (C) Tenant’s request for materials, finishes, or installations requiring unusually long lead times that were not originally included as a part of Landlord’s Work, (D) Tenant’s delay (which shall mean more than 5 business days) in reviewing, revising, or approving any plans and specifications relating to Landlord’s Work, (E) Tenant’s delay in providing information critical to the normal progression of the Project (Tenant shall provide such information as soon as reasonably possible, but in no event longer than 5 business days after receipt of any request for such information from Landlord), and (F) any other act or omission by Tenant or any Tenant Party (as defined herein), or persons employed by any of such persons, (iv) “Substantially Completed” means the substantial completion of Landlord’s Work (A) in a good and workmanlike manner, (B) in accordance with the requirements described in Exhibit C, and (C) in accordance with all applicable Legal Requirements (including, but not limited to, securing the applicable final building inspection for Landlord’s Work), subject only to normal “punch list” items, and (v) “Existing Tenant Delay” means the refusal or failure by the Existing Tenant (as defined below) to surrender the Premises by July 1, 2010 in accordance with the terms and conditions of the Existing Lease (as defined below). Landlord will promptly perform such punch list items. Tenant shall obtain, at its sole cost and expense, any applicable use and occupancy permit for the Premises issued by the applicable Governmental Authority. If Tenant does not elect to void this Lease within 5 business days of the lapse of such 60 day period, such right to void this Lease shall be waived and this Lease shall remain in full force and effect. If neither Landlord nor Tenant elects to void this Lease within 5 business days of the lapse of such 60 day period, such right to void this Lease shall be waived and this Lease shall remain in full force and effect. Sequoia Pharmaceuticals, Inc. (“Existing Tenant”), is currently leasing the Premises from Landlord, and the lease agreement (“Existing Lease”) between Landlord and Existing Tenant is scheduled to expire on July 1, 2010 subject to Landlord’s right to advance the expiration date. Tenant understands, acknowledges, and agrees that Landlord makes no guaranty, representation, or assurance that Landlord will be able to recapture the Premises from the Existing Tenant by July 1, 2010 and that Landlord shall have no obligation or duty to seek the vacation or removal of the Existing Tenant from the Premises.
Uncontrollable Circumstance means any act, event or condition that is:
Total Operating Expenses means all costs and expenses paid or incurred by the Company, as determined under generally accepted accounting principles, that are in any way related to the operation of the Company or to Company business, including advisory fees, but excluding (i) the expenses of raising capital such as Organization and Offering Expenses, legal, audit, accounting, underwriting, brokerage, listing, registration, and other fees, printing and other such expenses and tax incurred in connection with the issuance, distribution, transfer, registration and Listing of the Shares, (ii) interest payments, (iii) taxes, (iv) non-cash expenditures such as depreciation, amortization and bad debt reserves, (v) incentive fees paid in compliance with the NASAA REIT Guidelines, (vi) Acquisition Fees and Acquisition Expenses, (vii) real estate commissions on the Sale of Properties, (viii) Financing Coordination Fees and (ix) other fees and expenses connected with the acquisition, disposition, management and ownership of real estate interests, mortgage loans or other property (including the costs of foreclosure, insurance premiums, legal services, maintenance, repair and improvement of property).
AMPS Basic Maintenance Amount, as of any Valuation Date, means the dollar amount equal to (i) the sum of (A) the product of the number of shares of AMPS and Other AMPS Outstanding on such Valuation Date multiplied by the sum of (a) $25,000 and (b) any applicable redemption premium attributable to the designation of a Premium Call Period; (B) the aggregate amount of cash dividends (whether or not earned or declared) that will have accumulated for each share of AMPS and Other AMPS Outstanding, in each case, to (but not including) the end of the current Dividend Period that follows such Valuation Date in the event the then current Dividend Period will end within 49 calendar days of such Valuation Date or
Project Expenses means usual and customary operating and financial costs. The term does not include extraordinary capital expenses, development fees and other non-operating expenses.
Approved Operating Expenses means Operating Expenses incurred by Borrower which (i) are included in the Approved Annual Budget for the current calendar month, (ii) are for real estate taxes, insurance premiums, electric, gas, oil, water, sewer or other utility service to the Property, (iii) if applicable, are for property management fees payable to Manager under the Management Agreement, such amounts not to exceed three percent (3.0)% of the monthly Gross Revenue, (iv) or (v) have otherwise been approved by Lender.
Maintenance Costs means parts and materials, sublet and labour costs of a qualified licensed mechanic for the maintenance of the Revenue Service Vehicles, but shall not include costs associated with interior and exterior transit advertising signs and non-mechanical servicing of Revenue Service Vehicles such as fuelling, clearing fareboxes, cleaning and painting wheel rims, vehicle washing and other work performed by a serviceman; and,
Annual Operating Expenses for the Class means and will consist only of the following operating expenses of the Series for the Class that are, under generally accepted accounting principles, accruable and deductible from the Series’ assets with respect to the Class for the period involved: (i) investment advisory fees, if any; (ii) Rule 12b-1 distribution fees, if any; and (iii) custodian fees, shareholder servicing fees, administrative and office facilities expenses, professional fees, trustees' fees and any other operating expenses of the Series with respect to the Class that are recorded or includable in the Series' statement of operations in accordance with generally accepted accounting principles. Notwithstanding the provisions of the immediately preceding sentence, the Series' “Annual Operating Expenses” for the Class do not include “acquired fund expenses”, interest and dividends on securities sold short, amortization of organization expenses, taxes, brokerage commissions, litigation and indemnification expenses or any costs or expenses of or for the Series with respect to the Class that are "extraordinary" as determined under generally accepted accounting principles (see Accounting Principles Board Opinion No. 30). Very truly yours, ROYCE & ASSOCIATES, LP By: /s/ Xxxxx X. Xxxxxxx Xxxxx X. Xxxxxxx Chief Financial Officer THE ROYCE FUND By: /s/ Xxxxx X. Xxxxxxx Xxxxx X. Xxxxxxx Treasurer April 29, 2024 The Royce Fund 000 Xxxxx Xxxxxx New York, NY 10151 Gentlemen: Reference is made to the Investment Advisory Agreement dated July 31, 2020 (the “Agreement”), by and between The Royce Fund (the “Fund”), on behalf of Xxxxx Total Return Fund (the “Series”), and Royce & Associates, LP (the “Adviser”). Notwithstanding the provisions of Section 4 (Compensation of the Adviser) of the Agreement, the Adviser hereby waives compensation for services it provides under the Agreement for the period beginning May 1, 2024, and ending April 30, 2025 (the “Period”), and/or agrees to reimburse expenses relating to the Period to the Series with respect to its Service Class of shares (the “Class”) in an amount, if any, necessary so that the Series’ “Annual Operating Expenses” for the Class are not more than 1.49% of the Class’s average net assets for the Period. The Adviser's obligations to reimburse the Series with respect to the Class hereunder will not apply for any period when the Adviser is not rendering services to such Series under the Agreement.
Generator Maintenance Outage means the scheduled removal from service, in whole or in part, of a generating unit in order to perform necessary repairs on specific components of the facility, if removal of the facility meets the guidelines specified in the PJM Manuals.
Base Operating Costs means Operating Costs for the calendar year specified as the Base Year in the Basic Lease Information (excluding therefrom, however, any Operating Costs of a nature that would not ordinarily be incurred on an annual, recurring basis).
Tenant Delay means an actual delay in the occurrence of the Substantial Completion Date or the Final Completion Date with respect to Landlord’s Work as the result of: (1) any unreasonable delay by Tenant in approving the Plans; (2) any request by Tenant that Landlord delay the commencement or completion of Landlord’s Work for any reason; (3) any request by Tenant to change the Plans after initial approval thereof by Tenant, or the making of any changes to Landlord’s Work requested by Tenant and agreed to by Landlord after initial approval of the Plans by Tenant; (4) any failure by Tenant to respond in writing within seven (7) business days after any written request by Landlord for clarification or interpretation of the Plans or for approval of changes in the Plans deemed necessary by Landlord; or (5) any other act or omission of Tenant or its officers, agents, employees or contractors; Notwithstanding the foregoing, no event shall be deemed to be a Tenant Delay until and unless Landlord has given Tenant written notice (the “Tenant Delay Notice”) advising Tenant (i) that a Tenant Delay is occurring, (ii) of the basis on which Landlord has determined that a Tenant Delay is occurring, and (iii) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay, and Tenant has failed to correct the Tenant Delay specified in the Tenant Delay Notice within forty-eight (48) hours following receipt thereof. No period of time prior to expiration of such 48-hour period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice if Tenant corrects the Tenant Delay specified in the Tenant Delay Notice within such 48-hour period.
Operating Profit means the excess of Gross Revenues over the following deductions (“Deductions”) incurred by Manager, on behalf of Owner, in operating the Hotel:
Extraordinary Loss Any Realized Loss or portion thereof caused by or resulting from:
Base Operating Expenses means the Operating Expenses for the Base Year.