Examples of CPM Schedule in a sentence

After acceptance by Owner of the CPM Schedule, Contractor shall manage and update the CPM Schedule no less frequently than once per Month with Primavera Project Planner, using the critical path method, to reflect the actual progress to date (“Monthly Updated CPM Schedule”); provided, however, Contractor may not modify any Key Date without a Change Order executed pursuant to this Agreement, nor shall Contractor change any dates that relate to Owner’s obligations without obtaining Owner’s written consent.
All submittals by Contractor to Owner of the CPM Schedule, Recovery Schedule, Acceleration Schedule and any Monthly Updated CPM Schedule shall be in both hard copy and native electronic Primavera Project Planner format.
The CPM Schedule shall be consistent with the Key Dates and shall represent Contractor’s best judgment as to how it shall complete the Work in compliance with the Guaranteed Dates.
The CPM Schedule shall reflect the critical path to Substantial Completion.
Such submission to Owner of the CPM Schedule shall be in hard copy and native electronic format.

More Definitions of CPM Schedule

CPM Schedule means the cost loaded, design and construction schedule for the Design/Build Work prepared by the Company and approved by Village using CPM.

CPM Schedule has the meaning set forth in Section 5.4A. “Cure Period” has the meaning set forth in Section 16.1C.

CPM Schedule has the meaning set forth in Section 7.2.

CPM Schedule means a critical path method construction schedule or the equivalent thereof.

CPM Schedule means a document that shows the planned progression of the Work.

CPM Schedule means the Critical Path schedule prepared and revised in accordance with, and as defined in, Appendix J-1 to Exhibit J.