Delay in delivery definition

Delay in delivery means failure to make delivery (or partial delivery) on time, provided that such failure is not due to any act or omission on the part of the Buyer and that the Supplier is not entitled to relief in accordance with the rules in section 13 on force majeure.
Sample 1Sample 2Sample 3
Delay in delivery. LIQUIDATED DAMAGES: TERMINATION FOR DELAY IN DELIVERY............................................................31
Sample 1
Delay in delivery means the situation when the goods have not been delivered at the port of discharge provided for in the contract of carriage by sea within the time expressly agreed upon or, in the absence of such agreement, within the time which it would be reasonable to require of a diligent carrier, having regard to the circumstances of the case. The carrier shall not be responsible for delay in delivery due to the following reasons:
Sample 1Sample 2

Examples of Delay in delivery in a sentence

  • ANY DELAY IN DELIVERY SHALL NOT AFFECT THE VALIDITY OF THIS LEASE.

  • IN NO EVENT SHALL Lessor BE LIABLE FOR LOSS OF PROFITS, INDIRECT, SPECIAL OR CONSEQUENTIAL DAMAGES ARISING OUT OF ANY BREACH OF THIS AGREEMENT OR OBLIGATIONS UNDER THIS AGREEMENT, NOR SHALL Lessor BE LIABLE FOR ANY DAMAGES CAUSED BY DELAY IN DELIVERY, INSTALLATION OR FURNISHING OF THE EQUIPMENT OR SERVICES BY ANY MANUFACTURER OF THE EQUIPMENT OR OTHERWISE.

  • IN NO EVENT SHALL LICENSOR BE LIABLE TO LICENSEE OR ANY SUBLICENSEE OR ANY OTHER ENTITY FOR ANY DAMAGES OR LOSS CAUSED BY DELAY IN DELIVERY OR FURNISHING OF DATA USING THE INTELLECTUAL PROPERTY.

  • LICENSOR SHALL NOT BE LIABLE FOR ANY DAMAGES CAUSED BY DELAY IN DELIVERY, INSTALLATION OR FURNISHING OF THE SOFTWARE UNDER THIS AGREEMENT.

  • IN ADDITION, JUTVISION WILL NOT BE LIABLE FOR ANY DAMAGES CAUSED BY DELAY IN DELIVERY OF THE EQUIPMENT OR ANY OTHER MATERIALS PROVIDED HEREUNDER.

  • BOEING'S PERFORMANCE OF ITS OBLIGATIONS HEREUNDER SHALL CONSTITUTE FULL AND FINAL SETTLEMENT AND SATISFACTION OF ALL CLAIMS OR CAUSES OF ACTION OF CUSTOMER AGAINST BOEING RELATING TO THE DELAY IN DELIVERY OF THE DELAYED AIRCRAFT AND WILL BE REFLECTED IN A REDUCED INVOICE AMOUNT OR A CREDIT MEMORANDUM.

  • THE OBLIGATIONS OF BOEING EXPRESSLY SET FORTH IN THIS LETTER AGREEMENT ARE EXCLUSIVE AND IN SUBSTITUTION FOR, AND CUSTOMER HEREBY WAIVES, RELEASES AND RENOUNCES ALL OTHER OBLIGATIONS AND LIABILITIES OF BOEING AND ALL OTHER RIGHTS, CLAIMS AND REMEDIES OF CUSTOMER AGAINST BOEING, EXPRESS OR IMPLIED, ARISING BY LAW OR OTHERWISE WITH RESPECT TO THE DELAY IN DELIVERY OF THE DELAYED AIRCRAFT.

  • THE BORROWER AGREES TO LOOK SOLELY TO THE MANUFACTURER, VENDOR OR CARRIER OF THE EQUIPMENT FOR ANY CLAIM ARISING FROM ANY DEFECT, BREACH OF WARRANTY, FAILURE OR DELAY IN DELIVERY, MISDELIVERY OR INABILITY TO USE THE EQUIPMENT FOR ANY REASON WHATSOEVER, AND THE BORROWER'S OBLIGATIONS TO THE LENDER HEREUNDER SHALL NOT IN ANY MANNER BE AFFECTED THEREBY.

  • THE --------------------------------------------------------------------- BORROWER AGREES TO LOOK SOLELY TO THE MANUFACTURER, VENDOR OR CARRIER OF THE EQUIPMENT FOR ANY CLAIM ARISING FROM ANY DEFECT, BREACH OF WARRANTY, FAILURE OR DELAY IN DELIVERY, MISDELIVERY OR INABILITY TO USE THE EQUIPMENT FOR ANY REASON WHATSOEVER, AND THE BORROWER'S OBLIGATIONS TO THE LENDER HEREUNDER SHALL NOT IN ANY MANNER BE AFFECTED THEREBY.

  • NONE OF THE ISSUER, THE STORM RECOVERY BOND REGISTRAR, THE PAYING AGENT OR THE INDENTURE TRUSTEE SHALL BE LIABLE FOR ANY DELAY IN DELIVERY OF SUCH INSTRUCTIONS AND MAY CONCLUSIVELY RELY ON, AND SHALL BE FULLY PROTECTED IN RELYING ON, SUCH INSTRUCTIONS.


More Definitions of Delay in delivery

Delay in delivery means failure to make Delivery (or partial Delivery) on time, provided that such failure is not due to any act
Sample 1
Delay in delivery means failure to make delivery (or partial delivery) on time, provided that such failure is not due to any act or omission on the part of the Buyer and that the Supplier is not entitled
Sample 1

Related to Delay in delivery

  • Delay Delivery Certification As defined in Section 2.02(a) hereof.

  • Termination Delivery Unit means (a) in the case of a Termination Event, an Event of Default or an Extraordinary Event (other than an Insolvency, Nationalization, Merger Event or Tender Offer), one Share or (b) in the case of an Insolvency, Nationalization, Merger Event or Tender Offer, a unit consisting of the number or amount of each type of property received by a holder of one Share (without consideration of any requirement to pay cash or other consideration in lieu of fractional amounts of any securities) in such Insolvency, Nationalization, Merger Event or Tender Offer. If a Termination Delivery Unit consists of property other than cash or New Shares and Counterparty provides irrevocable written notice to the Calculation Agent on or prior to the Closing Date that it elects to deliver cash, New Shares or a combination thereof (in such proportion as Counterparty designates) in lieu of such other property, the Calculation Agent shall replace such property with cash, New Shares or a combination thereof as components of a Termination Delivery Unit in such amounts, as determined by the Calculation Agent in its discretion by commercially reasonable means, as shall have a value equal to the value of the property so replaced. If such Insolvency, Nationalization, Merger Event or Tender Offer involves a choice of consideration to be received by holders, such holder shall be deemed to have elected to receive the maximum possible amount of cash.

  • Delivery Notice Has the meaning specified in the NPA.

  • Delayed Delivery Fee shall have the meaning specified in paragraph 2H(2).

  • Final Delivery Date means the date the Supplier is entitled to deliver the Products form the Purchaser even if the Products have not been called off as agreed in any Sales Agreement.

  • Grain dealer means a person engaged in the business of receiving, buying, exchanging, selling, or storing farm produce in this state. The term includes a farm produce trucker, grain merchandiser, or processor. The term does not include a person solely engaged in 1 of the following:

  • Delay Delivery Mortgage Loans The Mortgage Loans for which all or a portion of a related Mortgage File is not delivered to the Trustee or to the Custodian on its behalf on the Closing Date. The number of Delay Delivery Mortgage Loans shall not exceed 25% of the aggregate number of Mortgage Loans as of the Closing Date.

  • Underwritten Demand shall have the meaning given in subsection 2.1.3 of this Agreement.

  • Final delivery certificate means the document issued by the COE confirming that all the known defects have been rectified and that the works, goods or services appear in good order and have been accepted;

  • Delivery Day means a day other than a Saturday, a Sunday or any other day on which national banking associations are authorized to be closed. Any party may change its address for purposes of the receipt of notices and demands by giving notice of the change in the manner provided in this provision.

  • Share Delivery Date shall have the meaning set forth in Section 4(c)(ii).

  • Notice Delivery Period means the period from and including the Trade Date, to and including a day that is three (3) Business Days following the date that is 14 calendar days after the Scheduled Termination Date. Section 1.23 (Notice Delivery Period) of the Credit Derivatives Definitions shall be amended accordingly.

  • First Delivery Date means the first date by which the commodity for a Futures Contract can be delivered in order for the terms of the Futures Contract to be fulfilled.

  • Initial Delivery Date has the meaning set forth in Section 1.1(d).

  • Exercise Notice has the meaning set forth in Section 3.2(1);

  • Delivery Date means the date or dates specified in the Purchase Order by which the Supplier is required to deliver the Work.

  • Warrant Share Delivery Date shall have the meaning set forth in Section 2(d)(i).

  • Scheduled Delivery Date means the Date on which the Seller is required to start delivering the power at the Delivery Point as per the terms and conditions of the PPA;

  • Delivery sale means any sale of a vapor product to a

  • undertaking in difficulty means an undertaking in respect of which at least one of the following circumstances occurs:

  • Responsible bidder or offeror means a person who at the time of Contract Award has the capability to perform the Contract requirements and the integrity and reliability which will assure good faith performance.

  • Underwritten Shelf Take-Down Notice has the meaning set forth in Section 2.02(e).

  • Draw Down Notice shall have the meaning assigned to such term in Section 5.1(f) hereof.

  • Delivery ex stock means immediate delivery directly from stock actually on hand.

  • Excusable Delay means a delay due to acts of God, governmental restrictions, stays, judgments, orders, decrees, enemy actions, civil commotion, fire, casualty, strikes, work stoppages, shortages of labor or materials or other causes beyond the reasonable control of Borrower, but lack of funds in and of itself shall not be deemed a cause beyond the control of Borrower.