Work Schedule means the approved order and timeline for how the requirements of this contract, including Work on individual Units or groups of Units, will be fulfilled by the Contractor.
Project Schedule means a document that, with respect to each Phase of the Project, identifies, coordinates and integrates the anticipated design and construction schedules, the Contracting Authority’s and Owner's responsibilities, government authority reviews and other activities as are necessary for the timely completion of the Work.
Annual Work Plan means each work plan approved by the Association under Section I.C of Schedule 2 to this Agreement for inclusion in the Project.
Construction Phase Services means the coordination, implementation and execution of the Work required by this Agreement, which are further defined in Article 8.
Project Description means the document that describes the Project's Reduction activities and that uses either the VCS Project Description Template or the project description template specified by the relevant Approved GHG Program;
Construction Schedule means a construction schedule indicating the planned start and completion dates of the major activities of the Work as set out in Appendix [ ], a future Appendix;
tidal work means so much of any work authorised by this Order as is on, under or over tidal waters or tidal lands below the level of high water;
Work crew means a program of partial confinement
Progress Schedule means a schedule of the Work, in a form satisfactory to Owner, as further set forth in Section 3.02.
Additional Work to mean additions or deletions or modifications to the amount, type or value of the Work and Services as required in this Contract, as directed and/or approved by the County.
Schedule of Work means that schedule attached to the Interconnection Construction Service Agreement setting forth the timing of work to be performed by the Constructing Entity pursuant to the Interconnection Construction Service Agreement, based upon the Facilities Study and subject to modification, as required, in accordance with Transmission Provider’s scope change process for interconnection projects set forth in the PJM Manuals.
Tenant Improvement Work means the construction of the Tenant Improvements, together with any related work (including demolition) that is necessary to construct the Tenant Improvements.
Time Schedule means the Time Schedule for final completion of the Works or Mechanical Completion of the Plant(s)/Unit(s), as the case may be, incorporated in the Contract or as may be extended by the OWNER or Engineer- in-Charge pursuant to the provisions hereof and shall include interim time schedules set up for achieving interim/phase-wise/stage-wise progress/completion/testing/commissioning/ handing over, as may be prescribed by the OWNER/Engineer-in-Charge, within the overall Time Schedule as originally envisaged or as extended.
Work area means a room or defined space in a workplace where hazardous chemicals are produced or used, and where employees are present.
Contract Schedule The list (as such list may be amended from time to time) identifying each Contract constituting part of the corpus of the Trust Fund as of the Cut-off Date, and which (a) identifies each Contract as either a Fixed Rate Contract or Adjustable Rate Contract and by contract number and name and address of the Obligor and (b) sets forth as to each Contract (i) the unpaid principal balance as of the related Transfer Date determined by giving effect to payments received prior to the related Transfer Date, (ii) the amount of each scheduled payment due from the Obligor, and (iii) the APR.
Tenant Improvements Defined in Exhibit B, if any.
Work space means that portion of the court’s facilities dedicated to each court reporter, including but not limited to actual space in the courtroom and any designated office space.
Statement of Work means the description of activities performed in completing the Project, as specified in the Contract and as may be amended.
Technical Specifications A specification in a document defining the characteristics of a product or a service, such as the quality levels, the environmental and climate performance levels, the design for all needs, including accessibility for people with disabilities, and the evaluation of conformity, of product performance, of the use of the product, safety or dimensions, as well as requirements applicable to the product as regards the name by which it is sold, terminology, symbols, testing and test methods, packaging, marking or labelling, instructions for use, the production processes and methods at every stage in the life cycle of the supply or service, as well as the evaluation and conformity procedures;
Standard Specifications means a compilation in book form of specifica- tions approved for general application and repetitive use;
Work Progress Schedule means the continually updated time schedule prepared and monitored by Contractor that accurately indicates all necessary appropriate revisions as required by the conditions of the Work and the Project while maintaining a concise comparison to the Baseline Schedule.
Scope of Work means the description of Services and Deliverables specified in the Contract and as may be amended.
Work Letter means the work letter between Landlord and Tenant regarding the construction of the Tenant Improvements in the form of Exhibit D attached hereto.
Completion of work means completion of the entire contracted work. Exhaustion of quantity of any particular item mentioned in the bid document shall not imply completion of work or any component thereof.
technical specification means a document that prescribes technical requirements to be fulfilled by a product, process or service;
The Project Plan means the document to be developed by the Supplier and approved by the Purchaser, pursuant to GCC Clause 19, based on the requirements of the Contract and the Preliminary Project Plan included in the Supplier’s bid. The “Agreed and Finalized Project Plan” is the version of the Project Plan approved by the Purchaser, in accordance with GCC Clause 19.2. Should the Project Plan conflict with the Contract in any way, the relevant provisions of the Contract, including any amendments, shall prevail.