Cover Damages means, with respect to any Delivery Failure, an amount equal to (a) the positive net amount, if, any, by which the Replacement Price exceeds the applicable Price that would have been paid pursuant to Section 5.1 hereof, multiplied by the quantity of that Delivery Failure, plus (b) any applicable penalties and other costs assessed by ISO-NE or any other Person against Buyer as a result of Seller’s failure to deliver such Products in accordance with the terms of this Agreement. Buyer shall provide a statement for the applicable period explaining in reasonable detail the calculation of any Cover Damages.
Indemnity Obligations means all obligations of the Company to Indemnitee under this Agreement, including the Company’s obligations to provide indemnification to Indemnitee and advance Expenses to Indemnitee under this Agreement.
Overhead Damage means any damage to the Vehicle or to any third-party property that is caused by:
(a) contact between any part of the Vehicle that is at or above the level of the top of the front windscreen with objects overhanging or obstructing its path;
(b) the Vehicle hitting a signed height restricted structure such as but not limited to bridges, car parks and drive throughs; or
(c) objects being placed on the roof of the Vehicle;
Indemnification Obligations means each of the Debtors’ indemnification obligations in place as of the Effective Date, whether in the bylaws, certificates of incorporation or formation, limited liability company agreements, other organizational or formation documents, board resolutions, management or indemnification agreements, or employment or other contracts, for their current and former directors, officers, managers, members, employees, attorneys, accountants, investment bankers, and other professionals and agents of the Debtors.
Indemnified Damages shall have the meaning assigned to such term in Section 6(a).
Special Damages has the meaning specified in Section 11.21.
Limitation of Liability PrimePay has negotiated preferred terms and conditions with FD as a service to PrimePay Clients. Client understands that FD, and not PrimePay, will be performing those services and that Client will enter its own service agreement(s) with FD for such services under terms and conditions specified by FD and agreed to by Client. Accordingly, Client acknowledges that FD shall be the provider of Payment Processing Services hereunder and that PrimePay shall have no liability whatsoever for or related to the performance of those services, including any and all damages, costs and related expenses (including attorney fees).
Damage Payment means the dollar amount equal to the amount initially posted as Project Development Security pursuant to Section 8.4(a).
Indemnification Obligation means any existing or future obligation of any Debtor to indemnify current and former directors, officers, members, managers, sponsors, agents or employees of any of the Debtors who served in such capacity, with respect to or based upon such service or any act or omission taken or not taken in any of such capacities, or for or on behalf of any Debtor, whether pursuant to agreement, letters, the Debtors’ respective memoranda, articles or certificates of incorporation, corporate charters, bylaws, operating agreements, limited liability company agreements, or similar corporate or organizational documents or other applicable contract or law in effect as of the Effective Date.
Consequential Damages means Losses claimed to have resulted from any indirect, incidental, reliance, special, consequential, punitive, exemplary, multiple or any other Loss, including damages claimed to have resulted from harm to business, loss of anticipated revenues, savings, or profits, or other economic Loss claimed to have been suffered not measured by the prevailing Party’s actual damages, and any other damages typically considered consequential damages under Applicable Law, regardless of whether the Parties knew or had been advised of the possibility that such damages could result in connection with or arising from anything said, omitted, or done hereunder or related hereto, including willful acts or omissions.
Daily Delay Damages means with respect to a Guaranteed Project Milestone, an amount equal to (a) the Project Development Security Amount posted as of the first date that Daily Delay Damages are payable under this Agreement with respect to such Guaranteed Project Milestone, divided by (b) 120.
Actual Damages has the meaning set forth in Section 12.4(C).
Indemnification Escrow Agreement means an agreement in substantially the form attached hereto as Exhibit B, between the Escrow Participant, the Escrow Agent and the Purchaser with respect to the Indemnification Escrow Shares to reflect the terms set forth in Section 10.3.
Delay Damages means the damages assessed pursuant to Section 3.2(a) hereof.
Indemnification Cap has the meaning set forth in Section 9.4(a).
Parallel Obligations means the independent obligations of any of the Grantors arising pursuant to the First Lien Intercreditor Agreement to pay to the Collateral Agent sums equal to the sums owed by such Grantor to the other Secured Parties (or any of them) under the Credit Documents.
Indemnity Matters means any and all actions, suits, proceedings (including any investigations, litigation or inquiries), claims, demands and causes of action made or threatened against a Person and, in connection therewith, all losses, liabilities, damages (including, without limitation, consequential damages) or reasonable costs and expenses of any kind or nature whatsoever incurred by such Person whether caused by the sole or concurrent negligence of such Person seeking indemnification.
Attorneys’ Fees means the full and actual cost of any legal services actually performed in connection with the matter involved calculated on the basis of the usual fee charged by the attorney performing such services and shall not be limited to "reasonable attorneys' fees" as defined in any statute or rule of court.
Attorneys’ Fees and Expenses means such funds as may be awarded to Class Counsel by the Court to compensate them (and all other attorneys for Plaintiff or the Settlement Class) for their fees and all expenses incurred by Plaintiff or Class Counsel in connection with the Litigation.
Crew Support Costs means all expenses of a general nature which are not particularly referable to any individual vessel for the time being managed by the Managers and which are incurred by the Managers for the purpose of providing an efficient and economic management service and, without prejudice to the generality of the foregoing, shall include the cost of crew standby pay, training schemes for officers and ratings, cadet training schemes, sick pay, study pay, recruitment and interviews.
Loss or Damage means any loss or damage to the Vehicle, including that caused by theft of the Vehicle or by adverse weather events, that requires repair or replacement including the loss of use of the Vehicle (demurrage), legal expenses, assessment fees, towing and recovery costs, storage, service charges and any appraisal fees of the Vehicle;
Indemnification Provisions means each of the Debtors’ indemnification provisions currently in place whether in the Debtors’ bylaws, certificates of incorporation, other formation documents, board resolutions, or contracts for the current and former directors, officers, managers, employees, attorneys, other professionals, and agents of the Debtors and such current and former directors’, officers’, and managers’ respective Affiliates.
Environmental Damages means all liabilities (including strict liability), losses, damages (excluding consequential, special, exemplary or punitive damages except to the extent such damages were imposed upon an Indemnitee as a result of any claims made against such Indemnitee by a governmental entity or any other third party), judgments, penalties, fines, costs and expenses (including fees, costs and expenses of attorneys, consultants, contractors, experts and laboratories), of any and every kind or character, at law or in equity, contingent or otherwise, matured or unmatured, foreseeable or unforeseeable, made, incurred, suffered, brought, or imposed at any time and from time to time, whether before or after the Release Date and arising in whole or in part from:
Indemnification Escrow Fund has the meaning set forth in Section 2.12(a).
Indemnification Escrow Amount has the meaning set forth in Section 2.2(b).
Punitive Damages are those damages awarded as a penalty, the amount of which is neither governed nor fixed by statute.