If an Unidentified Utility Delay is concurrent with another delay for which DB Contractor is entitled to a time extension, the delay shall be considered an Unidentified Utility Delay and the provisions of this Section 6.4 shall apply.
Force Majeure Delays means any actual delay in the construction of the Tenant Improvements, which is beyond the reasonable control of Landlord or Tenant, as the case may be, as described in Paragraph 33 of the Lease.
Force Majeure Delay means with respect to the Servicer, any cause or event which is beyond the control and not due to the negligence of the Servicer, which delays, prevents or prohibits such Person’s delivery of the reports required to be delivered or the performance of any other duty or obligation of the Servicer under the Indenture, as the case may be, including, without limitation, computer, electrical and mechanical failures, acts of God or the elements and fire; provided, that no such cause or event shall be deemed to be a Force Majeure Delay unless the Servicer shall have given the Indenture Trustee written notice thereof as soon as practicable after the beginning of such delay.
Elevator mechanic means any person who possesses an elevator
utility structure means transmission and distribution lines
Excluded Downtime has the meaning set forth in Section 2 below.
Generator Maintenance Outage means the scheduled removal from service, in whole or in part, of a generating unit in order to perform necessary repairs on specific components of the facility, if removal of the facility meets the guidelines specified in the PJM Manuals.
Tenant Delays means (A) Tenant’s request for changes to Landlord’s Work, regardless of whether any such changes are performed, (B) construction of any such changes, (C) Tenant’s request for materials, finishes, or installations requiring unusually long lead times that were not originally included as a part of Landlord’s Work, (D) Tenant’s delay (which shall mean more than 5 business days) in reviewing, revising, or approving any plans and specifications relating to Landlord’s Work, (E) Tenant’s delay in providing information critical to the normal progression of the Project (Tenant shall provide such information as soon as reasonably possible, but in no event longer than 5 business days after receipt of any request for such information from Landlord), and (F) any other act or omission by Tenant or any Tenant Party (as defined herein), or persons employed by any of such persons, (iv) “Substantially Completed” means the substantial completion of Landlord’s Work (A) in a good and workmanlike manner, (B) in accordance with the requirements described in Exhibit C, and (C) in accordance with all applicable Legal Requirements (including, but not limited to, securing the applicable final building inspection for Landlord’s Work), subject only to normal “punch list” items, and (v) “Existing Tenant Delay” means the refusal or failure by the Existing Tenant (as defined below) to surrender the Premises by July 1, 2010 in accordance with the terms and conditions of the Existing Lease (as defined below). Landlord will promptly perform such punch list items. Tenant shall obtain, at its sole cost and expense, any applicable use and occupancy permit for the Premises issued by the applicable Governmental Authority. If Tenant does not elect to void this Lease within 5 business days of the lapse of such 60 day period, such right to void this Lease shall be waived and this Lease shall remain in full force and effect. If neither Landlord nor Tenant elects to void this Lease within 5 business days of the lapse of such 60 day period, such right to void this Lease shall be waived and this Lease shall remain in full force and effect. Sequoia Pharmaceuticals, Inc. (“Existing Tenant”), is currently leasing the Premises from Landlord, and the lease agreement (“Existing Lease”) between Landlord and Existing Tenant is scheduled to expire on July 1, 2010 subject to Landlord’s right to advance the expiration date. Tenant understands, acknowledges, and agrees that Landlord makes no guaranty, representation, or assurance that Landlord will be able to recapture the Premises from the Existing Tenant by July 1, 2010 and that Landlord shall have no obligation or duty to seek the vacation or removal of the Existing Tenant from the Premises.
Natural gas utility means an investor-owned business engaged in the sale and distribution of natural gas within this state whose rates are regulated by the commission.
Utility vehicle means a motor vehicle that is (i) designed for off-road use, (ii) powered by an
Building, structure, facility, or installation means all of the pollutant-emitting activities which belong to the same industrial grouping, are located on one or more contiguous or adjacent properties, and are under the control of the same person (or persons under common control) except the activities of any vessel. Pollutant-emitting activities shall be considered as part of the same industrial grouping if they belong to the same major group (i.e., which have the same two-digit code) as described in the Standard Industrial Classification Manual, 1972, as amended by the 1977 Supplement (U.S. Government Printing Office stock numbers 4101-0066 and 003-005-00176-0, respectively).
Tenant Delay means an actual delay in the occurrence of the Substantial Completion Date or the Final Completion Date with respect to Landlord’s Work as the result of: (1) any unreasonable delay by Tenant in approving the Plans; (2) any request by Tenant that Landlord delay the commencement or completion of Landlord’s Work for any reason; (3) any request by Tenant to change the Plans after initial approval thereof by Tenant, or the making of any changes to Landlord’s Work requested by Tenant and agreed to by Landlord after initial approval of the Plans by Tenant; (4) any failure by Tenant to respond in writing within seven (7) business days after any written request by Landlord for clarification or interpretation of the Plans or for approval of changes in the Plans deemed necessary by Landlord; or (5) any other act or omission of Tenant or its officers, agents, employees or contractors; Notwithstanding the foregoing, no event shall be deemed to be a Tenant Delay until and unless Landlord has given Tenant written notice (the “Tenant Delay Notice”) advising Tenant (i) that a Tenant Delay is occurring, (ii) of the basis on which Landlord has determined that a Tenant Delay is occurring, and (iii) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay, and Tenant has failed to correct the Tenant Delay specified in the Tenant Delay Notice within forty-eight (48) hours following receipt thereof. No period of time prior to expiration of such 48-hour period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice if Tenant corrects the Tenant Delay specified in the Tenant Delay Notice within such 48-hour period.
Electric utility steam generating unit means any steam electric generating unit that is constructed for the purpose of supplying more than one-third of its potential electric output capacity and more than 25 MW electrical output to any utility power distribution system for sale. Any steam supplied to a steam distribution system for the purpose of providing steam to a steam-electric generator that would produce electrical energy for sale is also considered in determining the electrical energy output capacity of the affected facility.
Critical Energy Infrastructure Information means all information, whether furnished before or after the mutual execution of this Agreement, whether oral, written or recorded/electronic, and regardless of the manner in which it is furnished, that is marked “CEII” or “Critical Energy Infrastructure Information” or which under all of the circumstances should be treated as such in accordance with the definition of CEII in 18 C.F.R. § 388.13(c)(1). The Receiving Party shall maintain all CEII in a secure place. The Receiving Party shall treat CEII received under this agreement in accordance with its own procedures for protecting CEII and shall not disclose CEII to anyone except its Authorized Representatives.
Building Energy Benchmarking means the process of measuring a building’s Energy use, tracking that use over time, and comparing performance to similar buildings.
Interconnecting Utility means the utility (which may or may not be Buyer or an Affiliate of Buyer) providing interconnection service for the Facility to the Transmission System of that utility.
Utility Charges means water, sewer, electricity, gas and other utility charges, if any, applicable to the Real Property or the Leased Real Property;
Landlord Delay means a delay in the construction of the Tenant Improvements or Compliance Work resulting directly from the acts or omissions of Landlord, Landlord’s employees, agents, or contractors including, but not limited to (i) failure of Landlord to timely approve or disapprove any plans; (ii) interference by Landlord, its employees, agents or contractors with the completion of the Tenant Improvements or Compliance Work (including the impairment of Tenant’s contractors’ or vendors’ or employees’ access to the Premises for any reason (including due to the presence of Landlord’s contractors, vendors or personnel), failure to provide reasonable access to the Building’s loading docks or other facilities necessary for the construction of the Tenant Improvements or Compliance Work and/or the movement of materials and personnel to the Premises for such purpose) and (iii) delays due to the acts or failures to act of Landlord, its agents or contractors with respect to payment of the Tenant Improvement Allowance. If Tenant contends that a Force Majeure Construction Delay or a Landlord Delay has occurred, Tenant acknowledges and agrees that it has inspected the Building and the Site and in no event shall the physical character or condition of the Building and/or Site existing as of the Effective Date constitute a basis for a Landlord Delay (this agreement does not apply to the failure of any Building component to properly operate). Further, in no event shall any delay of Landlord constitute a Landlord Delay unless such delay results in a full day of delay in the construction of the Tenant Improvements or Compliance Work. Tenant shall notify Landlord in writing (the “Delay Notice”) of the event which constitutes such Force Majeure Construction Delay or Landlord Delay; such notice may be via electronic mail to Landlord’s construction representative described above. Tenant will additionally use reasonable efforts to mitigate the effects of any Force Majeure Construction Delay or Landlord Delay through the re-sequencing or re-scheduling of work, if feasible, but this sentence will not be deemed to require Tenant to incur overtime or after-hours costs unless Landlord agrees in writing to bear such costs. If the actions or inactions or circumstances described in the Delay Notice constitute a Landlord Delay, and are not cured by Landlord within one (1) business day after Landlord’s receipt of the Delay Notice, then a Landlord Delay shall be deemed to have occurred commencing as of the expiration of such one (l)-business day period. The Lease Commencement Date and the Lease Expiration Date will each be delayed on a day for day basis for each day of Force Majeure Construction Delay or Landlord Delay.
Excusable Delays mean delays arising without the fault or negligence of Lessor and Lessor's subcontractors and suppliers at any tier, and shall include, without limitation: (1) acts of God or of the public enemy, (2) acts of the United States of America in either its sovereign or contractual capacity, (3) acts of another contractor in the performance of a contract with the Government, (4) fires, (5) floods, (6) epidemics, (7) quarantine restrictions, (8) strikes, (9) freight embargoes, (10) unusually severe weather, or (11) delays of subcontractors or suppliers at any tier arising from unforeseeable causes beyond the control and without the fault or negligence of both the Lessor and any such subcontractor or supplier.
Ground water means water below the land surface in a zone of saturation.
Utility system means a water system, solid waste
Excusable Delay means a delay due to acts of God, governmental restrictions, stays, judgments, orders, decrees, enemy actions, civil commotion, fire, casualty, strikes, work stoppages, shortages of labor or materials or other causes beyond the reasonable control of Borrower, but lack of funds in and of itself shall not be deemed a cause beyond the control of Borrower.
Modular building retailer means any person who purchases or acquires a modular building from a
Generator Planned Outage means the scheduled removal from service, in whole or in part, of a generating unit for inspection, maintenance or repair with the approval of the Office of the Interconnection in accordance with the PJM Manuals.
Rechargeable Electrical Energy Storage System (REESS) means the rechargeable energy storage system that provides electric energy for electrical propulsion.
Specified anatomical areas means and includes:
Utility Costs means utility and home energy costs related to the occupancy of rental property (e.g. electricity, gas, water and sewer, trash removal, and energy costs (such as fuel oil)) that are separately-stated charges. Utility Costs do not include telecommunication services (e.g. telephone, cable, and internet services).