UNIT COMPLETION DATE definition

UNIT COMPLETION DATE. With respect to the Ammonia Project, thirty (30) months from the date on which the Initial Advance is made by Owner to Agent pursuant to Section 4 hereof plus any Force Majeure Delay, and with respect to any other Unit, as agreed to in writing among Agent, Owner and any Assignee.
Sample 1
UNIT COMPLETION DATE means the date which, with respect to a Unit, is nine (9) Calendar Months after the date such Unit first becomes Eligible Collateral or such later date (not later than the expiration of the applicable Unit Term) as may be appropriate by reason of a Force Majeure Event.
Sample 1
UNIT COMPLETION DATE. With respect to the Headquarters Unit, December -------------------- 31, 1998 and with respect to any other Unit, such date as shall be agreed to in writing between Owner and Agent (i) in the case of a Redwood Unit, as a condition to the Construction Advance for such Unit (which date shall not, in any event, be later than December 31, 2011), and (ii) in the case of any other Unit, as a condition to the Initial Advance for such Unit.
Sample 1

More Definitions of UNIT COMPLETION DATE

UNIT COMPLETION DATE. With respect to the Ammonia Project, May 15, 1998, unless an extension of the Unit Completion Date shall be agreed to in writing among Agent, Owner and any Assignee, and with respect to any other Unit, as agreed to in writing among Agent, Owner and any Assignee.
Sample 1
UNIT COMPLETION DATE. With respect to each Unit subject hereto (other than the Unit Premises located at Seville, Ohio and Laredo, Texas), twenty-four (24) months from the date of this Agreement and, with respect to the Unit Premises located at Seville, Ohio and Laredo, Texas (or any two Unit Premises substituted (by Agent in Agent's sole discretion) for the Unit Premises located at Seville, Ohio and Laredo, Texas), thirty (30) months from the date of this Agreement, unless such Unit Completion Date is extended by any Force Majeure Delay. The right of substitution set forth in the preceding sentence may be exercised by Agent more than once, in each case upon written notice to Owner prior to the expiration of such twenty-four (24) month period. UNIT FF&E: The specific items, if any, from the FF&E Specifications which are installed or (if such FF&E Specifications have been acquired by Owner for installation) to be installed in a particular Unit Improvement and for which advances are made by Owner hereunder.
Sample 1
UNIT COMPLETION DATE. With respect to the North Shoreline Unit, thirty (30) months from the date on which the Initial Advance is made by Owner to Agent pursuant to Section 4 hereof and with respect to any other Unit, such period as is agreed to in writing between Agent and Owner.
Sample 1
UNIT COMPLETION DATE means, in relation to a Unit, the day upon which CEPA certifies that such Unit, capable of operating in accordance with the Operation Parameters, has successfully completed its testing in accordance with Article 4 or would have had had NPC performed its obligations under this Agreement relating to the Site, the Ash Disposal Sites, the Access Road and the Pipelines, Fuel and electricity for testing and commissioning and start-up of the Power Station and the taking of electricity and the Transmission Line in a timely manner;
Sample 1
UNIT COMPLETION DATE means the day upon which HOPEWELL certifies that a Unit, capable of operating in accordance with the Operating Parameters, has successfully completed its testing, or would have had had NAPOCOR performed its obligations hereunder relating to access (Articles 2.4, 2.5, 3.6) fuel and start-up electricity and the taking of electricity (Articles 2.9, 2.10, 4.4, 6.1 and 6.7) and transmission line (Articles 2.9, 3.6, 13) in a timely manner.
Sample 1
UNIT COMPLETION DATE means the date on which any Unit is Shipped.
Sample 1

Related to UNIT COMPLETION DATE

  • Completion Date means the date of completion of the Services by the Service Provider as certified by the Procuring Entity

  • Project Completion Date means the date on which the Completion Certificate is issued;

  • The Completion Date means the date of completion of the Works as certified by the Employer’s Representative.

  • Substantial Completion Date means the date on which Substantial Completion occurs.

  • Construction Completion Date means the Completion Date of the Construction as specified in the Statutory Declaration of Completion for the Project;

  • Final Completion Date means the date on which Final Completion occurs.

  • Target Completion Date has the meaning given such term in Section 3.3(b).

  • project completion period means the period of sixty (60) months commencing from and expiring on for the construction and obtaining of Temporary Occupation Permit or Permits for the whole of the Development as provided in clause 3.3;

  • Scheduled Completion Date shall be the date set forth in Clause 10.3;

  • Outside Completion Date shall have the meaning assigned to such term in Section 6.3(d).

  • Completion Period means the period starting from the date of issue of "Order" and required to complete the work in all respect.

  • Construction Commencement Date means the date set out in the Addendum, if applicable, by which you must commence construction of the Hotel. For the Hotel to be considered under construction, youmust have begun to pour concrete foundations for the Hotel or otherwise satisfied any site-specific criteria for “under construction” set out in the Addendum.

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:

  • Construction Period means the period commencing from the Appointed Date and ending on the date of the Completion Certificate;

  • COMPLETION TIME means the period by ‘date/month’ specified in the ‘Letter of Intent/Award’ or date mutually agreed upon for handing over of the intended scope of work, the erected equipment/plant which are found acceptable by the Engineer, being of required standard and conforming to the specifications of the Contract.

  • Commercial Operation Date means the date on which a Material Project is substantially complete and commercially operable.

  • Project Completion means the date, as determined by the Division after consultation with the Recipient, that operation of the Project is initiated or is capable of being initiated, whichever comes first.

  • Accumulation Commencement Date means January 1, 2021, or such later date as the Calculation Agent on behalf of the Issuer determines in accordance with Section 2.11 hereof.

  • Loan Commencement Date means, with respect to each Growth Capital Loan: (a) the first day of the first full calendar month following the Borrowing Date of such Loan if such Borrowing Date is not the first day of a month; or (b) the same day as the Borrowing Date if the Borrowing Date is the first day of a month.

  • Start-up period means up to a maximum of 7 Academy Financial Years and covers the period up to and including the first Academy Financial Year in which all age groups are present at the Academy (that is, all the pupil cohorts relevant to the age-range of the Academy will have some pupils present).

  • Completion Deadline means the date by which the Arrangement is to be completed, which date shall be April 30, 2014 or such later date as may be agreed to in writing by the Parties;

  • Vesting Commencement Date means the Grant Date or such other date selected by the Committee as the date from which an Award begins to vest.

  • Final Completion means the date determined and certified by A/E and Owner on which the Work is fully and satisfactorily complete in accordance with the Contract.

  • Project Start Date means the first Milestone Start Date specified in Schedule B;

  • Construction Completion means physical construction of a cleanup action component is complete.

  • Outside Date has the meaning set forth in Section 8.1(b).