Common use of 252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998 Clause in Contracts

252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998. This contract incorporates the following clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this address: xxxx://xxx.xxxxxxxxxxx.xxx/far/ or xxxx://xxxxxxx.xxxx.xx.xxx/vffara.htm These addresses are subject to change. If the Federal Acquisition Regulation (FAR) is not available at the locations indicated above, use the Department of State Acquisition website at xxxx://xxx.xxxxxxxx.xxxxx.xxx/ to see the links to the FAR. You may also use an internet “search engine” (for example, Google, Yahoo, Excite) to obtain the latest location of the most current FAR. The following Federal Acquisition Regulation clauses are incorporated by reference: CLAUSE TITLE AND DATE 52.242-15 STOP WORK ORDER (AUG 1989) 52.242-17 GOVERNMENT DELAY OF WORK (APR 1984)

252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998. This contract incorporates the following clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this address: xxxx://xxx.xxxxxxxxxxx.xxx/far/ or xxxx://xxxxxxx.xxxx.xx.xxx/vffara.htm These addresses are subject to change. If the Federal Acquisition Regulation (FAR) is not available at the locations indicated above, use the Department of State Acquisition website at xxxx://xxx.xxxxxxxx.xxxxx.xxx/ to see the links to the FAR. You may also use an internet “search engine” (for example, Google, Yahoo, Excite) to obtain the latest location of the most current FAR. The following Federal Acquisition Regulation clauses clause(s) is/are incorporated by reference: CLAUSE TITLE AND DATE 52.24252.246-15 STOP WORK ORDER 4 INSPECTION OF SERVICES - FIXED PRICE (AUG 1989) 52.242-17 GOVERNMENT DELAY OF WORK (APR 19841996)

252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998. This contract incorporates the following clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this address: xxxx://xxx.xxxxxxxxxxx.xxx/far/ or xxxx://xxxxxxx.xxxx.xx.xxx/vffara.htm These addresses are subject to change. If the Federal Acquisition Regulation (FAR) is not available at the locations indicated above, use the Department of State Acquisition website at xxxx://xxx.xxxxxxxx.xxxxx.xxx/ to see the links to the FAR. You may also use an internet a network “search engine” (for example, Google, Yahoo, Excite) to obtain the latest location of the most current FAR. The following Federal Acquisition Regulation clauses are incorporated by reference: CLAUSE TITLE AND DATE 52.242-15 STOP WORK ORDER (AUG 1989) 52.242-17 GOVERNMENT DELAY OF WORK (APR 1984)DATE

252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998. This contract incorporates the following clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, Also the full text of a clause may be accessed electronically at this addressat: xxxx://xxx.xxxxxxxxxxx.xxx/far/ or xxxx://xxxxxxx.xxxx.xx.xxx/vffara.htm xxxx://xxxxxxx.xxxx.xx.xxx/vffara.htm. These addresses are subject to change. If the Federal Acquisition Regulation (FAR) is not available at the locations indicated above, use the Department of State Acquisition website at xxxx://xxx.xxxxxxxx.xxxxx.xxx/ to see the links to the FAR. You may also use an internet “search engine” (for example, Google, Yahoo, Excite) to obtain the latest location of the most current FAR. The following Federal Acquisition Regulation clauses Regulations are incorporated by reference: CLAUSE TITLE AND DATE 52.24252.246-15 STOP WORK ORDER 4 INSPECTION OF SERVICES - FIXED-PRICE (AUG 19891996) 52.24252.246-17 GOVERNMENT DELAY OF WORK 6 INSPECTION - TIME-AND-MATERIAL AND LABOR-HOUR (APR 1984MAY 2001)