Acceptance of Agreement This Agreement shall not be considered accepted, approved or otherwise effective until the statutorily required approvals and certifications have been given.
Acceptance of AAU You will have accepted an AAU for an Offering if: (a) we receive your acceptance, prior to the time specified in the Invitation Wire for such Offering, by wire, telex, telecopy or electronic data transmission, or other written communication (any such communication being deemed “In Writing”) or orally (if promptly confirmed In Writing), in the manner specified in the Invitation Wire, of our invitation to participate in the Offering, or (b) notwithstanding that we did not send you an Invitation Wire or you have not otherwise responded In Writing to any such Wire, you: (i) agree (orally or by a Wire) to be named as an Underwriter in the relevant Underwriting Agreement executed by us as Manager, or (ii) receive and retain an economic benefit for participating in the Offering as an Underwriter. Your acceptance of the invitation to participate will cause such AAU to constitute a valid and binding contract between us. Your acceptance of the AAU as provided above or an Invitation Wire will also constitute acceptance by you of the terms of subsequent Wires to you relating to the Offering unless we receive In Writing, within the time and in the manner specified in such subsequent Wire, a notice from you to the effect that you do not accept the terms of such subsequent Wire, in which case you will be deemed to have elected not to participate in the Offering.
ACCEPTANCE AND FINAL PAYMENT Upon written notice to the Owner
Acceptance/Payment Unless otherwise agreed to in writing by County, 1) acceptance shall not be deemed complete unless in writing and until all the goods/services have actually been received, inspected, and tested to the satisfaction of County, and 2) payment shall be made in arrears after satisfactory acceptance.
Final Payment All items or Automated Clearing House (ACH) transfers credited to your account are provisional until we receive final payment. If final payment is not received, we may charge your account for the amount of such items or ACH transfers and impose a return item charge on your account. Any collection fees we incur may be charged to your account. We reserve the right to refuse or return any item or funds transfer.
Acceptance of Contract This contract shall not be considered accepted, approved or otherwise effective until the statutorily required approvals and certifications have been given.
NON-ACCEPTANCE OF SETTLEMENT AGREEMENT If, for any reason whatsoever, this Settlement Agreement is not accepted by the Hearing Panel or an Order in the form attached as Schedule “A” is not made by the Hearing Panel, each of Staff and the Respondent will be entitled to any available proceedings, remedies and challenges, including proceeding to a disciplinary hearing pursuant to sections 20 and 24 of By- law No. 1, unaffected by this Settlement Agreement or the settlement negotiations.
Acceptance of the Terms of Use These terms of use are entered into by and between you and Tribal Convenience Store Association ("Company", "we" or "us"). The following terms and conditions (these "Terms of Use") govern your access to and use of the Company’s website, xxxx://xxx.xxxxxxxxxxxxx.xxx, including any content, functionality and services offered on or through the website (the "Website"), whether as a guest or a registered user. Please read the Terms of Use carefully before you start to use the Website. By using the Website or by clicking to accept or agree to the Terms of Use when this option is made available to you, you accept and agree to be bound and abide by these Terms of Use. If you do not want to agree to these Terms of Use, you must not access or use the Website. This Website is offered and available only to users who are 18 years of age or older, and reside in the United States or any of its territories or possessions. By using this Website, you represent and warrant that you are of legal age to form a binding contract with the Company and meet the foregoing eligibility requirements. If you do not meet all of these requirements, you must not access or use the Website.
FINAL COMPLETION AND FINAL PAYMENT 9.9.1 Upon receipt of written notice that the Work is ready for final inspection and acceptance and upon receipt of a final Application for Payment, the Architect will promptly make such
9.9.2 Neither the final payment nor the remaining retained percentage shall become due until the Contractor submits to the Architect (1) an affidavit that all payrolls, bills for materials and equipment, and other indebtedness connected with the Work for which the State or its property might in any way be responsible, have been paid or otherwise satisfied; (2) consent of surety, if any, to final payment; (3) Other data establishing payment or satisfaction of all such obligations, including, but not limited to, receipts, releases, or other supporting documentation. and (4) final waivers of liens arising out of the Contract, to the extent and in such form as may be designated by the State. If any Subcontractor refuses to furnish a release or waiver required by the State, the Contractor may furnish a bond satisfactory to the State to indemnify him against any such lien. If any such lien remains unsatisfied after all payments are made, the Contractor shall refund to the State all moneys that the latter may be compelled to pay in discharging such lien, including all costs and reasonable attorneys' fees.
9.9.3 If, after Substantial Completion of the Work, final completion thereof is materially delayed through no fault of the Contractor or by the issuance of Change Orders affecting final completion, and the Architect so confirms, the State shall, upon application by the Contractor and certification by the Architect, and without terminating the Contract, make payment of the balance due for that portion of the Work fully completed and accepted. If the remaining balance for Work not fully completed or corrected is less than the retainage stipulated in the Contract Documents, and if bonds have been furnished as required by the Contract Documents, the written consent of the surety to the payment of the balance due for that portion of the Work fully completed and accepted shall be submitted by the Contractor to the Architect prior to certification of such payment. Such payment shall be made under the terms and conditions governing final payment, except that it shall not constitute a waiver of claims.
9.9.4 The making of final payment shall constitute a waiver of all claims by the State except those arising from:
(a) unsettled liens,
(b) faulty or defective Work appearing after Substantial Completion,
(c) failure of the Work to comply with the requirements of the Contract Documents, or
(d) terms of any special warranties required by the Contract Documents.
9.9.5 The acceptance of final payment shall constitute a waiver of all claims by the Contractor except those previously made in writing and identified by the Contractor as unsettled at the time of the final Application for Payment.
Acceptance of Appointment; Standard of Performance Adviser accepts the appointment as discretionary portfolio manager and agrees to use its best professional judgment to make timely investment decisions for the Fund in accordance with the provisions of this Agreement.
