Termination and Suspension Customer is entitled to suspend the performance of its obligations in whole or in part or terminate the Agreement with immediate effect, without prejudice to its right to claim damages and without any compensation to or indemnification of Supplier (i) in case Supplier has been declared bankrupt, is in a state of liquidation, has ceased or suspended whole or a substantial part of its business, is subject of a court order or preventative legal scheme of settlement, (ii) in case of non- compliance with the Compliance Requirements or the provisions of safety, health, environment and security or (iii) in case of not approved changes pursuant to article 10. After such termination Customer may return received Goods and/or Services in whole or partly against repayment and retransfer of ownership therein to Supplier.
Effective Date; Termination; Cancellation and Suspension Section 4.01. This Agreement shall come into force and effect on the date upon which the Development Credit Agreement becomes effective. Section 4.02. (a) This Agreement and all obligations of the Association and of Republika Srpska thereunder shall terminate on the earlier of the following two dates: (i) the date on which the Development Credit Agreement shall terminate; or (ii) a date twenty (20) years after the date of this Agreement.
DISCHARGE AND SUSPENSION A. A suspended or discharged seniority employee will be allowed to discuss his/her suspension or discharge with the President or Vice President. The Board will allow the discussion before the employee is required to leave the property of the Board. If the President or Vice President is not available during the discharged employee’s shift, the employee may meet with the President or Vice President on Board property up to twenty-four hours after the end of his/her shift. Nothing contained herein, however, shall prevent the Board from requiring the summary removal of the offending employee if it appears that the safety of any person, property, or the maintenance of order requires such summary removal. The President or Vice President will not allow other employees to become involved in the discussion. Upon request of the Association, the Board’s designated representative will discuss the suspension with the Association representative and the employee. B. Grievances protesting the discharge or suspension will commence at Step Two and must be filed within three (3) working days after the action was taken. Failure to abide by this time limit shall be construed as a waiver, by both the Association and the employee involved, of any protest of the action. If a seniority employee is notified that he/she will be suspended, the suspension will not take effect, if a timely grievance has been filed, until after the third (3) step of the grievance procedure, unless the Board deems it is necessary to immediately suspend for maintenance of order, safety of person(s) or property. C. Any award of back wages shall be limited to the amount of wages that the employee would otherwise have earned, less any compensation that he/she may have received from any source during the period of back pay. D. The Board has the right to discharge for just cause. No seniority bargaining unit member shall be disciplined without just cause. E. The Board agrees, when suspending or discharging an employee, to notify, in writing, the employee and the Association, including the UniServ Director. F. In imposing discipline on a current charge, the Board will not take into account prior infractions which occurred more than two (2) years previously, nor impose discipline on an employee for inadvertent errors or mistakes on his/her employment application, after a period of one year from his/her date of seniority, except in cases of felony convictions.
CERTIFICATION REGARDING DEBARMENT AND SUSPENSION The undersigned (authorized official signing for the contracting organization) certifies to the best of his or her knowledge and belief, that the contractor, defined as the primary participant in accordance with 45 CFR Part 76, and its principals: are not presently debarred, suspended, proposed for debarment, declared ineligible, or voluntarily excluded from covered transactions by any Federal Department or agency have not within a 3-year period preceding this contract been convicted of or had a civil judgment rendered against them for commission of fraud or a criminal offense in connection with obtaining, attempting to obtain, or performing a public (Federal, State, or local) transaction or contract under a public transaction; violation of Federal or State antitrust statutes or commission of embezzlement, theft, forgery, bribery, falsification or destruction of records, making false statements, or receiving stolen property; are not presently indicted or otherwise criminally or civilly charged by a governmental entity (Federal, State, or local) with commission of any of the offenses enumerated in Section 2 of this certification; and have not within a 3-year period preceding this contract had one or more public transactions (Federal, State, or local) terminated for cause or default. Should the Contractor or Subrecipient not be able to provide this certification, an explanation as to why should be placed after the assurances page in the contract. The contractor agrees by signing this contract that it will include, without modification, the clause above certification in all lower tier covered transactions (i.e., transactions with sub-grantees and/or contractors) and in all solicitations for lower tier covered transactions in accordance with 45 CFR Part 76.
Term, Termination and Suspension 18.1 This Agreement shall be effective from the Effective Date for the Term. The Service shall commence on the Commencement Date and continue until the Completion Date, whereupon this Agreement shall expire unless terminated earlier in accordance with its terms. 18.2 You shall not commence any additional service in the event of notification of termination of this Agreement, however, in the event that service is provided to us beyond the Completion Date, the terms and conditions of this Agreement shall continue on a day-to-day basis terminable without cause upon twenty-four (24) hours prior written notice by either party to the other. 18.3 Either party may terminate a Service or this Agreement, in part or in whole, during the Term upon prior written notice without cause in accordance with the termination notice period as set out in Schedule 1. 18.4 We may terminate this Agreement at any time based upon your default of your obligations under this Agreement. We, in our sole discretion, may provide you with a notice to cure (“Cure Notice”) the breach that would otherwise amount to a basis to terminate this Agreement as a result of your failure to fulfill your obligations hereunder. You shall respond to any such Cure Notice within a reasonable time or within such time as provided therein, and you shall either cure the specified breach or provide assurances to cure the same which we, in our sole discretion, deem adequate. 18.5 Either party may terminate this Agreement immediately, if the other party: (a) commits an irremediable breach; or (b) is subject to a change of control or chooses to discontinue its business; or (c) if the other party has a lack of funding or becomes or is deemed insolvent; or (d) if the other party’s performance is affected by a force majeure event which lasts seven (7) days or more. 18.6 In the event of termination of this Agreement, all Fees then due and payable shall be paid to you. 18.7 Upon expiry or termination of this Agreement, you shall return all Government property or information or you shall irretrievably delete, as commercially practicable as possible, all Confidential Information, stored in any way using any device or application and all matter derived from such sources which is in your possession, custody or power and provide a signed statement that you have fully complied with your obligations under this section, save for any back-up required by law or as required in accordance with your record retention policy. 18.8 Upon expiry or termination of this Agreement, you shall provide us with all such assistance as may be reasonably necessary in order to end the relationship in a manner which causes the least inconvenience to us including assisting with the transfer of Data. 18.9 We may temporarily suspend a Service hereunder and shall confirm such instruction in writing to you. 18.10 Upon any such suspension, we shall pay all Fees and Expenses up until the time of such suspension of a Service. If, following suspension of a Service, there is no resumption within six (6) months, this Agreement may be terminated by you, and us shall make a payment of all outstanding Fees and Expenses in accordance with this Agreement if such amounts are due. 18.11 We may issue a written order to resume the provision of the Service within six (6) months of suspension in accordance with the terms and conditions of this Agreement. 18.12 The rights arising under this termination section represent your sole remedy and excludes common law rights to terminate and claim damages for any Loss you may suffer under this Agreement.
Certification Regarding Debarment, Suspension, Ineligibility and Voluntary Exclusion First Tier Participants: a. The prospective first tier participant certifies to the best of its knowledge and belief, that it and its principals: (1) Are not presently debarred, suspended, proposed for debarment, declared ineligible, or voluntarily excluded from participating in covered transactions by any Federal department or agency; (2) Have not within a three-year period preceding this proposal been convicted of or had a civil judgment rendered against them for commission of fraud or a criminal offense in connection with obtaining, attempting to obtain, or performing a public (Federal, State or local) transaction or contract under a public transaction; violation of Federal or State antitrust statutes or commission of embezzlement, theft, forgery, bribery, falsification or destruction of records, making false statements, or receiving stolen property; (3) Are not presently indicted for or otherwise criminally or civilly charged by a governmental entity (Federal, State or local) with commission of any of the offenses enumerated in paragraph (a)(2) of this certification; and (4) Have not within a three-year period preceding this application/proposal had one or more public transactions (Federal, State or local) terminated for cause or default. b. Where the prospective participant is unable to certify to any of the statements in this certification, such prospective participant shall attach an explanation to this proposal.
Cancellation and Suspension This Agreement shall come into force and effect on the date upon which the Loan Agreement becomes effective.
CERTIFICATION REGARDING DEBARMENT, SUSPENSION, INELIGIBILITY AND VOLUNTARY EXCLUSION
CONDITIONS OF SETTLEMENT, EFFECT OF DISAPPROVAL, CANCELLATION OR TERMINATION 9.1. The Effective Date of this Settlement Agreement shall not occur unless and until each and every one of the following events occurs: (a) This Agreement has been signed by the Parties and Class Counsel, and the individual settlement agreements with Xxxxxxxxx Xxxxx, the heirs of Xxxxx Xxxxx, Xxxxxx Xxxxxxxxx, and Xxxxxx Xxxxxxxx-Xxx have been fully executed; (b) The Court has entered an order granting Preliminary Approval of the Agreement; (c) The Court has entered a Final Approval Order finally approving the Agreement, or a judgment substantially consistent with this Settlement Agreement that has become final and unappealable, following Notice and a Final Approval Hearing, as provided in the Federal Rules of Civil Procedure; and (d) In the event that the Court enters an approval order and final judgment in a form other than that provided above (“Alternative Approval Order”) to which the Parties have consented, that Alternative Approval Order has become final and unappealable. 9.2. If some or all of the conditions specified in Paragraph 9.1 are not met, or in the event that this Settlement Agreement is not approved by the Court, or the settlement set forth in this Agreement is terminated or fails to become effective in accordance with its terms, then this Settlement Agreement shall be canceled and terminated subject to Paragraph 9.3, unless Class Counsel and Defendant’s Counsel mutually agree in writing to proceed with this Agreement. If any Party is in material breach of the terms hereof, any other Party, provided that it is in substantial compliance with the terms of this Agreement, may terminate this Agreement on notice to all other Parties. Notwithstanding anything herein, the Parties agree that the Court’s decision as to the amount of the Illinois Fee Award and Ohio Fee Award to Class Counsel set forth above or the incentive award to the Class Representatives, regardless of the amounts awarded, shall not prevent the Agreement from becoming effective, nor shall it be grounds for termination of the Agreement. 9.3. If this Agreement is terminated or fails to become effective for the reasons set forth in Paragraphs 6.1, 6.2, 9.1, or 9.2 above, the Parties shall be restored to their respective positions in the Action as of the date of the signing of this Agreement. In such event, any Final Approval Order or other order entered by the Court in accordance with the terms of this Agreement shall be treated as vacated, nunc pro tunc, and the Parties shall be returned to the status quo ante with respect to the Actions as if this Agreement had never been entered into, including Defendant’s right to seek to compel arbitration as to the Plaintiffs named in the Second Amended Complaint. 9.4. In the event the Settlement is terminated or fails to become effective for any reason, the Illinois Settlement Fund and Ohio Settlement Fund, together with any earnings thereon at the same rate as earned, less any taxes paid or due, less Settlement Administrative Expenses actually incurred and paid or payable from the Settlement Fund, shall be returned to Defendant or its Insurer within thirty (30) calendar days after written notification of such event in accordance with instructions provided by Defendant’s Counsel to the Settlement Administrator.
Amendments, Suspension and Termination To the extent permitted by the Plan, this Agreement may be wholly or partially amended or otherwise modified, suspended or terminated at any time or from time to time by the Board or the Committee. Except as provided in the preceding sentence, this Agreement cannot be modified, altered or amended, except by an agreement, in writing, signed by both the Partnership and the Participant.
