Acquisition of other Rolling stock by the Concessionaire. 1. The Concessionaire may at any time lease (use) or purchase any additional rolling stock. Any contract related to these acquisitions is independent of this Agreement.
Acquisition of other Rolling stock by the Concessionaire Sample Clauses
Related to Acquisition of other Rolling stock by the Concessionaire
Damages for delay by the Concessionaire In the event that (i) the Concessionaire does not procure fulfilment of any or all of the Conditions Precedent set forth in Clause 4.1.3 within a period of 180 (one hundred and eighty) days from the date of this Agreement, and (ii) the delay has not occurred as a result of failure to fulfil the obligations under Clause 4.1.2 or other breach of this Agreement by the Authority, or due to Force Majeure, the Concessionaire shall pay to the Authority Damages in an amount calculated at the rate of 0.2% (zero point two per cent) of the Performance Security for each day's delay until the fulfilment of such Conditions Precedent, subject to a maximum of 20% (twenty percent) of the Performance Security.
Substitution of Concessionaire At any time during the period of Suspension, the Lenders‟ Representative, on behalf of Senior Lenders, shall be entitled to substitute the Concessionaire under and in accordance with the Substitution Agreement, and upon receipt of notice thereunder from the Lenders‟ Representative, the Authority shall withhold Termination for a period not exceeding 180 (one hundred and eighty) days from the date of Suspension, and any extension thereof under Clause 36.1, for enabling the Lenders‟ Representative to exercise its rights of substitution on behalf of Senior Lenders.
Audits by The District and Correction of Accounts During the term of this Agreement and for a period of six (6) years following the termination of this Agreement, the District may begin an audit of Contractor’s provision of goods and/or services under this Agreement. Contractor agrees to retain and make available for inspection all of its records pertaining to its performance of this Agreement, including billing records and any banking records that may reflect proceeds from any transactions with the District, during the term of this Agreement and for at least six (6) years following the termination of this Agreement. If Contractor receives notice that The District is auditing its performance under this Agreement or litigation results from this Agreement, then Contractor agrees to retain and make available for inspection all of its records pertaining to its performance of this Agreement, including billing records and any banking records that may reflect proceeds from any transactions with the District, for an additional three (3) years following the conclusion of the audit or the entry of a final judgment in any such litigation and the final resolution of any possible appeals of a final judgment in any such litigation. If the District determines as result of its audit, that Contractor has failed to satisfy the invoicing or documentation requirements of this Agreement, has improperly billed the District for goods and/or services that were not actually provided, or has overcharged the District for goods and/or services that were actually provided by Contractor, then Contractor shall repay the District, without interest, for any improper payments or overpayments made by the District to Contractor within thirty (30) days of a written demand by the District. If Contractor fails to repay the District for any improper payments or overpayments within thirty (30) days of the District’s written demand, then Contractor will owe the District interest accrued daily at the rate of 7.0% per annum from the date of the District’s written demand until the improper payment and/or overpayment is repaid in full by Contractor. Conversely, if an audit initiated by the District reveals that the District owes additional compensation to Contractor pursuant to the terms of this Agreement, then the District will pay the additional compensation to Contractor, without interest, within thirty (30) days of the completion of its audit. If the District fails to pay Contractor for any additional compensation owed under this Agreement within thirty (30) days after completion of its audit, then the District will pay Contractor interest on the additional compensation accrued daily at the rate of 7.0% per annum from the date of the completion of the District’s audit.
Compensation for default by the Concessionaire Subject to the provisions of Clause 35.6, in the event of the Concessionaire being in material default or breach of this Agreement, it shall pay to the Authority by way of compensation, all direct costs suffered or incurred by the Authority as a consequence of such material default or breach, within 30 (thirty) days of receipt of the demand supported by necessary particulars thereof; provided that no compensation shall be payable under this Clause 35.1 for any material breach or default in respect of which Damages are expressly specified and payable under this Agreement.
Sole purpose of the Concessionaire The Concessionaire having been set up for the sole purpose of exercising the rights and observing and performing its obligations and liabilities under this Agreement, the Concessionaire or any of its subsidiaries shall not, except with the previous written consent of the Authority, be or become directly or indirectly engaged, concerned or interested in any business other than as envisaged herein.
Conditions on Permitted Transfers In the event a Holder proposes to sell or transfer a Note, the Company may, but shall not be required to, impose reasonable conditions on such sale or transfer including, but not limited, to: (i) Notes may be transferred only in whole units, i.e., fractions of Notes may not be transferred; (ii) the transferee shall agree in writing to be bound by this Revenue Sharing Agreement; (iii) the transferor shall provide the Company with an opinion of counsel, satisfactory in form and substance to the Company’s counsel, stating that the transfer is exempt from registration under the Securities Act of 1933 and other applicable securities laws; and (iv) the transferor and transferee shall together pay in advance for any reasonable expenses the Company expects to incur in connection with the transfer, including attorneys’ fees.
Permitted Transfers Within Escrow 5.1 Transfer to Directors and Senior Officers
Permitted License Transfers As Licensee’s business operations may be altered, expanded or diminished, licenses granted hereunder may be transferred or combined for use at an alternative or consolidated site not originally specified in the license, including transfers between Agencies (“permitted license transfers”). Licensee(s) do not have to obtain the approval of Contractor for permitted license transfers, but must give thirty (30) days prior written notice to Contractor of such move(s) and certify in writing that the Product is not in use at the prior site. There shall be no additional license or other transfer fees due Contractor, provided that: i) the maximum capacity of the consolidated machine is equal to the combined individual license capacity of all licenses running at the consolidated or transferred site (e.g., named users, seats, or MIPS); or ii) if the maximum capacity of the consolidated machine is greater than the individual license capacity being transferred, a logical or physical partition or other means of restricting access will be maintained within the computer system so as to restrict use and access to the Product to that unit of licensed capacity solely dedicated to beneficial use for Licensee. In the event that the maximum capacity of the consolidated machine is greater than the combined individual license capacity of all licenses running at the consolidated or transferred site, and a logical or physical partition or other means of restricting use is not available, the fees due Contractor shall not exceed the fees otherwise payable for a single license for the upgrade capacity.
Suspension upon Concessionaire Default Upon occurrence of a Concessionaire Default, the Authority shall be entitled, without prejudice to its other rights and remedies under this Agreement including its rights of Termination hereunder, to (i) suspend all rights of the Concessionaire under this Agreement including the Concessionaire's right to collect charge(s), and other revenues pursuant hereto, and (ii) exercise such rights itself and perform the obligations hereunder or authorise any other person to exercise or perform the same on its behalf during such suspension (the "Suspension"). Suspension hereunder shall be effective forthwith upon issue of notice by the Authority to the Concessionaire and may extend up to a period not exceeding 180 (one hundred and eighty) days from the date of issue of such notice; provided that upon written request from the Concessionaire and the Lenders’ Representative, the Authority shall extend the aforesaid period of 180 (one hundred and eighty) days by a further period not exceeding 90 (ninety) days.
Amendment Relating to Transfers to Disqualified Organizations Xxxxxx Xxx and the Trustee may, without the consent of any Holders of the Certificates, upon notice to the Holders of the Residual Certificates, notwithstanding any provisions hereof to the contrary, amend this Trust Agreement in such manner as Xxxxxx Mae may direct; provided, however, that any such amendment shall be limited to such matters as, in the judgment of Xxxxxx Xxx, based upon the written advice of its tax counsel, are reasonably necessary (i) to ensure that the record ownership of, or any beneficial interest in, any Residual Certificate is not transferred, directly or indirectly, to a Disqualified Organization; and (ii) to provide for a means to compel the transfer of any Residual Certificate which is held by a Disqualified Organization to a Holder which is not a Disqualified Organization.
