Force Majeure Events a) Neither Party shall be responsible or liable for or deemed in breach hereof because of any delay or failure in the performance of its obligations hereunder (except for obligations to pay money due prior to occurrence of Force Majeure events under this Agreement) or failure to meet milestone dates due to any event or circumstance (a "Force Majeure Event") beyond the reasonable control of the Party experiencing such delay or failure, including the occurrence of any of the following:
i) acts of God;
ii) typhoons, floods, lightning, cyclone, hurricane, drought, famine, epidemic, plague or other natural calamities;
iii) acts of war (whether declared or undeclared), invasion or civil unrest;
iv) any requirement, action or omission to act pursuant to any judgment or order of any court or judicial authority in India (provided such requirement, action or omission to act is not due to the breach by the SPG or of any Law or any of their respective obligations under this Agreement);
v) inability despite complying with all legal requirements to obtain, renew or maintain required licenses or Legal Approvals;
vi) earthquakes, explosions, accidents, landslides; fire;
vii) expropriation and/or compulsory acquisition of the Project in whole or in part by Government Instrumentality;
viii) chemical or radioactive contamination or ionizing radiation; or
ix) damage to or breakdown of transmission facilities of GETCO/ DISCOMs;
x) Exceptionally adverse weather condition which are in excess of the statistical measure of the last hundred (100) years.
Force Majeure If by reason of Force Majeure, either party hereto shall be rendered unable wholly or in part to carry out its obligations under this Agreement through no fault of its own then such party shall give notice and full particulars of Force Majeure in writing to the other party within a reasonable time after occurrence of the event or cause relied upon. Upon delivering such notice, the obligation of the affected party, so far as it is affected by such Force Majeure as described, shall be suspended during the continuance of the inability then claimed but for no longer period, and such party shall endeavor to remove or overcome such inability with all reasonable dispatch. In the event that Vendor’s obligations are suspended by reason of Force Majeure, all TIPS Sales accepted prior to the Force Majeure event shall be the legal responsibility of Vendor and the terms of the TIPS Sale Supplemental Agreement shall control Vendor’s failure to fulfill for a Force Majeure event.
Conduct of Third Party Claims If the matter or circumstance that may give rise to a Claim other than a Tax Claim is a result of or in connection with a claim by a third party (a “Third Party Claim”) then:
11.4.1 the Purchaser shall, to the extent reasonably practicable and subject to Applicable Law, consult with the Seller in relation to the conduct of the Third Party Claim and shall take reasonable account of the views of the Seller before taking any action in relation to the Third Party Claim;
11.4.2 no admissions in relation to the Third Party Claim shall be made by or on behalf of the Purchaser or any member of the Purchaser’s Group and the Third Party Claim shall not be compromised, disposed of or settled without the written consent of the Seller, such consent not to be unreasonably withheld or delayed;
11.4.3 subject to the Seller indemnifying the Purchaser or member of the Purchaser’s Group concerned against all reasonable costs and expenses (including legal and professional costs and expenses) that may be incurred thereby, the Purchaser shall, or the Purchaser shall procure that the members of the Purchaser’s Group shall, take such action as the Seller may reasonably request to avoid, dispute, deny, defend, resist, appeal, compromise or contest the Third Party Claim;
11.4.4 the Seller shall, subject in each case to being paid all reasonable out-of-pocket costs and expenses:
(i) make available to the Purchaser and the relevant Group Company such persons and all such information as the Purchaser may reasonably request for assessing, contesting, disputing, defending, compromising or appealing the Third Party Claim; and
(ii) shall give the Purchaser and the relevant Group Company reasonable access to its premises and to its books and records for such purpose during normal business hours on any Business Day following reasonable notice being given to the Seller;
11.4.5 subject to 11.4.3, the Seller shall be entitled at its own expense and in its absolute discretion, by notice in writing to the Purchaser, to assume conduct of any Third Party Claim and to have the conduct of any related proceedings, negotiations or appeals;
11.4.6 if the Seller sends a notice to the Purchaser pursuant to Clause 11.4.5 and until such time as any final compromise, agreement, expert determination or non-appealable decision of a court or tribunal of competent jurisdiction is made in respect of that Third Party Claim or that Third Party Claim is otherwise finally disposed of:
(i) the Purchaser shall, and the Purchaser shall procure that any member of the Purchaser’s Group shall:
(a) give, subject to being paid all reasonable costs and expenses, all such information and assistance including access to premises and personnel, and the right to examine and copy or photograph any assets, accounts, documents and records (excluding, in each case, information or documents which are protected by legal professional privilege but including, in each case, information or documents that are subject to common interest privilege), as the Seller may reasonably request, including instructing such professional or legal advisers as the Seller may nominate to act on behalf of the Purchaser or other member of the Purchaser’s Group concerned but in accordance with the Seller’s instructions, provided that the appointment of such adviser or advisers shall have been approved in writing by the Purchaser (such approval not to be unreasonably withheld, conditioned or delayed); and
(b) not make any admission of liability, agreement or compromise in relation to that Third Party Claim without the prior written approval of the Seller (such approval not to be unreasonably withheld, conditioned or delayed);
(ii) the Seller shall:
(a) consult with the Purchaser and take reasonable account of the views of the Purchaser before taking any action in relation to the Third Party Claim;
(b) without prejudice to its ability to defend the Third Party Claim, conduct the Third Party Claim with a view to minimising any material harm to the goodwill and reputation of the Wider Group or the Purchaser’s Group;
(c) keep the Purchaser informed of all relevant matters relating to the Third Party Claim and shall promptly forward or procure to be forwarded to the Purchaser copies of all correspondence and other written communications with such other information, including non-written records (except information or documents which are protected by legal professional privilege), relating to the Third Party Claim;
(d) not make any admission of liability, settlement or compromise of the Third Party Claim without the written consent of the Purchaser, such consent not to be unreasonably withheld, conditioned or delayed. If the Purchaser or member of the Purchaser’s Group fails to consent to a settlement or compromise, the maximum liability of the Seller shall (without prejudice to Clause 10) not exceed the full amount of the proposed settlement or compromise and the Purchaser or member of the Purchaser’s Group shall be liable for any damages awarded in excess of the proposed settlement or compromise and costs incurred from (and including) the date the Seller notified the Purchaser of the settlement or compromise; and
(e) indemnify, save as set out in Clause 11.4.6(ii)(d), the Purchaser or other member of the Purchaser’s Group concerned against all reasonable costs and expenses (including legal and professional costs and expenses) that may be incurred as a result of the Seller assuming conduct of the Third Party Claim.
11.4.7 The covenants in this Clause 11.4 may be enforced:
(i) by any Group Company against the Seller; and
(ii) by any member of the Seller’s Group against the Purchaser or a Group Company, under the Contracts (Rights of Third Parties) Xxx 0000.
11.4.8 The provisions of this Clause 11.4 may be varied or terminated by agreement between the Seller and the Purchaser (and the Purchaser may also release or compromise in whole or in part any liability in respect of rights or claims contemplated by this Clause 11.4) without the consent of any Group Company.
Settlement of Third Party Claims Notwithstanding any other provision of this Agreement, the Indemnifying Party shall not enter into settlement of any Third Party Claim without the prior written consent of the Indemnified Party, except as provided in this Section 8.05(b). If a firm offer is made to settle a Third Party Claim without leading to liability or the creation of a financial or other obligation on the part of the Indemnified Party and provides, in customary form, for the unconditional release of each Indemnified Party from all liabilities and obligations in connection with such Third Party Claim and the Indemnifying Party desires to accept and agree to such offer, the Indemnifying Party shall give written notice to that effect to the Indemnified Party. If the Indemnified Party fails to consent to such firm offer within ten days after its receipt of such notice, the Indemnified Party may continue to contest or defend such Third Party Claim and in such event, the maximum liability of the Indemnifying Party as to such Third Party Claim shall not exceed the amount of such settlement offer. If the Indemnified Party fails to consent to such firm offer and also fails to assume defense of such Third Party Claim, the Indemnifying Party may settle the Third Party Claim upon the terms set forth in such firm offer to settle such Third Party Claim. If the Indemnified Party has assumed the defense pursuant to Section 8.05(a), it shall not agree to any settlement without the written consent of the Indemnifying Party (which consent shall not be unreasonably withheld or delayed).
Force Majeure Exclusions 11.4.1 Force Majeure shall not include (i) any event or circumstance which is within the reasonable control of the Parties and (ii) the following conditions, except to the extent that they are consequences of an event of Force Majeure:
a. Unavailability, late delivery, or changes in cost of the plant, machinery, equipment, materials, spare parts or consumables for the Power Project;
x. Xxxxx in the performance of any contractor, sub-contractor or their agents;
c. Non-performance resulting from normal wear and tear typically experienced in power generation materials and equipment;
d. Strikes at the facilities of the Affected Party;
e. Insufficiency of finances or funds or the agreement becoming onerous to perform; and
f. Non-performance caused by, or connected with, the Affected Party’s:
i. Negligent or intentional acts, errors or omissions;
ii. Failure to comply with an Indian Law; or
iii. Breach of, or default under this Agreement.
SAVINGS/FORCE MAJEURE A Force Majeure occurrence is an event or effect that cannot be reasonably anticipated or controlled and is not due to the negligence or willful misconduct of the affected party. Force Majeure includes, but is not limited to, acts of God, acts of war, acts of public enemies, terrorism, strikes, fires, explosions, actions of the elements, floods, or other similar causes beyond the control of the Contractor or the Commissioner in the performance of the Contract where non- performance, by exercise of reasonable diligence, cannot be prevented. The affected party shall provide the other party with written notice of any Force Majeure occurrence as soon as the delay is known and provide the other party with a written contingency plan to address the Force Majeure occurrence, including, but not limited to, specificity on quantities of materials, tooling, people, and other resources that will need to be redirected to another facility and the process of redirecting them. Furthermore, the affected party shall use its commercially reasonable efforts to resume proper performance within an appropriate period of time. Notwithstanding the foregoing, if the Force Majeure condition continues beyond thirty (30) days, the Parties shall jointly decide on an appropriate course of action that will permit fulfillment of the Parties’ objectives hereunder. The Contractor agrees that in the event of a delay or failure of performance by the Contractor, under the Contract due to a Force Majeure occurrence:
a. The Commissioner may purchase from other sources (without recourse to and by the Contractor for the costs and expenses thereof) to replace all or part of the Products which are the subject of the delay, which purchases may be deducted from the Contract quantities without penalty or liability to the State, or
b. The Contractor will make commercially reasonable efforts to provide Authorized Users with access to Products first in order to fulfill orders placed before the Force Majeure event occurred. The Commissioner agrees that Authorized Users shall accept allocated performance or deliveries during the occurrence of the Force Majeure event. Neither the Contractor nor the Commissioner shall be liable to the other for any delay in or failure of performance under the Contract due to a Force Majeure occurrence. Any such delay in or failure of performance shall not constitute default or give rise to any liability for damages. The existence of such causes of such delay or failure shall extend the period for performance to such extent as determined by the Contractor and the Commissioner to be necessary to enable complete performance by the Contractor if reasonable diligence is exercised after the cause of delay or failure has been removed. Notwithstanding the above, at the discretion of the Commissioner where the delay or failure will significantly impair the value of the Contract to the State or to Authorized Users, the Commissioner may terminate the Contract or the portion thereof which is subject to delays, and thereby discharge any unexecuted portion of the Contract or the relative part thereof. In addition, the Commissioner reserves the right, in his/her sole discretion, to make an equitable adjustment in the Contract terms and/or pricing should extreme and unforeseen volatility in the marketplace affect pricing or the availability of supply. "Extreme and unforeseen volatility in the marketplace" is defined as market circumstances which meet the following criteria: (i) the volatility is due to causes outside the control of Contractor; (ii) the volatility affects the marketplace or industry, not just the particular Contract source of supply; (iii) the effect on pricing or availability of supply is substantial; and (iv) the volatility so affects Contractor's performance that continued performance of the Contract would result in a substantial loss. Failure of the Contractor to agree to any adjustment shall be a dispute under the Disputes clause; provided however, that nothing in this clause shall excuse the Contractor from performing in accordance with the Contract as changed.
Notice of Third Party Claims Pursuant to Public Contract Code Section 9201, District shall provide Contractor timely notification of the receipt of any third-party claim relating to this Contract. District shall be entitled to recover its reasonable costs incurred in providing such notification.
Force Majeure Event After giving effect to any applicable provision, disruption fallback or remedy specified in, or pursuant to, the relevant Confirmation or elsewhere in this Agreement, by reason of force majeure or act of state occurring after a Transaction is entered into, on any day:—
(1) the Office through which such party (which will be the Affected Party) makes and receives payments or deliveries with respect to such Transaction is prevented from performing any absolute or contingent obligation to make a payment or delivery in respect of such Transaction, from receiving a payment or delivery in respect of such Transaction or from complying with any other material provision of this Agreement relating to such Transaction (or would be so prevented if such payment, delivery or compliance were required on that day), or it becomes impossible or impracticable for such Office so to perform, receive or comply (or it would be impossible or impracticable for such Office so to perform, receive or comply if such payment, delivery or compliance were required on that day); or
(2) such party or any Credit Support Provider of such party (which will be the Affected Party) is prevented from performing any absolute or contingent obligation to make a payment or delivery which such party or Credit Support Provider has under any Credit Support Document relating to such Transaction, from receiving a payment or delivery under such Credit Support Document or from complying with any other material provision of such Credit Support Document (or would be so prevented if such payment, delivery or compliance were required on that day), or it becomes impossible or impracticable for such party or Credit Support Provider so to perform, receive or comply (or it would be impossible or impracticable for such party or Credit Support Provider so to perform, receive or comply if such payment, delivery or compliance were required on that day), so long as the force majeure or act of state is beyond the control of such Office, such party or such Credit Support Provider, as appropriate, and such Office, party or Credit Support Provider could not, after using all reasonable efforts (which will not require such party or Credit Support Provider to incur a loss, other than immaterial, incidental expenses), overcome such prevention, impossibility or impracticability;
Reporting of Non-Force Majeure Events Each Party (the “Notifying Party”) shall notify the other Parties when the Notifying Party becomes aware of its inability to comply with the provisions of this Agreement for a reason other than a Force Majeure event. The Parties agree to cooperate with each other and provide necessary information regarding such inability to comply, including the date, duration, reason for the inability to comply, and corrective actions taken or planned to be taken with respect to such inability to comply. Notwithstanding the foregoing, notification, cooperation or information provided under this Article shall not entitle the Party receiving such notification to allege a cause for anticipatory breach of this Agreement.
Available Relief for a Force Majeure Event 11.7.1 Subject to this Article 11:
(a) no Party shall be in breach of its obligations pursuant to this Agreement except to the extent that the performance of its obligations was prevented, hindered or delayed due to a Force Majeure Event;
(b) every Party shall be entitled to claim relief in relation to a Force Majeure Event in regard to its obligations, including but not limited to those specified under Article 4.5;
(c) For avoidance of doubt, neither Party’s obligation to make payments of money due and payable prior to occurrence of Force Majeure events under this Agreement shall be suspended or excused due to the occurrence of a Force Majeure Event in respect of such Party.
(d) Provided that no payments shall be made by either Party affected by a Force Majeure Event for the period of such event on account of its inability to perform its obligations due to such Force Majeure Event.
