Obligations of the Authority (i) The Authority shall, at its own cost and expense, undertake, comply with and perform all its obligations set out in this Agreement or arising hereunder.
(ii) The Authority shall be responsible for the correctness of the Scope of the Project, Project Facilities, Specifications and Standards and the criteria for testing of the completed Works.
(iii) The Authority shall, upon submission of the Performance Security as per the RFP by the Contractor, shall provide to the Contractor:
(a) No less than 90% (ninety per cent) of the required Right of Way of the Construction Zone of total length of the Project Highway within a period of 30 (thirty) days from the date of this Agreement, which shall be in contiguous stretches of length not less than 1( One) kilometre.
(b) approval of the general arrangement drawings (the “GAD”) from railway authorities to enable the Contractor to construct road over- bridges/ under- bridges at level crossings on the Project Highway in accordance with the Specifications and Standards, and subject to the terms and conditions specified in such approval, within a period of 60 (sixty) days from the Appointed Date, and reimbursement of all the costs and expenses paid by the Contractor to the railway authorities for and in respect of the road over- bridges/ under bridges; and7
(c) all environmental clearances as required under Clause 4.3.8
(iv) Delay in providing the Right of Way or approval of GAD by railway authorities, as the case may be, in accordance with the provisions of Clause 3.1 (iii) shall entitle the Contractor to Damages in a sum calculated in accordance with the provisions of Clause 8.3 of this Agreement and Time Extension in accordance with the provisions of Clause 10.5 of this Agreement. For the avoidance of doubt, the Parties agree that the Damages for delay in approval of GAD by the railway authorities for a particular road over-bridge/ under-bridge shall be deemed to be equal to the Damages payable under the provisions of Clause 8.3 for delay in providing Right of Way for a length of 2 (two) kilometre for each such road over-bridge/ under-bridge.
The Authority As to the Authority, the following section shall survive discharge: Section 2.3 (right to conduct audit).
REPRESENTATIONS OF THE ASSIGNOR; LIMITATIONS ON THE ASSIGNOR'S LIABILITY The Assignor represents and warrants that (i) it is the legal and beneficial owner of the interest being assigned by it hereunder, (ii) such interest is free and clear of any adverse claim created by the Assignor and (iii) the execution and delivery of this Assignment Agreement by the Assignor is duly authorized. It is understood and agreed that the assignment and assumption hereunder are made without recourse to the Assignor and that the Assignor makes no other representation or warranty of any kind to the Assignee. Neither the Assignor nor any of its officers, directors, employees, agents or attorneys shall be responsible for (i) the due execution, legality, validity, enforceability, genuineness, sufficiency or collectability of any Loan Document, including without limitation, documents granting the Assignor and the other Lenders a security interest in assets of the Borrower or any guarantor, (ii) any representation, warranty or statement made in or in connection with any of the Loan Documents, (iii) the financial condition or creditworthiness of the Borrower or any guarantor, (iv) the performance of or compliance with any of the terms or provisions of any of the Loan Documents, (v) inspecting any of the property, books or records of the Borrower, (vi) the validity, enforceability, perfection, priority, condition, value or sufficiency of any collateral securing or purporting to secure the Loans or (vii) any mistake, error of judgment, or action taken or omitted to be taken in connection with the Loans or the Loan Documents.
Certain Rights of the Agents If any of the Agents shall request instructions from the Required Lenders with respect to any act or action (including failure to act) in connection with this Agreement, any other Credit Document or the Hermes Cover, the Agents shall be entitled to refrain from such act or taking such action unless and until the Agents shall have received instructions from the Required Lenders; and the Agents shall not incur liability to any Person by reason of so refraining. Without limiting the foregoing, no Lender shall have any right of action whatsoever against the Agents as a result of any of the Agents acting or refraining from acting hereunder or under any other Credit Document in accordance with the instructions of the Required Lenders.
Certain Rights of the Agent The Agent shall have the right to take any action with respect to the Collateral, on behalf of all of the Secured Parties. To the extent practical, the Agent shall request instructions from the Secured Parties with respect to any material act or action (including failure to act) in connection with the Agreement or any other Transaction Document, and shall be entitled to act or refrain from acting in accordance with the instructions of a Majority in Interest; if such instructions are not provided despite the Agent’s request therefor, the Agent shall be entitled to refrain from such act or taking such action, and if such action is taken, shall be entitled to appropriate indemnification from the Secured Parties in respect of actions to be taken by the Agent; and the Agent shall not incur liability to any person or entity by reason of so refraining. Without limiting the foregoing, (a) no Secured Party shall have any right of action whatsoever against the Agent as a result of the Agent acting or refraining from acting hereunder in accordance with the terms of the Agreement or any other Transaction Document, and the Debtors shall have no right to question or challenge the authority of, or the instructions given to, the Agent pursuant to the foregoing and (b) the Agent shall not be required to take any action which the Agent believes (i) could reasonably be expected to expose it to personal liability or (ii) is contrary to this Agreement, the Transaction Documents or applicable law.
Obligations of the Academy Trust The Academy Trust must keep the Land clean and tidy and make good any damage or deterioration to the Land. The Academy Trust must not do anything to lessen the value or marketability of the Land without the Secretary of State’s consent.
Limitations on Actions Any action brought under this Contract, except an action for breach of warranty, shall be brought within the shorter of the statutory limitations period and the period of three years from the date of final payment without any tolling of this statutory limitations period for any reason whatsoever.
Limitations on Liability The Owner Trustee will not be liable under the Transaction Documents, including for the following actions, except (a) for its own willful misconduct, bad faith or negligence (except for errors in judgment) or (b) if a representation or warranty in Section 6.6 is not true and correct as of the Closing Date:
(i) the Owner Trustee will not be liable for any action taken or not taken by it (A) according to the instructions of the Noteholders of a majority of the Note Balance of the Controlling Class, the Indenture Trustee, the Depositor, the holder of the Residual Interest, the Administrator or the Servicer or (B) in good faith which it believes to be authorized or within its rights and powers under this Agreement so long as the action taken or not taken does not amount to negligence;
(ii) the Owner Trustee will not be liable for indebtedness evidenced by or created under the Transaction Documents, including the principal of and interest on the Notes or amounts distributable to the holder of the Residual Interest;
(iii) the Owner Trustee will not be liable for (A) the validity or sufficiency of this Agreement, (B) the due execution of this Agreement by the Depositor, (C) the form, genuineness, sufficiency, value or validity of the Trust Property, (D) the validity or sufficiency of the other Transaction Documents, the Notes or related documents, (E) the legality, validity and enforceability of a Receivable, (F) the perfection and priority of a security interest created by a Receivable in a Financed Vehicle or the maintenance of any perfection and priority, (G) the sufficiency of the Trust Property or the ability of the Trust Property to generate the amounts necessary to make payments to the Noteholders under the Indenture or distributions to the holder of the Residual Interest under this Agreement or (H) the accuracy of a representation or warranty made under a Transaction Document (other than the representations and warranties made by the Owner Trustee in Section 6.6);
(iv) the Owner Trustee will not be liable for the default or misconduct of the Servicer, the Administrator, the Depositor, the holder of the Residual Interest or the Indenture Trustee under the Transaction Documents or for any action taken by the Indenture Trustee, the Administrator or the Servicer in the name of the Owner Trustee;
(v) the Owner Trustee will not be responsible or liable for special, punitive, indirect or consequential damages (including lost profit), even if the Owner Trustee has been advised of the likelihood of the loss or damage and regardless of the form of action; or
(vi) the Owner Trustee will not be responsible or liable for a failure or delay in the performance of its obligations under this Agreement from or caused by, directly or indirectly, forces beyond its control, including strikes, work stoppages, acts of war, terrorism, civil or military disturbances, nuclear catastrophes, fires, floods, earthquakes, storms, hurricanes or other natural catastrophes and interruptions, loss or failures of mechanical, electronic or communication systems, pandemics or epidemics; the Owner Trustee will use reasonable efforts consistent with accepted practices in the banking industry to resume performance as soon as practicable under the circumstances.
Action upon Instructions; Certain Rights and Limitations Subject to the terms of Sections 5.02(a), 5.06, 6.01 and 6.03 hereof, upon the written instructions at any time and from time to time of a Majority in Interest of Note Holders, the Mortgagee shall, subject to the terms of this Section 6.02, take such of the following actions as may be specified in such instructions: (i) give such notice or direction or exercise such right, remedy or power hereunder as shall be specified in such instructions and (ii) give such notice or direction or exercise such right, remedy or power hereunder with respect to any part of the Collateral as shall be specified in such instructions; it being understood that without the written instructions of a Majority in Interest of Note Holders, the Mortgagee shall not, except as provided in Section 6.01, approve any such matter as satisfactory to the Mortgagee. The Mortgagee will execute and the Owner will file such continuation statements with respect to financing statements relating to the security interest created hereunder in the Collateral as may be specified from time to time in written instructions of a Majority in Interest of Note Holders (which instructions shall be accompanied by the form of such continuation statement so to be filed). The Mortgagee will furnish to each Note Holder, promptly upon receipt thereof, duplicates or copies of all reports, notices, requests, demands, certificates and other instruments furnished to the Mortgagee hereunder.
CONDITIONS PRECEDENT TO OBLIGATIONS OF THE ACQUIRED FUND The obligations of the Acquired Fund to consummate the transactions provided for herein shall be subject, at its election, to the performance by the Acquiring Fund of all the obligations to be performed by it hereunder on or before the Closing Date and, in addition thereto, the following conditions:
6.1 All representations and warranties of the Successor Company on behalf of the Acquiring Fund contained in this Agreement shall be true and correct in all material respects as of the date hereof and, except as they may be affected by the transactions contemplated by this Agreement, as of the Closing Date with the same force and effect as if made on and as of the Closing Date.
6.2 The Successor Company shall have delivered to the Predecessor Company on the Closing Date a certificate executed in its name by the Successor Company’s President or Vice President and its Treasurer or Assistant Treasurer, in form and substance reasonably satisfactory to the Predecessor Company, to the effect that the representations and warranties of the Successor Company made in this Agreement on behalf of the Acquiring Fund are true and correct at and as of the Closing Date, except as they may be affected by the transactions contemplated by this Agreement, and as to such other matters as the Predecessor Company reasonably requests.
6.3 The Successor Company (on behalf of and with respect to the Acquiring Fund) shall have entered into or adopted an investment management agreement with the investment advisers as set forth in Appendix B, an Administrative Services Agreement with Deutsche Investment Management Americas Inc. (“DIMA”), a distribution agreement with DWS Distributors Inc., plans of distribution pursuant to Rule 12b-1 under the 1940 Act, shareholder services plans, a transfer agency agreement with DWS Investments Service Company, and other agreements necessary for the Acquiring Fund’s operation as a series of an open-end investment company. The investment management agreement and each such agreement and plan shall have been approved by the Successor Board, including, to the extent required by law, those trustees who are not “interested persons” (as defined in the 0000 Xxx) of the Successor Company or DIMA and who do not have a material interest in such agreement or plan or any related agreement.
