Recognition of Previous Experience (a) The Employer will recognize recent related RN experience on the basis of one (1) annual increment for each one (1) year of service up to the maximum of the grid. Part-time service shall be recognized on the basis of fifteen hundred (1500) hours paid in previous employment equals one (1) year of service. It shall be the responsibility of a newly hired employee to make a claim of recent and related experience within the probationary period in order to be considered for a salary increment. If she/he fails to make a claim in the specified time period or fails to provide reasonable proof of recent related experience, she/he shall not be entitled to recognition.
Terms of Appointment/Duties of Price Associates Subject to the terms and conditions set forth in this Agreement, the Fund hereby employs and appoints Price Associates to provide, and Price Associates agrees to provide, the Accounting Services set forth in this Section A. It is agreed by the parties that Price Associates may subcontract or jointly contract with other parties, on behalf of the Funds, to perform certain of the functions and services described herein. 1. Maintain for each Fund a daily trial balance, a general ledger, subsidiary records and capital stock accounts; 2. Maintain for each Fund an investment ledger, including amortized bond and/or money market costs, foreign dollar denominated costs, and securities on loan where applicable; 3. Maintain for each Fund all records relating to the Fund’s income and expenses, gains and losses; 4. Provide for the daily valuation of each Fund’s portfolio securities and the computation of each Fund’s daily net asset value per share (“NAV”). Such daily valuations shall be made in accordance with the valuation policies established by each of the Fund's Board including, but not limited to, the utilization of such pricing valuation sources and/or pricing services as determined by the Boards. Price Associates shall have no liability for any losses or damages incurred by the Fund as a result of erroneous portfolio security evaluations provided by such designated sources and/or pricing services; provided that, Price Associates reasonably believes the prices are accurate, has adhered to its normal verification control procedures, and has otherwise met the standard of care as set forth in Article G of this Agreement; 5. Provide daily cash flow and transaction status information to each Fund’s adviser; 6. Authorize the payment of Fund expenses, either through instruction of custodial bank or utilization of custodian’s automated transfer system, manage the Fund’s inter-fund lending program and provide support for the Fund’s security lending program; 7. Prepare for each Fund such financial information that is reasonably necessary for shareholder reports, reports to the Board and to the officers of the Fund, reports to the Securities and Exchange Commission (“SEC”), the Internal Revenue Service (“IRS”) and other Federal and state regulatory agencies as well as class action and other claims filings arising out of legal proceedings; 8. Provide each Fund with such advice that may be reasonably necessary to properly account for all financial transactions and to maintain the Fund's accounting procedures and records so as to insure compliance with generally accepted accounting principles and tax practices and rules; 9. Maintain for each Fund all records that may be reasonably required in connection with the audit performed by each Fund's independent accountant, the SEC, the IRS or such other Federal or state regulatory agencies; 10. Cooperate with each Fund’s independent public accountants and take all reasonable action in the performance of its obligations under the Agreement to assure that the necessary information is made available to such accountants for the expression of their opinion without any qualification as to the scope of their examination including, but not limited to, their opinion included in each such Fund’s annual report on Form N-CSR and annual amendment to Form N-1A; 11. Maintain adequate internal controls over financial reporting to provide complete and accurate financial information and disclosures that are certified by officers of the Funds. Provide sub-certifications, as requested by the officers of the Funds, for the adequacy of such controls and the completeness and accuracy of information included in Form N-CSR, Form N-Q, or any other form that may require certification; 12. Implement and maintain the systems, data storage and reporting necessary to perform the above services; and 13. Such other services as mutually agreed upon by the parties.
Payment of Costs and Legal Fees and Reinstatement of Benefits In the event any dispute or controversy arising under or in connection with the Executive’s termination is resolved in favor of the Executive, whether by judgment, arbitration or settlement, the Executive shall be entitled to the payment of (a) all legal fees incurred by the Executive in resolving such dispute or controversy, and (b) any back-pay, including Base Salary, bonuses and any other cash compensation, fringe benefits and any compensation and benefits due to the Executive under this Agreement.
Assistance by COUNTY STAFF 1.3.1. County shall assign an appropriate staff member to work with A-E in connection with the work of this Contract. Said staff member's duties will consist of the giving of advice and consultations, assisting A-E in negotiations with other public agencies and private parties, miscellaneous items which in the judgment of A-E or County's staff warrant attention, and all other duties as may be described in Attachment A. 1.3.2. All of the above activities, however, shall be the primary responsibility of A-E to schedule, initiate and carry through to completion.
Allocation of Premiums Premiums due and payable under the Bond (as defined in the Agreement) shall be paid 90% by AXA Enterprise Multimanager Funds Trust and the Trust and 10% by the Manager or its affiliates. Except as modified and amended hereby, the Agreement is hereby ratified and confirmed in full force and effect in accordance with its terms.
Review by the Association of Procurement Decisions The Procurement Plan shall set forth those contracts which shall be subject to the Association’s Prior Review. All other contracts shall be subject to Post Review by the Association.
SUPERVISION AND CONSTRUCTION PROCEDURES 4.3.1 The Contractor shall supervise and direct the Work, using his / her best skill and attention. The Contractor shall be solely responsible for all construction means, methods, techniques, sequences and procedures and for coordinating all portions of the Work under the Contract. All aspects of the Project shall be subject to the inspection and approval of the State. Contractor guarantees to repair, replace, re-execute or otherwise correct any defect in workmanship, materials, or the like that fails to conform to the requirements of this Contract or that appears during the progress of the Work or within one year of final acceptance by the State. 4.3.2 The Contractor shall be responsible to the State for the acts and omissions of his / her employees, Subcontractors and their agents and employees, and other persons performing any of the Work under a contract with the Contractor. 4.3.3 The Contractor shall not be relieved from his / her obligations to perform the Work in accordance with the Contract Documents either by the activities or duties of the Architect in his / her administration of the Contract, or by inspections, tests or approvals required or performed under Paragraph 7.7 by persons other than the Contractor. 4.3.4 The Contractor shall acquaint himself (herself / itself) with the limits of the property or right- of-way of the State and shall not trespass on other property. The Contractor shall adequately protect the project, adjacent property and the public, and shall be responsible for any damage or injury due to the Contractor’s act or neglect, and shall save the State harmless in respect thereto. 4.3.5 All work shall be done in such a manner as not to interfere with the State’s operating functions. Contractor and his employees shall familiarize themselves and comply with all rules and regulations applicable to the project. 4.3.6 The Contractor shall keep the premises free from liens arising out of or from the Project. Contractor shall obtain and submit waivers of liens with a request for a progress or final payment.
Payment of Premiums Each Borrower shall punctually pay all premiums or other sums payable in respect of the obligatory insurances effected by it and produce all relevant receipts when so required by the Security Trustee.
Assistance and Cooperation (a) Each of the Companies shall provide (and shall cause its Affiliates to provide) the other Companies and their respective agents, including accounting firms and legal counsel, with such cooperation or information as they may reasonably request in connection with (i) preparing and filing Tax Returns, (ii) determining the liability for and amount of any Taxes due (including estimated Taxes) or the right to and amount of any refund of Taxes, (iii) examinations of Tax Returns, and (iv) any administrative or judicial proceeding in respect of Taxes assessed or proposed to be assessed. Such cooperation shall include making available, upon reasonable notice, all information and documents in their possession relating to the other Companies and their respective Affiliates as provided in Section 9. Each of the Companies shall also make available to the other Companies, as reasonably requested and available, personnel (including employees and agents of the Companies or their respective Affiliates) responsible for preparing, maintaining, and interpreting information and documents relevant to Taxes. (b) Any information or documents provided under this Section 8 or Section 9 shall be kept confidential by the Company or Companies receiving the information or documents, except as may otherwise be necessary in connection with the filing of Tax Returns or in connection with any administrative or judicial proceedings relating to Taxes. Notwithstanding any other provision of this Agreement or any other agreement, in no event shall any of the Companies or any of their respective Affiliates be required to provide the other Companies or any of their respective Affiliates or any other Person access to or copies of any information if such action could reasonably be expected to result in the waiver of any Privilege. In addition, in the event that any of the Companies determine that the provision of any information to the other Companies or their respective Affiliates could be commercially detrimental, violate any law or agreement or waive any Privilege, the Parties shall use reasonable best efforts to permit compliance with their obligations under this Section 8 or Section 9 in a manner that avoids any such harm or consequence.
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.