Adequacy of the Proposed Sample Clauses
Related to Adequacy of the Proposed
Adequacy of Financing The Purchaser has available to it sufficient funds to satisfy its obligations under this Agreement.
Scope of the Project Under this Agreement, the scope of the Project (the “Scope of the Project”) shall mean and include: (a) construction of the Project Highway on the Site set forth in Schedule- A and as specified in Schedule-B together with provision of Project Facilities as specified in Schedule-C, and in conformity with the Specifications and Standards set forth in Schedule-D; (b) maintenance of the Project Highway in accordance with the provisions of this Agreement and in conformity with the requirements set forth in Schedule-E; and (c) performance and fulfilment of all other obligations of the Contractor in accordance with the provisions of this Agreement and matters incidental thereto or necessary for the performance of any or all of the obligations of the Contractor under this Agreement.
Adequacy of Consideration Executive acknowledges and agrees that Executive has received adequate consideration from United HealthCare to enter into this Agreement.
Capital Adequacy If, after the Closing Date, the Lender has determined that the adoption or effectiveness of any applicable law, rule or regulation regarding capital adequacy, or any change therein, or any change in the interpretation or administration thereof by any Governmental Authority, central bank or comparable agency charged with the interpretation or administration thereof, or compliance by the Lender or its holding company with any request or directive regarding capital adequacy (whether or not having the force of law) of any such Governmental Authority, central bank or comparable agency, has or would have the effect of reducing the rate of return on the Lender’s or its holding company’s capital as a consequence of its commitments or obligations hereunder to a level below that which the Lender or its holding company could have achieved but for such adoption, effectiveness, change or compliance (taking into consideration the Lender’s or its holding company’s policies with respect to capital adequacy), then, upon notice from the Lender, the Borrower shall pay to the Lender such additional amount or amounts as will compensate the Lender or its holding company for such reduction. Each determination by the Lender of amounts owing under this Section shall, absent manifest error, be conclusive and binding on the Borrower. Notwithstanding anything contained herein to the contrary, the Borrower shall not be under any obligation to pay to the Lender amounts otherwise owing under this Section 2.5 if the Lender shall not have delivered such written notice to the Borrower within ninety (90) days following the later of (i) the date of occurrence of the event which forms the basis for such notice and request for compensation and (ii) the date the Lender becomes aware of such event. Notwithstanding the foregoing, the Lender agrees that, before giving any notice seeking a payment under this Section 2.5, it will use reasonable efforts (consistent with its internal policy and legal and regulatory restrictions) to designate a different office, branch or Affiliate of the Lender as the office, branch or Affiliate of the Lender having the commitments and obligations of the Lender hereunder if making such designation would avoid or reduce the amount of such reduction in its rate of return on its capital or assets and would not, in the reasonable judgment of the Lender, be otherwise disadvantageous to the Lender.
Maintenance of the Property Neither Broker nor Brokerage Firm is responsible for maintenance of the 324 Property nor are they liable for damage of any kind occurring to the Property, unless such damage is caused by their negligence or 325 intentional misconduct.
Construction of the Project Highway (i) The Contractor shall construct the Project Highway as specified in Schedule- B and Schedule-C, and in conformity with the Specifications and Standards set forth in Schedule-D. The Contractor shall be responsible for the correct positioning of all parts of the Works, and shall rectify any error in the positions, levels, dimensions or alignment of the Works. The [650th (six hundred and fiftieth) day] from the Appointed Date shall be the scheduled completion date (the “Scheduled Completion Date”) and the Contractor agrees and undertakes that the construction shall be completed on or before the Scheduled Completion Date, including any extension thereof. (ii) The Contractor shall construct the Project Highway in accordance with the Project Completion Schedule set forth in Schedule-J. In the event that the Contractor fails to achieve any Project Milestone or the Scheduled Completion Date within a period of 30 (thirty) days from the date set forth in Schedule-J, unless such failure has occurred due to Force Majeure or for reasons solely attributable to the Authority, it shall pay Damages to the Authority of a sum calculated at the rate of 0.05% (zero point zero five percent) of the Contract Price for delay of each day reckoned from the date specified in Schedule –J and until such Project Milestone is achieved or the Project Highway is completed; provided that if the period for any or all Project Milestones or the Scheduled Completion Date is extended in accordance with the provisions of this Agreement, the dates set forth in Schedule-J shall be deemed to be modified accordingly and the provisions of this Agreement shall apply as if Schedule-J has been amended as above; provided further that in the event the Project Highway is completed within or before the Scheduled Completion Date including any Time Extension, applicable for that work or section, the Damages paid under this Clause 10.3 (ii) shall be refunded by the Authority to the Contractor, but without any interest thereon. The Parties agree that for determining achievement or delays in completion of the Project Milestones or the Project on the due date, the works affected due to delay in providing the site for which time extension has been granted beyond the Scheduled Completion Date will be excluded. For example on the due date to achieve the Project Milestone-I (i.e., Stage Payments of 10% (ten percent) of Contract Price on 180th (one hundred and eighty) day from the Appointed Date), if 5% (five percent) of the project length corresponding to the Project Milestone-I is not handed over or lately handed over resulting in the extension of completion of this 5% (five percent) length beyond Scheduled Completion Date, Stage Payment of 10% X 0.95 = 9.5% only is to be achieved by 180th (one hundred and eighty) day. For the avoidance of doubt, it is agreed that recovery of Damages under this Clause 10.3 (ii) shall be without prejudice to the rights of the Authority under this Agreement including the right of Termination thereof. The Parties further agree that Time Extension hereunder shall only be reckoned for and in respect of the affected Works as specified in Clause 10.5 (ii). (iii) The Authority shall notify the Contractor of its decision to impose Damages in pursuance with the provisions of this Clause 10.3. Provided that no deduction on account of Damages shall be effected by the Authority without notifying the Contractor of its decision to impose the Damages, and taking into consideration the representation, if any, made by the Contractor within 20 (twenty) days of such notice. The Parties expressly agree that the total amount of Damages under Clause 10.3 (ii) shall not exceed 10% (ten percent) of the Contract Price. If the damages exceed 10% (ten percent) of the Contract Price, the Contractor shall be deemed to be in default of this agreement having no cure and the Authority shall be entitled to terminate this Agreement by issuing a Termination Notice in accordance with the provisions of Clause 23.1 (ii). (iv) In the event that the Contractor fails to achieve the Project Completion within a period of 90 (ninety) days from the Schedule Completion Date set forth in Schedule-J, unless such failure has occurred due to Force Majeure or for reasons solely attributable to the Authority, the contractor shall be deemed to be ineligible for bidding any future projects of the Authority, both as the sole party or as one of the parties of Joint Venture/ Consortium during the period from Scheduled Completion Date to issuance of Completion Certificate. This restriction is applicable if the contract value of the delayed project is not less than Rs. 300 Crore.
Capital Adequacy Adjustment In the event that any Lender (which term shall include Issuing Bank for purposes of this Section 2.19(b)) shall have reasonably determined that the adoption, effectiveness, phase in or applicability after the Third Restatement Date of any Applicable Law regarding capital or liquidity adequacy, reserve requirements or similar requirements, or any change therein or in the interpretation, application or administration thereof by any Governmental Authority, central bank or comparable agency charged with the interpretation or administration thereof, or compliance by any Lender (or its applicable lending office) with any Applicable Law regarding capital or liquidity adequacy, reserve requirements or similar requirements (whether or not having the force of law) of any such Governmental Authority, has or would have the effect of reducing the rate of return on the capital of such Lender or any corporation controlling such Lender as a consequence of, or with reference to, such Lender’s Loans or Revolving Commitments or Letters of Credit, or participations therein or other obligations hereunder with respect to the Loans or the Letters of Credit to a level below that which such Lender or such controlling corporation could have achieved but for such adoption, effectiveness, phase in, applicability, change or compliance (taking into consideration the policies of such Lender or such controlling corporation with regard to capital adequacy); provided that, notwithstanding anything herein to the contrary, (x) the Xxxx-Xxxxx Xxxx Street Reform and Consumer Protection Act and all requests, rules, guidelines or directives thereunder or issued in connection therewith and (y) all requests, rules, guidelines or directives promulgated by the Bank for International Settlements, the Basel Committee on Banking Supervision (or any successor or similar authority) or the United States regulatory authorities, in each case pursuant to Basel III, shall in each case be deemed a change of law, regardless of the date enacted, adopted or issued, then from time to time, within five Business Days after receipt by Borrower from such Lender of the statement referred to in the next sentence, Borrower shall pay to such Lender such additional amount or amounts as will compensate such Lender or such controlling corporation on an after tax basis for such reduction. Such Lender shall deliver to Borrower (with a copy to Administrative Agent) a written statement, setting forth in reasonable detail the basis for calculating the additional amounts owed to Lender under this Section 2.19(b), which statement shall be conclusive and binding upon all parties hereto absent manifest error.
Construction of the Project The Allottee has seen the proposed layout plan, specifications, amenities and facilities of the Apartment/ Plot and accepted the floor plan, payment plan and the specification, amenities and facilities annexed along with this Agreement which has been approved by the competent authority, as represented by the Promoter. The Promoter shall develop the Project in accordance with the said layout plans, floor plans and specifications, amenities and facilities. Subject to the terms in this Agreement, the Promoter undertakes to strictly abide by such plans approved by the competent authorities and shall also strictly abide by the bye-laws, FAR, and density norms and provisions prescribed by the relevant building bye-laws and shall not have an option to make any variation/ alteration/ modification in such plans, other than in the manner provided under the Act, and breach of this term by the Promoter shall constitute a material breach of this Agreement.
Self Scheduling The Home and the Union may agree to implement a self-scheduling process. Self-scheduling is the mechanism by which employees in a Home create their own work schedules. The purpose of self scheduling is to improve job satisfaction and quality of work life for the participating employees. Self scheduling requires a collaboration of employees and management to ensure proper coverage of the Home and to meet the provisions of the Collective Agreement. It is agreed that self scheduling will be negotiated locally by the Home and the Union and will include a trial period. Each Home must have the majority agreement of the full-time and part-time employees who vote on the issue to agree on a trial period of up to six months. Once the trial period is complete, each Home must have a minimum of 66⅔% agreement of the full-time and part-time employees who vote on the issue to continue with the new schedule on a permanent basis.
Condition of the Property THE LESSEE ACKNOWLEDGES AND AGREES THAT IT IS LEASING THE PROPERTY "AS IS" WITHOUT REPRESENTATION, WARRANTY OR COVENANT (EXPRESS OR IMPLIED) BY THE LESSOR AND SUBJECT TO (A) THE EXISTING STATE OF TITLE, (B) THE RIGHTS OF ANY PARTIES IN POSSESSION THEREOF, (C) ANY STATE OF FACTS WHICH AN ACCURATE SURVEY OR PHYSICAL INSPECTION MIGHT SHOW, AND (D) VIOLATIONS OF REQUIREMENTS OF LAW WHICH MAY EXIST ON THE DATE HEREOF OR ON THE ACQUISITION DATE. THE LESSOR HAS NOT MADE AND SHALL NOT BE DEEMED TO HAVE MADE ANY REPRESENTATION, WARRANTY OR COVENANT (EXPRESS OR IMPLIED) AND SHALL NOT BE DEEMED TO HAVE ANY LIABILITY WHATSOEVER AS TO THE TITLE (OTHER THAN FOR LESSOR LIENS), VALUE, HABITABILITY, USE, CONDITION, DESIGN, OPERATION, OR FITNESS FOR USE OF THE PROPERTY (OR ANY PART THEREOF), OR ANY OTHER REPRESENTATION, WARRANTY OR COVENANT WHATSOEVER, EXPRESS OR IMPLIED, WITH RESPECT TO THE PROPERTY (OR ANY PART THEREOF) AND THE LESSOR SHALL NOT BE LIABLE FOR ANY LATENT, HIDDEN, OR PATENT DEFECT THEREIN (OTHER THAN FOR LESSOR LIENS) OR THE FAILURE OF THE PROPERTY, OR ANY PART THEREOF, TO COMPLY WITH ANY REQUIREMENT OF LAW.
