Termination of Sub-Servicing Agreements For so long as the Trust or any Other Securitization Trust is subject to the reporting requirements of the Exchange Act, each of the Master Servicer, the Special Servicer, the Custodian, the Certificate Administrator and the Trustee, as applicable, shall (i) cause each Sub-Servicing Agreement (with respect to the Master Servicer or the Special Servicer) or sub-servicing agreement (with respect to any other Servicer) to which it is a party to entitle the Depositor to terminate such agreement (without compensation, termination fee or the consent of any other Person) at any time following any failure of the applicable Sub-Servicer or sub-servicer, as applicable, to deliver any Exchange Act reporting items that such Sub-Servicer or sub-servicer, as applicable, is required to deliver under Regulation AB or as otherwise contemplated by this Article X and (ii) promptly notify the Depositor following any failure of the applicable Sub-Servicer or sub-servicer, as applicable, to deliver any Exchange Act reporting items that such Sub-Servicer or sub-servicer, as applicable, is required to deliver under Regulation AB or as otherwise contemplated by this Article X. The Depositor is hereby authorized to exercise the rights described in clause (i) of the preceding sentence in its sole discretion. The rights of the Depositor to terminate a Sub-Servicing Agreement (with respect to the Master Servicer or the Special Servicer) or sub-servicing agreement (with respect to any other Servicer) as aforesaid shall not limit any right Master Servicer, the Special Servicer, the Custodian, the Certificate Administrator or the Trustee, as applicable, may have to terminate such Sub-Servicing Agreement or sub-servicing agreement, as applicable.
Execution of Supplemental Agreements In executing, or accepting the additional agencies created by, any supplemental agreement permitted by this Article or the modifications thereby of the agencies created by this Agreement, the Agent shall be entitled to receive and (subject to Section 7.1) shall be fully protected in relying upon, an Opinion of Counsel stating that the execution of such supplemental agreement is authorized or permitted by this Agreement. The Agent may, but shall not be obligated to, enter into any such supplemental agreement which affects the Agent's own rights, duties or immunities under this Agreement or otherwise.
Selection of Subcontractors, Procurement of Materials and Leasing of Equipment The contractor shall not discriminate on the grounds of race, color, religion, sex, national origin, age or disability in the selection and retention of subcontractors, including procurement of materials and leases of equipment. The contractor shall take all necessary and reasonable steps to ensure nondiscrimination in the administration of this contract. a. The contractor shall notify all potential subcontractors and suppliers and lessors of their EEO obligations under this contract. b. The contractor will use good faith efforts to ensure subcontractor compliance with their EEO obligations.
Maintenance Agreement The parties will abide by the terms of the Maintenance Agreement including the capacity to dispute the classification in accordance with the Maintenance Agreement (Information Appendix C).
Master Services Agreement This Agreement is a master agreement governing the relationship between the Parties solely with regard to State Street’s provision of Services to each BTC Recipient under the applicable Service Modules.
Servicing Agreement General Summary The Sellers and the Purchasers intend this Agreement to amend and restate that certain “Servicing Agreement,” dated March 23, 2021, for purposes of the Purchase Agreement and wish to set forth herein the terms upon which each Purchaser will, to the fullest extent permitted by applicable Law and the applicable Corporate Trust Contract, and subject to the applicable provisions of this Agreement, assume the responsibility (as agent of the applicable Seller) to supervise, manage, administer and otherwise discharge the duties of the applicable Seller in a Corporate Trust Capacity under (a) any Restricted Appointment and (b) any Excluded Appointment (collectively, the “Serviced Appointments”), and the Purchasers will discharge and perform when due, and indemnify the Sellers for, the Assumed Servicing Liabilities.
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
Assumption or Termination of Sub-Servicing Agreements by Trustee In the event the Master Servicer shall for any reason no longer be the master servicer (including termination due to a Master Servicer Event of Default), the Trustee or its designee shall thereupon assume (or cause its designee or the successor master servicer for the Trustee appointed pursuant to Section 7.02 to assume) all of the rights and obligations of the Master Servicer under each Sub-Servicing Agreement that the Master Servicer may have entered into, unless the Trustee elects to terminate any Sub-Servicing Agreement in accordance with its terms as provided in Section 6.07. Upon such assumption, the Trustee, its designee or the successor servicer for the Trustee appointed pursuant to Section 7.02 shall be deemed, subject to Section 6.07, to have assumed all of the Master Servicer's interest therein and to have replaced the Master Servicer as a party to each Sub-Servicing Agreement to the same extent as if each Sub-Servicing Agreement had been assigned to the assuming party, except that (i) the Master Servicer shall not thereby be relieved of any liability or obligations under any Sub-Servicing Agreement and (ii) none of the Trustee, its designee or any successor Master Servicer shall be deemed to have assumed any liability or obligation of the Master Servicer that arose before it ceased to be the Master Servicer. The Master Servicer at its expense shall, upon request of the Trustee, deliver to the assuming party all documents and records relating to each Sub-Servicing Agreement and the Mortgage Loans then being serviced and an accounting of amounts collected and held by or on behalf of it, and otherwise use its best efforts to effect the orderly and efficient transfer of the Sub- Servicing Agreements to the assuming party.
Amendments to Servicing Agreements, Modification of Standard Provisions (a) Subject to the prior written consent of the Trustee pursuant to Section 3.07(b), the Master Servicer from time to time may, to the extent permitted by the applicable Servicing Agreement, make such modifications and amendments to such Servicing Agreement as the Master Servicer deems necessary or appropriate to confirm or carry out more fully the intent and purpose of such Servicing Agreement and the duties, responsibilities and obligations to be performed by the Servicer thereunder. Such modifications may only be made if they are consistent with the REMIC Provisions, as evidenced by an Opinion of Counsel. Prior to the issuance of any modification or amendment, the Master Servicer shall deliver to the Trustee such Opinion of Counsel and an Officer's Certificate setting forth (i) the provision that is to be modified or amended, (ii) the modification or amendment that the Master Servicer desires to issue and (iii) the reason or reasons for such proposed amendment or modification. (b) The Trustee shall consent to any amendment or supplement to a Servicing Agreement proposed by the Master Servicer pursuant to Section 3.07(a), which consent and amendment shall not require the consent of any Certificateholder if it is (i) for the purpose of curing any mistake or ambiguity or to further effect or protect the rights of the Certificateholders or (ii) for any other purpose, provided such amendment or supplement for such other purpose cannot reasonably be expected to adversely affect Certificateholders. The lack of reasonable expectation of an adverse effect on Certificateholders may be established through the delivery to the Trustee of (i) an Opinion of Counsel to such effect or (ii) written notification from each Rating Agency to the effect that such amendment or supplement will not result in reduction of the current rating assigned by that Rating Agency to the Certificates. Notwithstanding the two immediately preceding sentences, the Trustee may, in its discretion, decline to enter into or consent to any such supplement or amendment if its own rights, duties or immunities shall be adversely affected. (i) Notwithstanding anything to the contrary in this Section 3.07, the Master Servicer from time to time may, without the consent of any Certificateholder or the Trustee, enter into an amendment (A) to an Other Servicing Agreement for the purpose of (i) eliminating or reducing Month End Interest and (ii) providing for the remittance of Full Unscheduled Principal Receipts by the applicable Servicer to the Master Servicer not later than the 24th day of each month (or if such day is not a Business Day, on the previous Business Day) or (B) to the WFHM Servicing Agreement for the purpose of changing the applicable Remittance Date to the 18th day of each month (or if such day is not a Business Day, on the previous Business Day). (ii) The Master Servicer may direct WFHM to enter into an amendment to the WFHM Servicing Agreement for the purposes described in Sections 3.07(c)(i)(B) and 10.01(b)(iii).
Assumption or Termination of Subservicing Agreements by Trustee (a) If the Master Servicer shall for any reason no longer be the master servicer (including by reason of an Event of Default), the Trustee, its designee or its successor shall thereupon assume all of the rights and obligations of the Master Servicer under each Subservicing Agreement that may have been entered into. The Trustee, its designee or the successor servicer for the Trustee shall be deemed to have assumed all of the Master Servicer's interest therein and to have replaced the Master Servicer as a party to the Subservicing Agreement to the same extent as if the Subservicing Agreement had been assigned to the assuming party except that the Master Servicer shall not thereby be relieved of any liability or obligations under the Subservicing Agreement. (b) The Master Servicer shall, upon request of the Trustee but at the expense of the Master Servicer, deliver to the assuming party all documents and records relating to each Subservicing Agreement and the Mortgage Loans then being serviced and an accounting of amounts collected and held by it and otherwise use its best efforts to effect the orderly and efficient transfer of each Subservicing Agreement to the assuming party.
