Administrative Delay Sample Clauses

Administrative Delay. (“the first few weeks”) rule. 415 Compensation for a limitation year shall not include, unless otherwise elected in Section 2.2 of this Amendment, amounts earned but not paid during the limitation year solely because of the timing of pay periods and pay dates. However, if elected in Section 2.2 of this Amendment, 415 Compensation for a limitation year shall include amounts earned but not paid during the limitation year solely because of the timing of pay periods and pay dates, provided the amounts are paid during the first few weeks of the next limitation year, the amounts are included on a uniform and consistent basis with respect to all similarly situated participants, and no compensation is included in more than one limitation year.
Sample 1
AutoNDA by SimpleDocs
Administrative Delay. Option exercise requests will be processed as soon as administratively practicable following the receipt of the Participant’s request which is complete in all respects. The Company shall not be liable for any delay in exercising the option as a result of administrative delay or error.
Sample 1
Administrative Delay. Section 415 Compensation for a limitation year shall include amounts earned but not paid during the limitation year solely because of the timing of pay periods and pay dates, provided the amounts are paid during the first few weeks of the next limitation year, the amounts are included on a uniform and consistent basis with respect to all similarly situated Participants, and no compensation is included in more than one limitation year.
Sample 1
Administrative Delay. Meaning failure by governmental entities to act within reasonable times under applicable laws or actions by governmental entities that are successfully challenged by the Developer or an assignee/transferee/vertical developer.
Sample 1

Related to Administrative Delay

  • Administrative Agents Clawback Section 12.01 Administrative Agent’s Claw back

  • Six-Month Delay Notwithstanding anything to the contrary in this Agreement, no compensation or benefits, including without limitation any severance payments or benefits payable under this Section 4, shall be paid to the Executive during the six-month period following the Executive’s Separation from Service if the Company determines that paying such amounts at the time or times indicated in this Agreement would be a prohibited distribution under Section 409A(a)(2)(B)(i) of the Code. If the payment of any such amounts is delayed as a result of the previous sentence, then on the first day of the seventh month following the date of Separation from Service (or such earlier date upon which such amount can be paid under Section 409A without resulting in a prohibited distribution, including as a result of the Executive’s death), the Company shall pay the Executive a lump-sum amount equal to the cumulative amount that would have otherwise been payable to the Executive during such period.

  • Increased Cost and Reduced Return; Capital Adequacy; Reserves on Eurodollar Rate Loans (a) If any Lender determines that as a result of the introduction of or any change in or in the interpretation of any Law, or such Lender’s compliance therewith, there shall be any increase in the cost to such Lender of agreeing to make or making, funding or maintaining Eurodollar Rate Loans or (as the case may be) issuing or participating in Letters of Credit, or a reduction in the amount received or receivable by such Lender in connection with any of the foregoing (excluding for purposes of this subsection (a) any such increased costs or reduction in amount resulting from (i) Taxes or Other Taxes (as to which Section 3.01 shall govern), (ii) changes in the basis of taxation of overall net income or overall gross income by the United States or any foreign jurisdiction or any political subdivision of either thereof under the Laws of which such Lender is organized or has its Lending Office, and (iii) reserve requirements contemplated by Section 3.04(c)), then from time to time upon demand of such Lender (with a copy of such demand to the Administrative Agent), the Borrower shall pay to such Lender such additional amounts as will compensate such Lender for such increased cost or reduction.

  • Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).

  • Tenant Delay If the Substantial Completion of the Tenant Improvement Work is delayed (a “Tenant Delay”) as a result of (a) any failure of Tenant to approve the Construction Pricing Proposal pursuant to Section 2.6 above on or before Tenant’s Approval Deadline; (b) Tenant’s failure to timely approve any matter requiring Tenant’s approval; (c) any breach by Tenant of this Work Letter or the Lease; (d) any request by Tenant for a revision to the Approved Construction Drawings (except to the extent such delay results from any failure of Landlord to perform its obligations under Section 2.7 above); (e) Tenant’s requirement for materials, components, finishes or improvements that are not available in a commercially reasonable time given the anticipated date of Substantial Completion of the Tenant Improvement Work as set forth in this Agreement; (f) any change to the base, shell or core of the Premises or Building required by the Approved Construction Drawings; or (g) any other act or omission of Tenant or any of its agents, employees or representatives, then, notwithstanding any contrary provision of this Agreement, and regardless of when the Tenant Improvement Work is actually Substantially Completed, the Tenant Improvement Work shall be deemed to be Substantially Completed on the date on which the Tenant Improvement Work would have been Substantially Completed if no such Tenant Delay had occurred.

  • Force Majeure Delays In any case where either party hereto is required to do any act (other than the payment of money), delays caused by or resulting from Acts of God or Nature, war, civil commotion, fire, flood or other casualty, labor difficulties, shortages of labor or materials or equipment, government regulations, delay by government or regulatory agencies with respect to approval or permit process, unusually severe weather, or other causes beyond such party’s reasonable control the time during which act shall be completed, shall be deemed to be extended by the period of such delay, whether such time be designated by a fixed date, a fixed time or “a reasonable time.”

  • Payments Generally Administrative Agents Clawback (a) All payments to be made by the Borrowers shall be made free and clear of and without condition or deduction for any counterclaim, defense, recoupment or setoff. Except as otherwise expressly provided herein and except with respect to principal of and interest on Loans denominated in an Alternative Currency, all payments by the Borrowers hereunder shall be made to the Administrative Agent, for the account of the respective Lenders to which such payment is owed, at the applicable Administrative Agent’s Office in Dollars and in Same Day Funds not later than 2:00 p.m. on the date specified herein. Except as otherwise expressly provided herein, all payments by the Borrowers hereunder with respect to principal and interest on Loans denominated in an Alternative Currency shall be made to the Administrative Agent, for the account of the respective Lenders to which such payment is owed, at the applicable Administrative Agent’s Office in such Alternative Currency and in Same Day Funds not later than the Applicable Time specified by the Administrative Agent on the dates specified herein. Without limiting the generality of the foregoing, the Administrative Agent may require that any payments due under this Agreement be made in the United States. If, for any reason, any Borrower is prohibited by any Law from making any required payment hereunder in an Alternative Currency, such Borrower shall make such payment in Dollars in the Dollar Equivalent of the Alternative Currency payment amount. The Administrative Agent will promptly distribute to each Lender its Applicable Percentage in respect of the applicable Facility (or other applicable share as provided herein) of such payment in like funds as received by wire transfer to such Lender’s Lending Office. All payments received by the Administrative Agent (i) after 2:00 p.m., in the case of payments in Dollars, or (ii) after the Applicable Time specified by the Administrative Agent in the case of payments in an Alternative Currency, shall in each case be deemed received on the next succeeding Business Day and any applicable interest or fee shall continue to accrue. If any payment to be made by any Borrower shall come due on a day other than a Business Day, payment shall be made on the next following Business Day, and such extension of time shall be reflected in computing interest or fees, as the case may be.

  • Payments to Administrative Agent A payment by the Borrower to the Administrative Agent hereunder or any of the other Loan Documents for the account of any Lender shall constitute a payment to such Lender. The Administrative Agent agrees promptly to distribute to each Lender such Lender’s pro rata share of payments received by the Administrative Agent for the account of the Lenders except as otherwise expressly provided herein or in any of the other Loan Documents.

  • Uncontrollable Events BISYS assumes no responsibility hereunder, and shall not be liable for any damage, loss of data, delay or any other loss whatsoever caused by events beyond its reasonable control.

  • Performance by Administrative Agent If the Borrower or any other Loan Party shall fail to perform any covenant, duty or agreement contained in any of the Loan Documents, the Administrative Agent may, after notice to the Borrower, perform or attempt to perform such covenant, duty or agreement on behalf of the Borrower or such other Loan Party after the expiration of any cure or grace periods set forth herein. In such event, the Borrower shall, at the request of the Administrative Agent, promptly pay any amount reasonably expended by the Administrative Agent in such performance or attempted performance to the Administrative Agent, together with interest thereon at the applicable Post-Default Rate from the date of such expenditure until paid. Notwithstanding the foregoing, neither the Administrative Agent nor any Lender shall have any liability or responsibility whatsoever for the performance of any obligation of the Borrower under this Agreement or any other Loan Document.

Time is Money Join Law Insider Premium to draft better contracts faster.