After delivery of the possession of all the Unit/Flat Unit Sample Clauses

After delivery of the possession of all the Unit/Flat Unit. Flats in the Buildings, the Owners-Vendors and the Developer-Vendor herein shall take steps for formation of the Association. Any association, syndicate, committee, body or society formed by the Unit/Flat/Car Parking Owners and occupiers without the participation of the Owners/ Vendors and the Developer-Vendor herein shall not be entitled to be recognized by the Owners-Vendors and the Developer-Vendor herein and shall not have any right to represent the Unit/Flat/Car Parking owner/s and occupier/s to raise any issue relating to the Building/s or the premises. The maintenance of the Building/s shall be made over or handed over to the Association by the Developer or its nominated/appointed Maintenance Agency and upon such making over the Association shall be responsible for the maintenance of the Building/s and the premises.
Sample 1Sample 2
AutoNDA by SimpleDocs

Related to After delivery of the possession of all the Unit/Flat Unit

  • Collateral in the Possession of a Bailee If any Inventory or other Goods are at any time in the possession of a bailee, such Assignor shall promptly notify the Collateral Agent thereof and, if requested by the Collateral Agent, shall use its commercially reasonable efforts to promptly obtain an acknowledgment from such bailee, in form and substance reasonably satisfactory to the Collateral Agent, that the bailee holds such Collateral for the benefit of the Collateral Agent and shall act upon the instructions of the Collateral Agent, without the further consent of such Assignor. The Collateral Agent agrees with such Assignor that the Collateral Agent shall not give any such instructions unless an Event of Default has occurred and is continuing or would occur after taking into account any action by the respective Assignor with respect to any such bailee.

  • POSSESSION OF THE APARTMENT PLOT 8.1 Schedule for possession of the said Apartment: The Promoter agrees and understands that timely delivery of possession of the Apartment to the Allottee and the Common Areas to the Association of the Allottees , is the essence of the Agreement. Provided that the Promoter shall be entitled to reasonable extension of time as agreed by and between the Allottee and the Promoter for giving possession of the Apartment on the aforesaid date and the same shall not include the period of extension given by the Authority for registration. The Promoter, based on the approved plans and specifications, assures to hand over possession of the Apartment on …………,with a grace period of twelve months (Completion date) in case the Promoter fails to complete the Project. unless there is a delay or failure due to war, flood, drought, fire, cyclone, earthquake or any other calamity or order, rule, notification of the Government and/or other public or competent authority/court and/or caused by nature affecting the regular development of the real estate project (“Force Majeure”). If, however, the completion of the Project is delayed due to the Force Majeure conditions then the Allottee agrees that the Promoter shall be entitled to the extension of time for delivery of possession of the Apartment, Provided that such Force Majeure conditions are not of a nature which make it impossible for the contract to be implemented. Promoter will be entitled to give block-wise and phase-wise possession upon obtaining the Completion Certificate/ Partial Completion Certificate of a building block or a particular phase as the case may be irrespective of the fact that construction of other Blocks and/or other phases and/or provision of facilities may be incomplete. The Allottee agrees and confirms that, in the event it becomes impossible for the Promoter to implement the project due to Force Majeure conditions, then this allotment shall stand terminated and the Promoter shall refund to the Allottee the entire amount received by the Promoter from the allotment within 45 days from that date.After refund of the money paid by the Allottee, the Allottee agrees that he/ she shall not have any rights, claims etc. against the Promoter and that the Promoter shall be released and discharged from all its obligations and liabilities under this Agreement. It is clarified that all amounts collected as taxes, charges, levies, cess, assessments and impositions and deposited with the appropriate authorities concerned shall not be returned by the Promoter and the Allottee shall be free to approach the authorities concerned for refund of such taxes, charges, levies, cess, assessments and impositions. 8.2 The right of the Allottee shall remain restricted to the respective Apartment and the properties appurtenant thereto and the Allottee shall have no right, title or interest nor shall claim any right, title or interest of any kind whatsoever over and in respect of any other Apartment or space and/or any other portions of the Project or Complex. 8.3 The Promoter has provided to the Allottee a time schedule for construction progress based on the milestones on which payment is due. The dates provided are only tentative and for the purpose of dealing with contractors and will also make efforts to complete various stages as per the time schedule upto completion of the Project including the provisions of civic infrastructure like water, electricity, sanitation and all other above mentioned internal/external development works but the Promoter knows there will definitely be delays in the timelines provided but the Promoter assures the Allottee that the Project will be completed within the ‘Completion date’ provided in Clause 8.1 above.

  • Documents Records and Funds in Possession of Master Servicer to be Held for the Trustee Notwithstanding any other provisions of this Agreement, the Master Servicer shall transmit to the Trustee as required by this Agreement all documents and instruments in respect of a Mortgage Loan coming into the possession of the Master Servicer from time to time and shall account fully to the Trustee for any funds received by the Master Servicer or which otherwise are collected by the Master Servicer as Liquidation Proceeds or Insurance Proceeds in respect of any Mortgage Loan. All Mortgage Files and funds collected or held by, or under the control of, the Master Servicer in respect of any Mortgage Loans, whether from the collection of principal and interest payments or from Liquidation Proceeds, including but not limited to, any funds on deposit in the Certificate Account, shall be held by the Master Servicer for and on behalf of the Trustee and shall be and remain the sole and exclusive property of the Trustee, subject to the applicable provisions of this Agreement. The Master Servicer also agrees that it shall not create, incur or subject any Mortgage File or any funds that are deposited in the Certificate Account, Distribution Account or any Escrow Account, or any funds that otherwise are or may become due or payable to the Trustee for the benefit of the Certificateholders, to any claim, lien, security interest, judgment, levy, writ of attachment or other encumbrance, or assert by legal action or otherwise any claim or right of setoff against any Mortgage File or any funds collected on, or in connection with, a Mortgage Loan, except, however, that the Master Servicer shall be entitled to set off against and deduct from any such funds any amounts that are properly due and payable to the Master Servicer under this Agreement.

  • POSSESSION OF THE APARTMENT/PLOT 7.1 Schedule for possession of the said [Apartment/Plot] - The Promoter agrees and understands that timely delivery of possession of the [Apartment/Plot] to the allottee and the common areas to the association of allottees or the competent authority, as the case may be, is the essence of the Agreement. The Promoter assures to hand over possession of the [Apartment/Plot] along with ready and complete common areas with all specifications, amenities and facilities of the project in place on , unless there is delay or failure due to war, flood, drought, fire, cyclone, earthquake or any other calamity caused by nature affecting the regular development of the real estate project (“Force Majeure”). If, however, the completion of the Project is delayed due to the Force Majeure conditions then the Allottee agrees that the Promoter shall be entitled to the extension of time for delivery of possession of the [Apartment/Plot], provided that such Force Majeure conditions are not of a nature which make it impossible for the contract to be implemented. The Allottee agrees and confirms that, in the event it becomes impossible for the Promoter to implement the project due to Force Majeure conditions, then this allotment shall stand terminated and the Promoter shall refund to the Allottee the entire amount received by the Promoter from the allotment within 60 days from that date. The promoter shall intimate the allottee about such termination at least thirty days prior to such termination. After refund of the money paid by the Allottee, the Allottee agrees that he/ she shall not have any rights, claims etc. against the Promoter and that the Promoter shall be released and discharged from all its obligations and liabilities under this Agreement.

  • LOCATION AND DESCRIPTION OF THE PROPERTY The subject property is a single-storey terraced house bearing the postal address of Xx. 00, Xxxxxx 00/XX0, Xxxxxx Xxxxx Xxxxxxx, 00000 Xxxxxxx Xxxxx, Xxxxxx. The subject property will be sold on an “as is where is basis” and subject to a reserve price of RM310,000.00 (RINGGIT MALAYSIA THREE HUNDRED TEN THOUSAND ONLY) and subject to the Conditions of Sale and by way of an Assignment from the above Assignee/Bank subject to the consent being obtained by the Purchaser from the Developer and other relevant authorities if any, including all terms, conditions, stipulations and covenants which were and may be imposed by the Developer and the relevant authorities. Any arrears of quit rent, assessments and service or maintenance charges which may be lawfully due to any relevant authority or the Developer up to the date of auction sale of the property shall be paid out of the purchase money upon receipt of full purchase price. All other fees, costs and charges relating to the transfer and assignment of the property shall be borne by the successful Purchaser. Online bidders are further subject to the Terms & Conditions on xxx.xxxxxxxxxxxxxxxx.xxx. All intending bidders are required to deposit 10% of the fixed reserve price for the said property by Bank Draft or Cashier’s Order in favour of UOBM for KRISHNAMAL A/P MURLIGIAH & XXXXXXXXXXX A/L XXXXXXX or remit the same through online banking transfer, one (1) working day before auction date. The balance of the purchase money shall be paid by the Purchaser within one hundred and twenty (120) days from the date of auction sale to UNITED OVERSEAS BANK (MALAYSIA) BHD via Real Time Electronics Transfer of Funds and Securities (XXXXXX). For online bidders please refer to the Terms & Conditions on xxx.xxxxxxxxxxxxxxxx.xxx on the manner of payment of the deposit. FOR FURTHER PARTICULARS, please contact M/S HOE & MOIRA, of Xxxxx 000X (Xxxxx), 0xx Xxxxx, Xxxxx Xxxxxx Xxxxxx, Xxxxxxxxxx Xxxx, 00000 Xxxxxx, Xxxxxxxx. (Ref:H&M/MT/Z4P/CB23/16) Tel.: 00-000 0000, Fax: 00-000 0000) the Assignee herein or the undermentioned Auctioneer. Suite C-20-3A, Level 20, Block C, Megan Avenue II, / XXXXX XXXXX BIN XXXXXX 00, Xxxxx Xxx Xxxx Xxxx, 50450 Kuala Lumpur (Licensed Auctioneers) Tel No.: 00-0000 0000 Fax No.: 00-0000 0000 Our Ref: LIAN/UOB1035HM Website: xxx.xxxxxxxxxxxxxxxx.xxx E-mail: xxxx@xxxxxxxxxxxxxxxx.xxx [berkuatkuasa dari 1.11.2022, perniagaan perbankan pengguna (consumer banking business) CITIBANK BERHAD (No. Syarikat: 199401011410 (297089-M) telah dipindahmilik kepada xxx diletakhakkan kepada UOB di bawah Perintah Letakhak bertarikh 12.10.2022 melalui Mahkamah Tinggi Kuala Lumpur Saman Pemula No. WA-24NCC-903-09/2022] Dalam menjalankan xxx xxx kuasa xxxx telah diberikan kepada Pihak Pemegang Serahhak/Bank dibawah Perjanjian Kemudahan, Penyerahanhak xxx Surat Kuasa Wakil kesemuanya Bertarikh 09hb Julai, 2001 diantara Pihak Penyerahhak, Pihak Pelanggan xxx Pihak Pemegang Serahhak/Bank yang diperbuat dalam perkara diatas, adalah dengan ini diisytiharkan bahawa Pihak Pemegang Serahhak/Bank tersebut dengan bantuan Pelelong yang tersebut dibawah.

  • Documents, Records and Funds in Possession of the Servicer to be Held for the Trustee The Servicer shall transmit to the Trustee or, at the direction of the Trustee, the Custodian as required by this Agreement all documents and instruments in respect of a Mortgage Loan coming into the possession of the Servicer from time to time and shall account fully to the Trustee for any funds received by the Servicer or which otherwise are collected by the Servicer as Liquidation Proceeds or Insurance Proceeds in respect of any Mortgage Loan. The documents constituting the Servicing File shall be held by the Servicer as custodian and bailee for the Trustee. All Mortgage Files and funds collected or held by, or under the control of, the Servicer in respect of any Mortgage Loans, whether from the collection of principal and interest payments or from Liquidation Proceeds, including but not limited to, any funds on deposit in the Servicer Custodial Account, shall be held by the Servicer for and on behalf of the Trustee and shall be and remain the sole and exclusive property of the Trustee, subject to the applicable provisions of this Agreement. The Servicer also agrees that it shall not knowingly create, incur or subject any Mortgage File or any funds that are deposited in the Servicer Custodial Account, Certificate Account or any Escrow Account, or any funds that otherwise are or may become due or payable to the Trustee for the benefit of the Certificateholders, to any claim, lien, security interest, judgment, levy, writ of attachment or other encumbrance created by the Servicer, or assert by legal action or otherwise any claim or right of setoff against any Mortgage File or any funds collected on, or in connection with, a Mortgage Loan, except, however, that the Servicer shall be entitled to set off against and deduct from any such funds any amounts that are properly due and payable to the Servicer under this Agreement.

  • Documents, Records and Funds in Possession of Master Servicer To Be Held for Trustee (a) The Master Servicer shall transmit and each Servicer (to the extent required by the related Servicing Agreement) shall transmit to the Trustee or Custodian such documents and instruments coming into the possession of the Master Servicer or such Servicer from time to time as are required by the terms hereof, or in the case of the Servicers, the applicable Servicing Agreement, to be delivered to the Trustee or Custodian. Any funds received by the Master Servicer or by a Servicer in respect of any Mortgage Loan or which otherwise are collected by the Master Servicer or by a Servicer as Liquidation Proceeds or Insurance Proceeds in respect of any Mortgage Loan shall be held for the benefit of the Trustee and the Certificateholders subject to the Master Servicer's right to retain or withdraw from the Master Servicer Collection Account the Master Servicing Compensation and other amounts provided in this Agreement, and to the right of each Servicer to retain its Servicing Fee and other amounts as provided in the applicable Servicing Agreement. The Master Servicer shall, and (to the extent provided in the applicable Servicing Agreement) shall cause each Servicer to, provide access to information and documentation regarding the Mortgage Loans to the Trustee, its agents and accountants at any time upon reasonable request and during normal business hours, and to Certificateholders that are savings and loan associations, banks or insurance companies, the Office of Thrift Supervision, the FDIC and the supervisory agents and examiners of such Office and Corporation or examiners of any other federal or state banking or insurance regulatory authority if so required by applicable regulations of the Office of Thrift Supervision or other regulatory authority, such access to be afforded without charge but only upon reasonable request in writing and during normal business hours at the offices of the Master Servicer designated by it. In fulfilling such a request the Master Servicer shall not be responsible for determining the sufficiency of such information. (b) All Mortgage Files and funds collected or held by, or under the control of, the Master Servicer, in respect of any Mortgage Loans, whether from the collection of principal and interest payments or from Liquidation Proceeds or Insurance Proceeds, shall be held by the Master Servicer for and on behalf of the Trustee and the Certificateholders and shall be and remain the sole and exclusive property of the Trustee; provided, however, that the Master Servicer and each Servicer shall be entitled to setoff against, and deduct from, any such funds any amounts that are properly due and payable to the Master Servicer or such Servicer under this Agreement or the applicable Servicing Agreement.

  • Access to the Property 1. We and our representatives shall only have access to the Property during the Vendor's normal business hours upon reasonable notice to the Vendor, at our sole risk and expense. Such site visits shall be conducted in the presence of a representative of the Vendor, in a manner that minimizes interference with the use of the Property and does not contravene any leases or unreasonably interfere with any Tenants. We and our representatives shall not have any communications with Tenants or their employees without the prior written approval of the Vendor and in the presence of a representative of the Vendor.

  • TERMINATION OR OPTIONAL PURCHASE OF ALL CERTIFICATES Section 9.01. Optional Purchase by the Master Servicer of All Certificates; Termination Upon Purchase by the Master Servicer or Liquidation of All Mortgage Loans. (a) Subject to Section 9.02, the respective obligations and responsibilities of the Company, the Master Servicer and the Trustee created hereby in respect of the Certificates (other than the obligation of the Trustee to make certain payments after the Final Distribution Date to Certificateholders and the obligation of the Company to send certain notices as hereinafter set forth) shall terminate upon the last action required to be taken by the Trustee on the Final Distribution Date pursuant to this Article IX following the earlier of: (i) the later of the final payment or other liquidation (or any Advance with respect thereto) of the last Mortgage Loan remaining in the Trust Fund or the disposition of all property acquired upon foreclosure or deed in lieu of foreclosure of any Mortgage Loan, or (ii) the purchase by the Master Servicer of all Mortgage Loans and all property acquired in respect of any Mortgage Loan remaining in the Trust Fund at a price equal to 100% of the unpaid principal balance of each Mortgage Loan or, if less than such unpaid principal balance, the fair market value of the related underlying property of such Mortgage Loan with respect to Mortgage Loans as to which title has been acquired if such fair market value is less than such unpaid principal balance (net of any unreimbursed Advances attributable to principal) on the day of repurchase plus accrued interest thereon at the Net Mortgage Rate (or Modified Net Mortgage Rate in the case of any Modified Mortgage Loan) to, but not including, the first day of the month in which such repurchase price is distributed, provided, however, that in no event shall the trust created hereby continue beyond the expiration of 21 years from the death of the last survivor of the descendants of Xxxxxx X. Xxxxxxx, the late ambassador of the United States to the Court of St. Xxxxx, living on the date hereof and provided further that the purchase price set forth above shall be increased as is necessary, as determined by the Master Servicer, to avoid disqualification of any portion of any REMIC formed under the Series Supplement as a REMIC. The purchase price paid by the Master Servicer shall also include any amounts owed by Residential Funding pursuant to the last paragraph of Section 4 of the Assignment Agreement in respect of any liability, penalty or expense that resulted from a breach of the Compliance With Laws Representation, that remain unpaid on the date of such purchase. The right of the Master Servicer to purchase all the assets of the Trust Fund pursuant to clause (ii) above is conditioned upon the Pool Stated Principal Balance as of the Final Distribution Date, prior to giving effect to distributions to be made on such Distribution Date, being less than ten percent of the Cut-off Date Principal Balance of the Mortgage Loans. If such right is exercised by the Master Servicer, the Master Servicer shall be deemed to have been reimbursed for the full amount of any unreimbursed Advances theretofore made by it with respect to the Mortgage Loans. In addition, the Master Servicer shall provide to the Trustee the certification required by Section 3.15 and the Trustee and the Custodian shall, promptly following payment of the purchase price, release to the Master Servicer the Custodial Files pertaining to the Mortgage Loans being purchased. In addition to the foregoing, on any Distribution Date on which the Pool Stated Principal Balance, prior to giving effect to distributions to be made on such Distribution Date, is less than ten percent of the Cut-off Date Principal Balance of the Mortgage Loans, the Master Servicer shall have the right, at its option, to purchase the Certificates in whole, but not in part, at a price equal to the outstanding Certificate Principal Balance of such Certificates plus the sum of Accrued Certificate Interest thereon for the related Interest Accrual Period and any previously unpaid Accrued Certificate Interest. If the Master Servicer exercises this right to purchase the outstanding Certificates, the Master Servicer will promptly terminate the respective obligations and responsibilities created hereby in respect of the Certificates pursuant to this Article IX. (b) The Master Servicer shall give the Trustee not less than 40 days' prior notice of the Distribution Date on which the Master Servicer anticipates that the final distribution will be made to Certificateholders (whether as a result of the exercise by the Master Servicer of its right to purchase the assets of the Trust Fund or otherwise) or on which the Master Servicer anticipates that the Certificates will be purchased (as a result of the exercise by the Master Servicer to purchase the outstanding Certificates). Notice of any termination specifying the anticipated Final Distribution Date (which shall be a date that would otherwise be a Distribution Date) upon which the Certificateholders may surrender their Certificates to the Trustee (if so required by the terms hereof) for payment of the final distribution and cancellation or notice of any purchase of the outstanding Certificates, specifying the Distribution Date upon which the Holders may surrender their Certificates to the Trustee for payment, shall be given promptly by the Master Servicer (if it is exercising its right to purchase the assets of the Trust Fund or to purchase the outstanding Certificates), or by the Trustee (in any other case) by letter. Such notice shall be prepared by the Master Servicer (if it is exercising its right to purchase the assets of the Trust Fund or to purchase the outstanding Certificates), or by the Trustee (in any other case) and mailed by the Trustee to the Certificateholders not earlier than the 15th day and not later than the 25th day of the month next preceding the month of such final distribution specifying: (i) the anticipated Final Distribution Date upon which final payment of the Certificates is anticipated to be made upon presentation and surrender of Certificates at the office or agency of the Trustee therein designated where required pursuant to this Agreement or, in the case of the purchase by the Master Servicer of the outstanding Certificates, the Distribution Date on which such purchase is to be made, (ii) the amount of any such final payment, or in the case of the purchase of the outstanding Certificates, the purchase price, in either case, if known, and (iii) that the Record Date otherwise applicable to such Distribution Date is not applicable, and in the case of the Senior Certificates, or in the case of all of the Certificates in connection with the exercise by the Master Servicer of its right to purchase the Certificates, that payment will be made only upon presentation and surrender of the Certificates at the office or agency of the Trustee therein specified. If the Master Servicer is obligated to give notice to Certificateholders as aforesaid, it shall give such notice to the Certificate Registrar at the time such notice is given to Certificateholders and, if the Master Servicer is exercising its rights to purchase the outstanding Certificates, it shall give such notice to each Rating Agency at the time such notice is given to Certificateholders. As a result of the exercise by the Master Servicer of its right to purchase the assets of the Trust Fund, the Master Servicer shall deposit in the Certificate Account, before the Final Distribution Date in immediately available funds an amount equal to the purchase price for the assets of the Trust Fund, computed as provided above. As a result of the exercise by the Master Servicer of its right to purchase the outstanding Certificates, the Master Servicer shall deposit in an Eligible Account, established by the Master Servicer on behalf of the Trustee and separate from the Certificate Account in the name of the Trustee in trust for the registered holders of the Certificates, before the Distribution Date on which such purchase is to occur in immediately available funds an amount equal to the purchase price for the Certificates, computed as above provided, and provide notice of such deposit to the Trustee. The Trustee will withdraw from such account the amount specified in subsection (c) below. (c) In the case of the Senior Certificates, upon presentation and surrender of the Certificates by the Certificateholders thereof, and in the case of the Class M and Class B Certificates, upon presentation and surrender of the Certificates by the Certificateholders thereof in connection with the exercise by the Master Servicer of its right to purchase the Certificates, and otherwise in accordance with Section 4.01(a), the Trustee shall distribute to the Certificateholders (i) the amount otherwise distributable on such Distribution Date, if not in connection with the Master Servicer's election to repurchase the assets of the Trust Fund or the outstanding Certificates, or (ii) if the Master Servicer elected to so repurchase the assets of the Trust Fund or the outstanding Certificates, an amount determined as follows: (A) with respect to each Certificate the outstanding Certificate Principal Balance thereof, plus Accrued Certificate Interest for the related Interest Accrual Period thereon and any previously unpaid Accrued Certificate Interest, subject to the priority set forth in Section 4.02(a), and (B) with respect to the Class R Certificates, any excess of the amounts available for distribution (including the repurchase price specified in clause (ii) of subsection (a) of this Section) over the total amount distributed under the immediately preceding clause (A). Notwithstanding the reduction of the Certificate Principal Balance of any Class of Subordinate Certificates to zero, such Class will be outstanding hereunder until the termination of the respective obligations and responsibilities of the Company, the Master Servicer and the Trustee hereunder in accordance with Article IX. (d) If any Certificateholders shall not surrender their Certificates for final payment and cancellation on or before the Final Distribution Date (if so required by the terms hereof), the Trustee shall on such date cause all funds in the Certificate Account not distributed in final distribution to Certificateholders to be withdrawn therefrom and credited to the remaining Certificateholders by depositing such funds in a separate escrow account, which may be non-interest bearing, for the benefit of such Certificateholders, and the Master Servicer (if it exercised its right to purchase the assets of the Trust Fund), or the Trustee (in any other case) shall give a second written notice to the remaining Certificateholders to surrender their Certificates for cancellation and receive the final distribution with respect thereto. If within six months after the second notice any Certificate shall not have been surrendered for cancellation, the Trustee shall take appropriate steps as directed by the Master Servicer to contact the remaining Certificateholders concerning surrender of their Certificates. The costs and expenses of maintaining the escrow account and of contacting Certificateholders shall be paid out of the assets which remain in the escrow account. If within nine months after the second notice any Certificates shall not have been surrendered for cancellation, the Trustee shall pay to the Master Servicer all amounts distributable to the holders thereof and the Master Servicer shall thereafter hold such amounts until distributed to such Holders. No interest shall accrue or be payable to any Certificateholder on any amount held in the escrow account or by the Master Servicer as a result of such Certificateholder's failure to surrender its Certificate(s) for final payment thereof in accordance with this Section 9.01. (e) If any Certificateholders do not surrender their Certificates on or before the Distribution Date on which a purchase of the outstanding Certificates is to be made, the Trustee shall on such date cause all funds in the Certificate Account deposited therein by the Master Servicer pursuant to Section 9.01(b) to be withdrawn therefrom and deposited in a separate escrow account, which may be non-interest bearing, for the benefit of such Certificateholders, and the Master Servicer shall give a second written notice to such Certificateholders to surrender their Certificates for payment of the purchase price therefor. If within six months after the second notice any Certificate shall not have been surrendered for cancellation, the Trustee shall take appropriate steps as directed by the Master Servicer to contact the Holders of such Certificates concerning surrender of their Certificates. The costs and expenses of maintaining the escrow account and of contacting Certificateholders shall be paid out of the assets which remain in the escrow account. If within nine months after the second notice any Certificates shall not have been surrendered for cancellation in accordance with this Section 9.01, the Trustee shall pay to the Master Servicer all amounts distributable to the Holders thereof and the Master Servicer shall thereafter hold such amounts until distributed to such Holders. No interest shall accrue or be payable to any Certificateholder on any amount held in the escrow account or by the Master Servicer as a result of such Certificateholder's failure to surrender its Certificate(s) for payment in accordance with this Section 9.01. Any Certificate that is not surrendered on the Distribution Date on which a purchase pursuant to this Section 9.01 occurs as provided above will be deemed to have been purchased and the Holder as of such date will have no rights with respect thereto except to receive the purchase price therefor minus any costs and expenses associated with such escrow account and notices allocated thereto. Any Certificates so purchased or deemed to have been purchased on such Distribution Date shall remain outstanding hereunder until the Master Servicer has terminated the respective obligations and responsibilities created hereby in respect of the Certificates pursuant to this Article IX. The Master Servicer shall be for all purposes the Holder thereof as of such date.

  • Possession of the Property The Parties hereby agree that the exclusive possession of the Property shall be delivered by the Seller to the Buyer on

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!