Termination for Market Change (a) In the event of delay or interruption under B8.33, exceeding 90 days, and Contract has not been modified to include replacement timber, this contract may be terminated upon election and written notice by Purchaser, if (i) a rate redetermination for market change under B3.33 shows that the appraised weighted average Indicated Advertised Rate of all Included Timber remaining immediately prior to the delay or interruption has been reduced through a market change by an amount equal to or more than the the weighted average Current Contract Rate, or (ii) the appraised value of the remaining timber is insufficient to cover the adjusted base rates as determined under B3.33.
HHS Single Audit Unit will notify Grantee to complete the Single Audit Determination Form If Grantee fails to complete the form within thirty (30) calendar days after receipt of notice, Grantee maybe subject to sanctions and remedies for non-compliance.
Payment for Material Completion The Contractor may request payment of the remaining contract balance, including retainage, less amounts credited the Owner or incurred as liquidated damages, and less amounts withheld for the Punchlist by reason of Minor Items or Permitted Incomplete Work (See Paragraph 6.5.3.2). Payment for Material Completion shall be made by a check payable jointly to the Contractor and Surety and shall be mailed to the Surety.
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Payment Method Used for My Transaction Selecting a preferred payment method Paying online If you have chosen an online preferred payment method, it will be shown as the primary method of payment. We'll process payments for goods or services made online using your preferred payment method or an available payment method you choose for a particular transaction during checkout. We'll process payments to friends and family using an available payment method you choose for the transaction. In-store and Automatic Payments If you have chosen a preferred payment method for in store transactions or for automatic payments, we'll process the payment using: • any PayPal balance you hold in the currency of the payment; then • your preferred payment method or an available payment method you choose for any remaining amount. There may be times when your preferred payment method cannot be used, for example, if you select a card that has expired. We may remove cards that are expired or otherwise not able to be processed from your account. The availability of certain payment methods may be limited based on that particular seller or the third party website you are using to complete the transaction. Backup payment method Certain one-time online transactions may require that a backup funding method be used in the event that your selected or preferred payment method has expired or declined. In those instances, the backup funding method may be displayed to you on your transaction review page, before you complete the transaction. Note that this only applies for one- time, online transactions, and not for in-store or automatic payments. If PayPal determines currency conversion is necessary for a transaction that also requires a backup payment method, you may not be able to separately choose whether PayPal or your card issuer performs the currency conversion on your backup payment method. Sending money to friends and family When you send money to friends and family using your PayPal balance or your bank account, we waive all fees, so we always show you these payment options first, if available, even if you have a set preferred payment method for your online purchases. Remember, you always have the choice to select any payment method in your account by clicking the “Change” link on the Send Money page. We will always show you if there is a fee and how much the fee is before you send money. Automatic payments Choosing PayPal as your way of paying a seller may involve entering into an agreement with them that permits the seller to request that we process your PayPal account each time you make a purchase. You can select a payment method for future purchases with a particular seller either at the time of creating the agreement or in your account settings at xxx.xxxxxx.xxx.xx. For example, you can instruct your monthly movie subscription service to always charge your credit card in your PayPal wallet for the monthly cost. If your chosen payment method is unavailable (e.g. credit card expired), a particular agreement with a seller does not provide for the ability to specify a payment method, or if you have not designated a payment method for future transactions with a seller, the payment method used will be in the following order, if applicable: 1. balance; 2. bank account; 3. debit card; and 4. credit card. You can cancel any agreement in your account settings at xxx.xxxxxx.xxx.xx. Pay with Rewards PayPal may allow you to redeem rewards associated with your eligible card(s) when making a purchase with your PayPal account through PayPal's Pay with Rewards program. PayPal may share with and receive information from your issuer about your issuer accounts to complete the redemption of your rewards when using PayPal's Pay with Rewards program. The exchange of this information is necessary to complete the purchase when you select the Pay with Rewards redemption option. All Pay with Rewards redemptions are subject to the terms of your card agreement with your card issuer. Pay with Rewards is only available for eligible purchases with certain merchants, and PayPal or your issuer may limit, suspend, or terminate your ability to redeem rewards at any time in accordance with this user agreement, and/or your card agreement and reward program terms. Your issuer determines the value of rewards redeemed through PayPal and available redemption methods (e.g., to pay for your purchase or for a statement credit). There may be a delay between checkout with Pay with Rewards and processing of your payment. Only rewards available upon processing of your payment will be used. Because your reward balance and/or transaction balance may change, whenever you request to redeem rewards for a purchase you also authorise PayPal to charge up to the full payment amount to your associated card if that happens. Cancellations and refunds are subject to your merchant's cancellation and refund policy. PayPal may cancel your transaction as outlined in this user agreement. If your transaction is cancelled or you return your purchase, your refund will be processed back as a dollar amount; depending on your card agreement and reward program terms with your issuer, your issuer may or may not credit your purchase back to your reward balance. If you split your payment between your reward balance and another payment method, PayPal and/or your issuer will choose the order and split of funds when processing a cancellation or refund. Each card issuer may treat chargebacks for purchases involving rewards redemption differently, please check with your card issuer for more information. If your card information changes (including if it is reissued with a new account number), you may need to update your PayPal wallet and re-enroll your card to continue using rewards.
Rate Redetermination for Market Change In the event of delay or interruption, exceeding 90 days, under B8.33, Contracting Officer shall make an appraisal to determine for each species the difference between the appraised unit value of Included Timber immediately prior to the delay or interruption and the appraised unit value of Included Timber immediately after the delay or interruption. The appraisal shall be done after any rate redetermination done pursuant to B3.31, using remaining volumes. Tentative Rates and Flat Rates in effect at the time of delay or interruption or established pursuant to B3.31 will be reduced, if appraised rates declined during the delay or interruption, to become Current Contract Rates. Increases in rates will not be considered. Accordingly, Base Rates shall be adjusted to correspond to the redetermined rates if redetermined rates are less than the original Base Rates, subject to a new Base Rate limitation of the cost of essential reforestation or 25 cents per hundred cubic feet or equivalent, whichever is larger. However, existing Base Indices shall not be changed under this Subsection. Redetermined rates shall be considered established under B3.1 for timber Scaled subsequent to the delay or interruption.
Master Contract Sales Reporting System Contractor shall report quarterly Master Contract sales in Enterprise Services’ Master Contract Sales Reporting System. Enterprise Services will provide Contractor with a login password and a vendor number. The password and vendor number will be provided to the Sales Reporting Representative(s) listed on Contractor’s Bidder Profile.
Rate Redetermination for Environmental Modification In the event of a contract modification under B8.33 or partial termination under B8.34, Contracting Officer shall make an appraisal to determine for each species the difference between the appraised unit value of Included Timber remaining immediately prior to the revision and the appraised unit value of Included Timber to be cut under the modification. The appraisal shall consider the estimated cost of any construction work listed in the Schedule of Items that was performed and abandoned. Tentative Rates and Flat Rates in effect at the time of the revision will be adjusted by said differences to become Current Contract Rates. Accordingly, Base Rates shall be adjusted to correspond to the redetermined rates if redetermined rates are less than the original Base Rates, subject to a new Base Rate limitation of the cost of essential reforestation or 25 cents per hundred cubic feet or equivalent, whichever is larger. However, existing Base Indices shall not be changed under this Subsection. Redetermined rates, or differences for rates subject to B3.2, and Required Deposits shall be considered established under B3.1 for timber Scaled subsequent to the contract revision.
PAYMENT TERMS/PRE-PAYMENT/QUANTITY DISOUNTS If discounts for accelerated payment, pre-payment, progress payment, or quantity discounts are offered, they must be clearly indicated in the Contractor’s submission prior to contract award. The applicability or acceptance of these terms is at the discretion of the Customer.
Automatic Renewal Limitation for TIPS Sales No TIPS Sale may incorporate an automatic renewal clause that exceeds month to month terms with which the TIPS Member must comply. All renewal terms incorporated into a TIPS Sale Supplemental Agreement shall only be valid and enforceable when Vendor received written confirmation of acceptance of the renewal term from the TIPS Member for the specific renewal term. The purpose of this clause is to avoid a TIPS Member inadvertently renewing an Agreement during a period in which the governing body of the TIPS Member has not properly appropriated and budgeted the funds to satisfy the Agreement renewal. Any TIPS Sale Supplemental Agreement containing an “Automatic Renewal” clause that conflicts with these terms is rendered void and unenforceable.
