Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. Does Vendor agree? Yes, Vendor agrees Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body.
General Provisions Applicable to Loans and Letters of Credit 4.1. Interest Rates and Payment Dates
4.2. Conversion and Continuation Options
4.3. Minimum Amounts of Sets
Federal Medicaid System Security Requirements Compliance Party shall provide a security plan, risk assessment, and security controls review document within three months of the start date of this Agreement (and update it annually thereafter) in order to support audit compliance with 45 CFR 95.621 subpart F, ADP System Security Requirements and Review Process.
GUARANTEED DISPLAY REFERRAL FEE WAIVERS XXXX.xxx offers a paid featured agent program referred to as “Guaranteed Display.” This paid product provides the following Referral Fee benefits to the Recipient Broker/Agent: • If a closing results from a lead originated during the time, and in the zip code, that the Recipient Broker/Agent was an active Guaranteed Display sponsor, the referral fee will be discounted from the standard 35% to 30%. • If a closing results from a lead originated during the time, and in the zip code, that the Recipient Broker/Agent was an active Guaranteed Display sponsor, and if XXXX.xxx was not responsible for brokering an appointment between the Referred Client and the Recipient Broker/ Agent, the referral fee will be waived entirely to 0%. To qualify for this Referral Fee waiver, Recipient Broker/Agent must update the Referral Status in the XXXX.xxx Agent Portal (xxxxx://xxxxxx.xxxx.xxx) to reflect the property has been listed prior to XXXX.xxx indicating that an appointment has been set.
New Hampshire Specific Data Security Requirements The Provider agrees to the following privacy and security standards from “the Minimum Standards for Privacy and Security of Student and Employee Data” from the New Hampshire Department of Education. Specifically, the Provider agrees to:
(1) Limit system access to the types of transactions and functions that authorized users, such as students, parents, and LEA are permitted to execute;
(2) Limit unsuccessful logon attempts;
(3) Employ cryptographic mechanisms to protect the confidentiality of remote access sessions;
(4) Authorize wireless access prior to allowing such connections;
(5) Create and retain system audit logs and records to the extent needed to enable the monitoring, analysis, investigation, and reporting of unlawful or unauthorized system activity;
(6) Ensure that the actions of individual system users can be uniquely traced to those users so they can be held accountable for their actions;
(7) Establish and maintain baseline configurations and inventories of organizational systems (including hardware, software, firmware, and documentation) throughout the respective system development life cycles;
(8) Restrict, disable, or prevent the use of nonessential programs, functions, ports, protocols, and services;
(9) Enforce a minimum password complexity and change of characters when new passwords are created;
(10) Perform maintenance on organizational systems;
(11) Provide controls on the tools, techniques, mechanisms, and personnel used to conduct system maintenance;
(12) Ensure equipment removed for off-site maintenance is sanitized of any Student Data in accordance with NIST SP 800-88 Revision 1;
(13) Protect (i.e., physically control and securely store) system media containing Student Data, both paper and digital;
(14) Sanitize or destroy system media containing Student Data in accordance with NIST SP 800-88 Revision 1 before disposal or release for reuse;
(15) Control access to media containing Student Data and maintain accountability for media during transport outside of controlled areas;
(16) Periodically assess the security controls in organizational systems to determine if the controls are effective in their application and develop and implement plans of action designed to correct deficiencies and reduce or eliminate vulnerabilities in organizational systems;
(17) Monitor, control, and protect communications (i.e., information transmitted or received by organizational systems) at the external boundaries and key internal boundaries of organizational systems;
(18) Deny network communications traffic by default and allow network communications traffic by exception (i.e., deny all, permit by exception);
(19) Protect the confidentiality of Student Data at rest;
(20) Identify, report, and correct system flaws in a timely manner;
(21) Provide protection from malicious code (i.e. Antivirus and Antimalware) at designated locations within organizational systems;
(22) Monitor system security alerts and advisories and take action in response; and
(23) Update malicious code protection mechanisms when new releases are available.
Special Provisions Applicable to LIBOR Rate (i) The LIBOR Rate may be adjusted by Agent with respect to any Lender on a prospective basis to take into account any additional or increased costs to such Lender of maintaining or obtaining any eurodollar deposits or increased costs, in each case, due to changes in applicable law occurring subsequent to the commencement of the then applicable Interest Period, including any Changes in Law (including any changes in tax laws (except changes of general applicability in corporate income tax laws)) and changes in the reserve requirements imposed by the Board of Governors, which additional or increased costs would increase the cost of funding or maintaining loans bearing interest at the LIBOR Rate. In any such event, the affected Lender shall give Borrowers and Agent notice of such a determination and adjustment and Agent promptly shall transmit the notice to each other Lender and, upon its receipt of the notice from the affected Lender, Borrowers may, by notice to such affected Lender (A) require such Lender to furnish to Borrowers a statement setting forth in reasonable detail the basis for adjusting such LIBOR Rate and the method for determining the amount of such adjustment, or (B) repay the LIBOR Rate Loans of such Lender with respect to which such adjustment is made (together with any amounts due under Section 2.12(b)(ii)).
(ii) In the event that any change in market conditions or any Change in Law shall at any time after the date hereof, in the reasonable opinion of any Lender, make it unlawful or impractical for such Lender to fund or maintain LIBOR Rate Loans or to continue such funding or maintaining, or to determine or charge interest rates at the LIBOR Rate, such Lender shall give notice of such changed circumstances to Agent and Borrowers and Agent promptly shall transmit the notice to each other Lender and (y) in the case of any LIBOR Rate Loans of such Lender that are outstanding, the date specified in such Lender’s notice shall be deemed to be the last day of the Interest Period of such LIBOR Rate Loans, and interest upon the LIBOR Rate Loans of such Lender thereafter shall accrue interest at the rate then applicable to Base Rate Loans, and (z) Borrowers shall not be entitled to elect the LIBOR Option until such Lender determines that it would no longer be unlawful or impractical to do so.
General Conditions Applicable to Insurance All policies of insurance required by this section shall comply with the following requirements:
Requirements Pertaining Only to Federal Grants and Subrecipient Agreements If this Agreement is a grant that is funded in whole or in part by Federal funds:
Geographic Area and Sector Specific Allowances, Conditions and Exceptions The following allowances and conditions shall apply where relevant. Where the Employer does work which falls under the following headings, the Employer agrees to pay and observe the relevant respective conditions and/or exceptions set out below in each case.
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE
1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State.
1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent.
1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State.
1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress.
1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER.
1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period.
1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State.
1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work.
1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon.
1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval.
1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6.
1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover.
1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions.
1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment.
1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
