Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Certification Regarding Lobbying Applicable to Grants Subgrants, Cooperative Agreements, and Contracts Exceeding $100,000 in Federal Funds Submission of this certification is a prerequisite for making or entering into this transaction and is imposed by section 1352, Title 31, U.S. Code. This certification is a material representation of fact upon which reliance was placed when this transaction was made or entered into. Any person who fails to file the required certification shall be subject to a civil penalty of not less than $10,000 and not more than $100,000 for each such failure. The undersigned certifies, to the best of his or her knowledge and belief, that: (1) No Federal appropriated funds have been paid or will be paid by or on behalf of the undersigned, to any person for influencing or attempting to influence an officer or employee of any agency, a Member of Congress, an officer or employee of congress, or an employee of a Member of Congress in connection with the awarding of a Federal contract, the making of a Federal grant, the making of a Federal loan, the entering into a cooperative agreement, and the extension, continuation, renewal, amendment, or modification of a Federal contract, grant, loan, or cooperative agreement.
Limitations Applicable to Section 16 Persons Notwithstanding any other provision of the Plan or this Agreement, if Participant is subject to Section 16 of the Exchange Act, the Plan, the Option and this Agreement shall be subject to any additional limitations set forth in any applicable exemptive rule under Section 16 of the Exchange Act (including any amendment to Rule 16b-3 of the Exchange Act) that are requirements for the application of such exemptive rule. To the extent permitted by applicable law, this Agreement shall be deemed amended to the extent necessary to conform to such applicable exemptive rule.
COMPLIANCE WITH LICENSING REQUIREMENTS CONTRACTOR shall comply with all necessary licensing requirements and shall obtain appropriate licenses and display the same in a location that is reasonably conspicuous, as well as file copies of same with the County Executive Office.
Geographic Area and Sector Specific Allowances, Conditions and Exceptions The following allowances and conditions shall apply where relevant. Where the Employer does work which falls under the following headings, the Employer agrees to pay and observe the relevant respective conditions and/or exceptions set out below in each case.
Requirements Pertaining Only to Federal Grants and Subrecipient Agreements If this Agreement is a grant that is funded in whole or in part by Federal funds:
RELEASE OF GENERAL INFORMATION TO THE PUBLIC AND MEDIA NASA or Partner may, consistent with Federal law and this Agreement, release general information regarding its own participation in this Agreement as desired. Pursuant to Section 841(d) of the NASA Transition Authorization Act of 2017, Public Law 115-10 (the "NTAA"), NASA is obligated to publicly disclose copies of all agreements conducted pursuant to NASA's 51 U.S.C. §20113(e) authority in a searchable format on the NASA website within 60 days after the agreement is signed by the Parties. The Parties acknowledge that a copy of this Agreement will be disclosed, without redactions, in accordance with the NTAA.
Public Posting of Approved Users’ Research Use Statement The PI agrees that information about themselves and the approved research use will be posted publicly on the dbGaP website. The information includes the PI’s name and Requester, project name, Research Use Statement, and a Non-Technical Summary of the Research Use Statement. In addition, and if applicable, this information may include the Cloud Computing Use Statement and name of the CSP or PCS. Citations of publications resulting from the use of controlled-access datasets obtained through this DAR may also be posted on the dbGaP website.
Penalties for Non-compliance to Service Level Agreement Where the Supplier/Service Provider fails to deliver the Goods/Services within the agreed and accepted milestone timelines and provided that the cause of the delay was not due to a fault of Transnet, penalties shall be imposed at …………………………………………………… .
