DELAYS AND EXTENSIONS OF TIME 8.3.1 If the Contractor is delayed at any time in the progress of the Work by any act or failure to act by the State or the Architect, or by any employee of either, or by any separate contractor employed by the State, or by changes ordered in the Work, fire, unusual delay in transportation, adverse weather conditions not reasonably anticipatable, unavoidable casualties, or any causes beyond the Contractor's control, or by delay authorized by the State pending alternative dispute resolution proceedings, or by any other cause which may justify the delay, then the Contract Time shall be extended by Change Order for such reasonable time as recommended by the Architect and approved by the State.
Submissions on Behalf of Others Should You wish to submit work that is not Your original creation, You may submit it to OIDF separately from any Contribution, identifying the complete details of its source and of any license or other restriction (including, but not limited to, related patents, trademarks, and license agreements) of which you are personally aware, and conspicuously marking the work as "Submitted on behalf of a third-party: [named here]".
Delays and Extensions The CONSULTANT agrees that no charges or claim for damages shall be made by it for any minor delays from any cause whatsoever during the progress of any portion of the Services specified in this Contract. Such delays, if any, shall be compensated for by an extension of time for such period as may be determined by the LPA subject to the CONSULTANT's approval, it being understood, however, that permitting the CONSULTANT to proceed to complete any services, or any part of them after the date to which the time of completion may have been extended, shall in no way operate as a waiver on the part of the LPA of any of its rights herein. In the event of substantial delays or extensions, or change of any kind, not caused by the CONSULTANT, which causes a material change in scope, character or complexity of work the CONSULTANT is to perform under this Contract, the LPA at its sole discretion shall determine any adjustments in compensation and in the schedule for completion of the Services. CONSULTANT must notify the LPA in writing of a material change in the work immediately after the CONSULTANT first recognizes the material change.
Limitations on Transfers Federal regulations limit transfers for savings accounts and money market accounts, if applicable. During any statement period, you may not make more than six withdrawals or transfers to another Credit Union account of yours or to a third party by means of a pre-authorized or automatic transfer. This includes transfers by phone, fax, wire and cable, audio response, overdraft transfers to checking and Internet instruction. No more than three of the six transfers may be made by check, draft or debit card, or similar order to a third party. A pre-authorized transfer includes any arrangement with us to pay a third party from your account upon oral or written orders including orders received through the automated clearinghouse (ACH). If you exceed the transfer limitations set forth above in any statement period, the transfer may not be completed, your regular share account and draft account may be subject to a fee, account closure, or suspension or we may revoke your access to Online Banking. We will not be required to complete a withdrawal or transfer from your account(s) if you do not have enough money in the designated account(s) to cover the transaction; however, we may complete the transaction. You agree not to use Online Banking to initiate a transaction that would cause the balance in your designated account(s) to go below zero. If you have a line-of-credit, you agree not to use Online Banking to initiate a transaction that would cause the outstanding balance of your line-of-credit to go above your credit limit. We will not be required to complete such a transaction, but if we do, you agree to pay us the excess amount or improperly withdrawn amount or transferred amount immediately upon our request. We also will refuse to complete your Online Banking transactions if we have canceled your Online Banking access, or we cannot complete the transaction for security reasons. The functions and limitations of Online Banking may be updated, without notice, at the option of the Credit Union in order to provide improved service to the membership.
Definitions and Other Provisions of General Application SECTION 101.
Exclusion of applications on preliminary points of law Any recourse to any Court for the determination of a preliminary point of law arising in the course of the arbitration proceedings is excluded.
Limitations on Use No part of the moneys delivered to the Recipient pursuant to Section II hereof is being or will be used to refinance, retire, redeem, or otherwise pay debt service on all or any part of any part of any governmental obligations regardless of whether the interest on such obligations is or was excluded from gross income for federal income tax purposes unless prior approval by the Director is given.
Limitations on Transfer In addition to any other limitation on transfer created by applicable securities laws, Purchaser shall not assign, encumber or dispose of any interest in the Shares except in compliance with the provisions below and applicable securities laws.
Limitations on Frequency and Dollar Amounts of Transactions We impose certain limitations on the number or dollar amount of transactions you can make with your Card. Detailed at the end of this Agreement is a table of limitations that apply to the Card. For security reasons, we may further limit the number or dollar amount of transactions you can make with your Card. We may increase or decrease these limits from time to time in our sole discretion and, to the extent permitted by applicable law, without prior notice to you.
Limitations on License (a) This license is not assignable or transferable by operation of law or otherwise, except as provided in Paragraph "1(b)" hereof, and is limited to the LICENSEE and to the premises.
