Assets and Liabilities At the Effective Time, the Surviving Corporation shall possess all the rights, privileges, powers and franchises of a public as well as of a private nature, and be subject to all the restrictions, disabilities and duties of each of Acquisition Corp. and the Company (collectively, the “Constituent Corporations”); and all the rights, privileges, powers and franchises of each of the Constituent Corporations, and all property, real, personal and mixed, and all debts due to any of the Constituent Corporations on whatever account, as well as all other things in action or belonging to each of the Constituent Corporations, shall be vested in the Surviving Corporation; and all property, rights, privileges, powers and franchises, and all and every other interest shall be thereafter as effectively the property of the Surviving Corporation as they were of the several and respective Constituent Corporations, and the title to any real estate vested by deed or otherwise in either of such Constituent Corporations shall not revert or be in any way impaired by the Merger; but all rights of creditors and all liens upon any property of any of the Constituent Corporations shall be preserved unimpaired, and all debts, liabilities and duties of the Constituent Corporations shall thenceforth attach to the Surviving Corporation, and may be enforced against it to the same extent as if said debts, liabilities and duties had been incurred or contracted by it.
Assets and Liabilities of Series All consideration received by the Trust for the issue or sale of Shares of a particular Series, together with all assets in which such consideration is invested or reinvested, all income, earnings, profits, and proceeds thereof (including any proceeds derived from the sale, exchange or liquidation of such assets, and any funds or payments derived from any reinvestment of such proceeds in whatever form the same may be), shall be held and accounted for separately from the assets of every other Series and are referred to as "assets belonging to" that Series. The assets belonging to a Series shall belong only to that Series for all purposes, and to no other Series, subject only to the rights of creditors of that Series. Any assets, income, earnings, profits, and proceeds thereof, funds, or payments which are not readily identifiable as belonging to any particular Series shall be allocated by the Trustees between and among one or more Series as the Trustees deem fair and equitable. Each such allocation shall be conclusive and binding upon the Shareholders of all Series for all purposes, and such assets, earnings, income, profits or funds, or payments and proceeds thereof shall be referred to as assets belonging to that Series. The assets belonging to a Series shall be so recorded upon the books of the Trust, and shall be held by the Trustees in trust for the benefit of the Shareholders of that Series. The assets belonging to a Series shall be charged with the liabilities of that Series and all expenses, costs, charges and reserves attributable to that Series, except that liabilities and expenses allocated solely to a particular Class shall be borne by that Class. Any general liabilities, expenses, costs, charges or reserves of the Trust which are not readily identifiable as belonging to any particular Series or Class shall be allocated and charged by the Trustees between or among any one or more of the Series or Classes in such manner as the Trustees deem fair and equitable. Each such allocation shall be conclusive and binding upon the Shareholders of all Series or Classes for all purposes. Without limiting the foregoing, but subject to the right of the Trustees to allocate general liabilities, expenses, costs, charges or reserves as herein provided, the debts, liabilities, obligations and expenses incurred, contracted for or otherwise existing with respect to a particular Series shall be enforceable against the assets of such Series only, and not against the assets of any other Series. Notice of this contractual limitation on liabilities among Series may, in the Trustees' discretion, be set forth in the certificate of trust of the Trust (whether originally or by amendment) as filed or to be filed in the Office of the Secretary of State of the State of Delaware pursuant to the Delaware Act, and upon the giving of such notice in the certificate of trust, the statutory provisions of Section 3804 of the Delaware Act relating to limitations on liabilities among Series (and the statutory effect under Section 3804 of setting forth such notice in the certificate of trust) shall become applicable to the Trust and each Series. Any person extending credit to, contracting with or having any claim against any Series may look only to the assets of that Series to satisfy or enforce any debt, with respect to that Series. No Shareholder or former Shareholder of any Series shall have a claim on or any right to any assets allocated or belonging to any other Series.
Liabilities of the Company Except as stated in this Section 8, the Company shall have no liability for damages of any kind arising out of or related to events, acts, rights or privileges contemplated in this Agreement. a. The liability of the Company for damages resulting in whole or in part from or arising in connection with the furnishing of Service under this Agreement including, but not limited to, mistakes, omissions, interruptions, delays, errors or other defects or misrepresentations shall not exceed an amount equal to the charges under this Agreement applicable to the specific call (or portion thereof) that was affected. No other liability shall attach to the Company. b. The Company shall not be liable for any failure of performance hereunder due to causes beyond its control, including, but not limited to: (1) acts of God, fires, flood or other catastrophes; (2) any law, order, regulation, directive, action or request of the United States Government, or any other government, including state and local governments having jurisdiction over the Company, or of any department, agency, bureau, corporation or other instrumentality of any one or more of said governments, or of any civil or military authority; or (3) national emergencies, insurrections, riots, wars or other labor difficulties. c. The Company shall not be liable for any act or omission of any other entity furnishing facilities, equipment, or services used by a Customer, with the Company's Services. In addition, the Company shall not be liable for any damages or losses due to the failure or negligence of any customer or due to the failure of customer provided equipment, facilities or services.
Excluded Assets and Liabilities Notwithstanding that this ------------------------------- Agreement relates to the purchase of capital stock from Seller by Purchaser, which results in the Company retaining any and all of its assets and liabilities, it is understood and agreed that Seller shall remove from the Company's premises prior to Closing and/or, as appropriate, remove from the Company's books and records, only those particular assets set forth on Schedule 1.3 hereto (the "EXCLUDED ASSETS"). Further, Seller shall assume any and all liabilities set forth on Schedule 1.3 hereto (the "EXCLUDED LIABILITIES"). Purchaser agrees that it shall cause Penta-Gen and the Company to execute any and all such bills of sale, assignments and/or agreements as may be necessary to transfer title to the Excluded Assets to Seller and to assign and/or transfer the Excluded Liabilities to Seller. The parties hereto further agree that no other assets of the Company, whether tangible or intangible, shall be removed from the Company's premises or from the Company's books and records except in the ordinary course of the Company's Business as provided herein from and after December 31, 1995 through the Closing Date.
Responsibilities of the Seller (a) Anything herein to the contrary notwithstanding, the Seller shall: (i) perform all of its obligations, if any, under the Contracts related to the Pool Receivables to the same extent as if interests in such Pool Receivables had not been transferred hereunder, and the exercise by the Administrator, the Purchaser Agents or the Purchasers of their respective rights hereunder shall not relieve the Seller from such obligations, and (ii) pay when due any taxes, including any sales taxes payable in connection with the Pool Receivables and their creation and satisfaction. The Administrator, the Purchaser Agents or any of the Purchasers shall not have any obligation or liability with respect to any Pool Asset, nor shall any of them be obligated to perform any of the obligations of the Seller, Servicer, WESCO or the Originators thereunder. (b) WESCO hereby irrevocably agrees that if at any time it shall cease to be the Servicer hereunder, it shall act (if the then-current Servicer so requests) as the data-processing agent of the Servicer and, in such capacity, WESCO shall conduct the data-processing functions of the administration of the Receivables and the Collections thereon in substantially the same way that WESCO conducted such data-processing functions while it acted as the Servicer.
LIABILITIES OF THE PARTIES 11.1. The Parties acknowledge that the Seller has a legitimate interest in ensuring prompt payment under the Contract. Should the Buyer breach the terms of payment stipulated in Clause 6 of the Contract and corresponding additional agreements, the Buyer shall pay to the Seller liquidated damages of 0.05% of the amount outstanding per full calendar day of the payment delay. Should the Buyer fail to make 100% payment of Goods cost within 2 days of the time stipulated for payment, the Seller has the right, at its sole discretion, to terminate the Contract by written notice to the Buyer and without further liability upon the Seller. Should the Buyer breach the terms of signing of additional agreements both on provisional price and on final one, and the terms of fulfillment of final settlement, indicated in cl.8.3, the Seller reserves the right at its sole discretion, not to nominate the future Goods lots with further postponement of the delivery or decrease of the whole amount under the current Contract and / or to terminate the Contract without further liability upon the Seller. The Seller and the Buyer are relieved from any responsibility for the partial or complete default of their obligations under the Supply Сontract, if they prove by the documents that proper fulfillment of their obligations became impossible due to shut-down, unscheduled repairs of JSC Naftan OR facilities or due to force-majeure occurrence. The Parties shall bear no responsibility for the failure to properly fulfil their obligations under the Contract by virtue of provisions of law or other laws and regulations (other documents binding for the Seller / consignor) currently in force that prevent the Contract fulfilment, adopted by the respective state authorities or organizations and Belarusian State Concern of Oil and Chemistry (Belneftekhim concern) in particular, in case they were adopted (published) after the Contract signing and directly affect its fulfillment. 11.2. The Parties acknowledge that the Seller has a legitimate interest in ensuring prompt and full loading of the stipulated quantity of Goods and that any failure of the Buyer to load the full quantity of Goods at the time specified in the Contract could cause the Seller significant loss and inconvenience. In particular, the Buyer understands that any such failure may cause the Seller to incur costs including, but not limited to, terminal storage charges, railway demurrage and / or infrastructure charges, and / or vessel demurrage in respect of other vessels. Accordingly, should the Buyer fail to load the full quantity of Goods at the time specified in the Contract: 11.2.1. the final price (Pr(F)) of the Goods shall be increased by 0,05% of the Contract value of the unlifted goods, per full calendar day of delay in lifting; and 11.2.2. the Seller shall have the right, at its sole discretion, to cancel the delivery of the unlifted Goods and / or to terminate the Contract without further liability upon the Seller. 11.2.3. Сompensates to the Seller losses suffered, including, but not limited to the following: charges of the Seller for storage of the Goods in the tanks of the terminal and in tanks of park of Ministry of Railways, charges of the Seller for using an infrastructure of the railways, other connected with this charges including demurrage claims of other vessels. 11.3. The Buyer shall exercise reasonable efforts to ensure that: 11.3.1. for vessels carrying persistent oil products as cargo, the vessel carries on board a certificate of insurance as described in the Civil Liability Convention for Oil Pollution Damage; and 11.3.2. the vessel has in place insurance cover for oil pollution no less in scope and amounts than available under the Rules of P&I Clubs entered into the International Group of P&I Clubs. 11.3.3. the vessel shall comply with the requirements of the International Ship and Port Facility Security Code and the relevant amendments to chapter XI of SOLAS (ISPS Code). 11.4. The Seller shall procure that the loading port/terminal/installation shall comply with the requirements of the International Ship and Port Facility Security Code and the relevant amendments to Chapter XI of SOLAS (ISPS Code).
RESPONSIBILITIES OF THE STATE 3.2.1 The State will identify a Project Manager for the Project. The Project Manager will be the sole point of contact between the Contractor and the State. The Project Manager will be the State’s representative authorized to communicate the State’s position and directions related to all contract work and to coordinate all change orders with the Commissioner of Buildings and General Services as deemed necessary. 3.2.2 If applicable, the State shall furnish all surveys describing the physical characteristics, legal limitations and utility locations for the site of the Project, and a legal description of the site. 3.2.3 Except as provided in Subparagraph 4.7.1, the State shall secure and pay for necessary approvals, easements, assessments and charges required for the construction, use or occupancy of permanent structures or for permanent changes in existing facilities. 3.2.4 Information or services under the State's control shall be furnished by the State with reasonable promptness to avoid delay in the orderly progress of the Work. 3.2.5 Unless otherwise provided in the Contract Documents, the Contractor will be furnished, free of charge, all copies of Drawings and Specifications reasonably necessary for the execution of the Work. 3.2.6 The State shall forward instructions to the Contractor through the Architect. 3.2.7 The foregoing are in addition to any other duties and responsibilities of the State enumerated in the Contract Documents including those responsibilities described in Articles 6, 9 and 11 of this agreement. 3.2.8 The State may utilize a Clerk-of-the-Works to provide inspection and monitoring work on behalf of the State. If a Clerk-of-the-Works is utilized, it is the responsibility of the Architect and the Contractor to review and understand the Clerk’s duties, responsibilities and limitations of authority. Upon request, the State shall provide a copy of the Clerk-of-the-Works contract to Architect and Contractor.
Litigation and Liabilities There are no civil, criminal or administrative actions, suits, claims, hearings, arbitrations, investigations or other proceedings (“Proceedings”) pending or, to the Knowledge of the Company, threatened against the Company or any of its Subsidiaries, except for those that would not, individually or in the aggregate, reasonably be expected to have a Company Material Adverse Effect. There are no obligations or liabilities of the Company or any of its Subsidiaries, whether or not accrued, contingent or otherwise other than (i) liabilities or obligations disclosed, reflected, reserved against or otherwise provided for in the consolidated balance sheet of the Company as of June 30, 2017, and the notes thereto set forth in the Company’s annual report on Form 10-K for the fiscal year ended June 30, 2017 (the “Company Balance Sheet”); (ii) liabilities or obligations incurred in the ordinary course of business consistent with past practice since June 30, 2017; (iii) liabilities or obligations arising out of the Transaction Documents (and which do not arise out of a breach by the Company or SpinCo of any representation or warranty in the Transaction Documents); or (iv) liabilities or obligations that would not, individually or in the aggregate, reasonably be expected to have a Company Material Adverse Effect. Neither the Company nor any of its Subsidiaries is a party to or subject to the provisions of any judgment, order, writ, injunction, decree, award, stipulation or settlement of or with any Governmental Entity that would, individually or in the aggregate, reasonably be expected to have, a Company Material Adverse Effect (except to the extent expressly consented to by Parent pursuant to Section 5.06).
Respective Liabilities of the Company and the Master Servicer The Company and the Master Servicer shall each be liable in accordance herewith only to the extent of the obligations specifically and respectively imposed upon and undertaken by the Company and the Master Servicer herein. By way of illustration and not limitation, the Company is not liable for the servicing and administration of the Mortgage Loans, nor is it obligated by Section 7.01 or Section 10.01 to assume any obligations of the Master Servicer or to appoint a designee to assume such obligations, nor is it liable for any other obligation hereunder that it may, but is not obligated to, assume unless it elects to assume such obligation in accordance herewith.
Responsibilities of the Company 3.3.1 The Company shall provide participants of CopyTrade with a complete package of services according to the Customer Agreement. The Company is liable for proper performance of technological solutions according to the Customer Agreement. 3.3.2 The Company bears no liability to participants of CopyTrade for lost profit or losses, which may directly or indirectly occur as a result of trading operations performed or not performed by an Investor or a Trader. 3.3.3 The Company bears no liability to participants of CopyTrade for lost profit or losses, which may be directly or indirectly occur as a result of their ignorance of regulatory documents or cooperation scheme. 3.3.4 The Company doesn’t evaluate Traders’ professional skills and suitability not on a single stage of their activity and bears no responsibility to Investors for any losses or lost profit they may incur. 3.3.5 The Company is not liable for:
