Common use of Background Checks for Installation Access Clause in Contracts

Background Checks for Installation Access. Contractor and all associated sub- contractors employees shall comply with adjudication standards and procedures using the National Crime Information Center Interstate Identification Index (NCIC-III) and Terrorist Screening Database (TSDB), applicable installation, facility and area commander installation/facility access and local security policies and procedures. Installation personnel will conduct background checks on all visitors 18 years of age and older to determine if the person requesting unescorted access presents a potential threat to the good order, discipline, or health and safety on the installation. All access applicants will provide a valid and original form of ID (State driver’s license, passport, and so forth, which complies with Public Law 109-13 (The REAL ID Act of 2005)). Installation will check applicant’s background through NCIC-III and TSDB to identify wanted persons, known or appropriately suspected terrorists (KST), missing persons, foreign fugitives, wanted persons, gang affiliations, protection orders, immigration violators, identity theft, supervised releases, violent persons, and the National Sex Offender Registry. Failure to provide requested information will result in the denial of an authorized access pass (or equivalent) and denial of entry. Delays in gaining access to a facility shall not be a valid basis for delay charges.

Background Checks for Installation Access. Contractor and all associated sub- sub-contractors employees shall comply with adjudication standards and procedures using the National Crime Information Center Interstate Identification Index (NCIC-III) and Terrorist Screening Database (TSDB), applicable installation, facility and area commander installation/facility access and local security policies and procedures. Installation personnel will conduct background checks on all visitors 18 years of age and older to determine if the person requesting unescorted access presents a potential threat to the good order, discipline, or health and safety on the installation. All access applicants will provide a valid and original form of ID (State driver’s license, passport, and so forth, which complies with Public Law 109-13 (The REAL ID Act of 2005)). Installation will check applicant’s background through NCIC-III and TSDB to identify wanted persons, known or appropriately suspected terrorists (KST), missing persons, foreign fugitives, wanted persons, gang affiliations, protection orders, immigration violators, identity theft, supervised releases, violent persons, and the National Sex Offender Registry. Failure to provide requested information will result in the denial of an authorized access pass (or equivalent) and denial of entry. Delays in gaining access to a facility shall not be a valid basis for delay charges.