Procedure for taking possession The Promoter, upon obtaining the occupancy certificate* from the competent authority shall offer in writing the possession of the [Apartment/Plot], to the Allottee in terms of this Agreement to be taken within two months from the date of issue of occupancy certificate. [Provided that, in the absence of local law, the conveyance deed in favour of the allottee shall be carried out by the promoter within 3 months from the date of issue of occupancy certificate]. The Promoter agrees and undertakes to indemnify the Allottee in case of failure of fulfillment of any of the provisions, formalities, documentation on part of the Promoter. The Allottee, after taking possession, agree(s) to pay the maintenance charges as determined by the Promoter/association of allottees, as the case may be after the issuance of the completion certificate for the project. The promoter shall hand over the occupancy certificate of the apartment/ plot, as the case may be, to the allottee at the time of conveyance of the same.
TERM; POSSESSION The Term of this Lease shall commence on the Commencement Date and shall end on the Expiration Date, unless extended or sooner terminated in accordance with this Lease. If Landlord is delayed in delivering possession of all or any portion of the Premises to Tenant as of the Commencement Date, Tenant will take possession on the date Landlord delivers possession, which date will then become the Commencement Date (and the Expiration Date will be extended so that the length of the Term remains unaffected by such delay). Subject to this Section 4, Landlord shall not be liable for any loss or damage to Tenant resulting from any delay in delivering possession due to the holdover of any existing tenant or other circumstances outside of Landlord’s reasonable control. In the event that the Tenant Improvements are not Substantially Completed within one hundred (100) days following the date that Landlord receives a building permit to commence the Tenant Improvements in the Premises (the “Delivery Date”), subject to Tenant Delay or force majeure (in the event of either, the Delivery Date shall be extended by one (1) day for each one (1) day of Tenant Delay or force majeure), Landlord shall credit Tenant against Minimum Annual Rent due under this Lease an amount equal to the holdover portion of Tenant’s existing rental obligations under Tenant’s existing Lease actually incurred by Tenant following the Delivery Date, which Tenant represents to Landlord is equal to $17,031.13 per month. Notwithstanding anything in this Lease to the contrary, if the Commencement Date has not occurred on or before one hundred ninety (190) days following the date that Landlord receives a building permit for the Tenant Improvements, for any reason other than Tenant Delay or force majeure, then Tenant shall have the right to terminate this Lease by written notice to Landlord, as Tenant’s sole and exclusive remedy with respect to such delay, except as provided above, subject to Tenant giving Landlord thirty (30) days’ advance written notice of its intention to terminate this Lease if Substantial Completion shall not occur within such thirty (30) day period, in which event all amounts prepaid or deposited by Tenant hereunder shall be promptly returned to Tenant.
Quiet Possession Upon Tenant paying the rent reserved hereunder and observing and performing all of the covenants, conditions and provisions on Tenant's part to be observed and performed hereunder, Tenant shall have quiet possession of the Premises for the entire term hereof, subject to all the provisions of this Lease.
DELAY IN POSSESSION If for any reason Lessor cannot deliver possession of the Premises to Lessee by the Early Possession Date, if one is specified in Paragraph 1.4, or if no Early Possession Date is specified, by the Commencement Date, Lessor shall not be subject to any liability therefor, nor shall such failure affect the validity of this Lease, or the obligations of Lessee hereunder, or extend the term hereof, but in such case, Lessee shall not, except as otherwise provided herein, be obligated to pay rent or perform any other obligation of Lessee under the terms of this Lease until Lessor delivers possession of the Premises to Lessee. If possession of the Premises is not delivered to Lessee within sixty (60) days after the Commencement Date, Lessee may, at its option, by notice in writing to Lessor within ten (10) days after the end of said sixty (60) day period, cancel this Lease, in which event the parties shall be discharged from all obligations hereunder; provided further, however, that if such written notice of Lessee is not received by Lessor within said ten (10) day period, Lessee's right to cancel this Lease hereunder shall terminate and be of no further force or effect. Except as may be otherwise provided, and regardless of when the Original Term actually commences, if possession is not tendered to Lessee when required by this Lease and Lessee does not terminate this Lease, as aforesaid, the period free of the obligation to pay Base Rent, if any, that Lessee would otherwise have enjoyed shall run from the date of delivery of possession and continue for a period equal to the period during which the Lessee would have otherwise enjoyed under the terms hereof, but minus any days of delay caused by the acts, changes or omissions of Lessee.
Complete Taking If at any time during the Fee Term title to or temporary use of the entire Project should become vested in a public or quasi-public authority by virtue of the exercise of a taking by condemnation, inverse condemnation or the right of eminent domain, or by voluntary transfer under threat of such taking, or in the event that title to a portion of the Project shall be taken rendering continued occupancy of the Project commercially infeasible in the judgment of the Sponsor, the Sponsor shall have the option to terminate this Fee Agreement as of the time of vesting of title by sending written notice to the County within a reasonable period of time following such vesting.
FAILURE TO GIVE POSSESSION If Owner is unable to give possession of the demised premises on the date of the commencement of the term hereof, because of the holding-over or retention of possession of any tenant, undertenant or occupants or if the demised premises are located in a building being constructed, because such building has not been sufficiently completed to make the premises ready for occupancy or because of the fact that a certificate of occupancy has not been procured or for any other reason, Owner shall not be subject to any liability for failure to give possession on said date and the validity of the lease shall not be impaired under such circumstances, nor shall the same be construed in any wise to extend the term of this lease, but the rent payable hereunder shall be abated (provided Tenant is not responsible for Owner's inability to obtain possession) until after Owner shall have given Tenant written notice that the premises are substantially ready for Tenant's occupancy. If permission is given to Tenant to enter into the possession of the demised premises or to occupy premises other than the demised premises prior to the date specified as the commencement of the term of this lease, Tenant covenants and agrees that such occupancy shall be deemed to be under all the terms, covenants, conditions and provisions of this lease, except as to the covenant to pay rent. The provisions of this article are intended to constitute "an express provision to the contrary" within the meaning of Section 223-a of the New York Real Property Law. No Waiver:
Possession and Control The Grantor has exclusive possession and control of its Equipment and Inventory.
POSSESSION OF PREMISES Tenant shall not be entitled to possession of the premises designated for lease until the security deposit and first month’s rent (or prorated portion thereof), less any applicable promotional discount, is paid in full and the premises designated for lease is vacated by the prior tenant.
Peaceful Possession The Authority hereby warrants that: a) The Project Site has been acquired through the due process of law and belongs to and is vested with the Authority and that the Authority has full powers to hold, dispose of and deal with the same consistent, inter alia, with the provisions of this Agreement. b) In the event the Developer is obstructed by any Person claiming any right, title or interest in or over the Project Site or any part thereof, or in the event of any enforcement action including any attachment, distrait, appointment of receiver or liquidator being initiated by any Person claiming to have any interest in/charge or the Project Site or any part thereof, the Authority shall, if called upon by the Developer, defend such claims and proceedings and also keep the Developer indemnified against any consequential loss or damages which the Developer may suffer, on account of any such right, title, interest or charge.
Possession Tenant has examined the condition of the Premises and by taking possession acknowledges that they have accepted the Premises in good order and in its current condition except as herein otherwise stated. Failure of the Landlord to deliver possession of the Premises at the start of the Lease Term to the Tenant shall terminate this Agreement at the option of the Tenant. Furthermore, under such failure to deliver possession by the Landlord, and if the Tenant cancels this Agreement, the Security Deposit (if any) shall be returned to the Tenant along with any other pre-paid rent, fees, including if the Tenant paid a fee during the application process before the execution of this Agreement.
