Lease Year Lease Year" means each consecutive twelve-month period beginning with the Commencement Date, except that if the Commencement Date is not the first day of a calendar month, then the first Lease Year shall be the period from the Commencement Date through the final day of the twelve months after the first day of the following month, and each subsequent Lease Year shall be the twelve months following the prior Lease Year.
Base Year Calendar year 2000.
Lease Commencement Date The earlier to occur of (i) the date upon which Tenant first commences to conduct business in the Premises, and (ii) the later to occur of (A) November 1, 2018 and (B) the date upon which the Premises are Ready for Occupancy (as that term is defined in Section 5.1 of the Tenant Work Letter attached hereto as Exhibit B (the “Tenant Work Letter”)).
Commencement Date Delay Except as otherwise provided in the Lease, Delivery of the Premises shall occur when Landlord’s Work has been Substantially Completed, except to the extent that completion of Landlord’s Work shall have been actually delayed by any one or more of the following causes (“Tenant Delay”):
Rent Commencement Date The "Rent Commencement Date" shall be the date that Tenant first uses the Premises or any portion thereof for any purpose permitted under this lease. In the event this lease pertains to a building or building interior finish to be constructed, the "Rent Commencement Date" shall be the date upon which the buildings and other improvements erected and to be erected upon the premises shall have been substantially completed in accordance with the plans and specifications described on Exhibit "C" attached hereto and incorporated herein by reference, provided however, that if Landlord shall be delayed in such substantial completion as a result of: (i) Tenant's failure to agree to plans, specifications, and cost estimates, within a reasonable period of time; (ii) Tenant's request for materials, finishes or installations other than Landlord's standard; (iii) Tenant's changes in plans: the commencement date and the payment of rent hereunder shall be accelerated by the number of days of such delay, and provided further that if Landlord cannot substantially complete the premises as a result of any events (i) through (iii) above, Landlord may as its election complete so much of Landlord's work as may be practical under the circumstances and, by written notice to Tenant, establish the commencement date as the date of such partial completion, subject to any applicable accelerations due to delays resulting from events (i) through (iii) above. Taking possession by Tenant shall be deemed conclusively to establish that said buildings and other improvements have been completed in accordance with the plans and specifications and that the premises are in good and satisfactory condition, as of when possession was so taken. Tenant acknowledges that no representations as to the repair of the premises have been made by Landlord, unless such are expressly set forth in the lease. After such "Rent Commencement Date" Tenant shall, upon demand, execute and deliver to Landlord a letter of acceptance of delivery of the premises. In the event of any dispute as to substantial completion of work performed, execute or required to be performed by Landlord, the certificate of Landlord's architect or general contractor shall be conclusive.
Annual Fixed Rent Tenant covenants and agrees to pay the Annual Fixed Rent in Section 1.1 to Landlord in advance in equal monthly installments commencing on the Term Commencement Date (if not the first day of a month) and thereafter on the first day of each calendar month during the Term. All payments shall be due without billing or demand and without deduction, setoff or counterclaim, except as expressly set forth in this Lease. Tenant shall make payment for any portion of a month at the beginning or end of the Term. All payments shall be payable to Landlord at Landlord’s address, as specified in Section 1.1, or to such other entities at such other places as Landlord may from time to time designate. Without limiting the foregoing, except as expressly set forth in this Lease, Tenant’s obligation so to pay Rent (as hereinafter defined) shall not be discharged or otherwise affected by any law or regulation now or hereafter applicable to the Premises, or any other restriction on Tenant’s use, or any casualty or taking, or any failure by Landlord to perform any covenant contained herein, or any other occurrence; and, except as expressly set forth in this Lease, Tenant waives all rights now or hereafter existing to terminate or cancel this Lease or quit or surrender the Premises or any part thereof, or to assert any defense in the nature of constructive eviction to any action seeking to recover Rent. The foregoing notwithstanding, if Landlord fails for any reason within Landlord’s control to provide any service to be supplied by Landlord under the Lease which is necessary for Tenant’s reasonable use of the Premises (such as HVAC, elevator service, electricity, water, or structural repairs), and Tenant is unable to use the Premises on account of such failure, Tenant shall be entitled to a proportional abatement of Annual Fixed Rent and Additional Charges for Operating Expenses and Taxes based on the portion of the Premises which cannot be used by Tenant. This abatement shall begin on the fourth (4th) consecutive Business Day from Tenant’s written notice to Landlord of the failure. The abatement shall end when the services are restored sufficiently to permit use of the Premises.
Commencement Date Landlord shall deliver possession of the Premises to Tenant on the date (the “Delivery Date”) that Landlord’s Market Ready Improvements described on EXHIBIT C attached hereto and the Tenant Improvements to be completed by Landlord pursuant to the Work Letter Agreement attached hereto as EXHIBIT D are substantially completed. For purposes of this Lease, Landlord’s Market Ready Improvements and the Tenant Improvements shall be deemed to be “substantially completed” when Landlord’s Market Ready Improvements and the Tenant Improvements have been completed in accordance with any plans and specifications therefor, subject only to the completion of any minor punch-list items, and the City of Sunnyvale has completed a final inspection of such work and issued a temporary certificate of occupancy or other written approvals permitting legal occupancy of the Premises. The term of this Lease (“Term”) shall be seventy-six (76) months commencing on the date (the “Commencement Date”) which is thirty (30) days from the Delivery Date. If the Delivery Date does not occur on or before May 1, 2018, for any reason other than (i) ArcTec’s failure to complete the Final Plans and Specifications (as such term is defined in the Work Letter attached as EXHIBIT D) and submit such Final Plans and Specifications (and any other documentation required by the City of Sunnyvale for the issuance of a building permit for the Tenant Improvements) to Landlord’s general contractor by January 8, 2018, (ii) the City requiring Landlord to stop construction due to its commencement of the Tenant Improvements before the permits therefor were issued or (iii) delays caused by the acts or omission of Tenant, as defined in Paragraph 3(c) below, then the date Tenant is otherwise obliged to commence payment of Rent shall be delayed by one (1) additional day for each day the Delivery Date is delayed beyond such date.
Sublease Rent Limitation Anything contained in this Lease to the contrary notwithstanding, Lessee shall not sublet the Leased Property on any basis such that the rental to be paid by the sublessee thereunder would be based, in whole or in part, on either (a) the income or profits derived by the business activities of the sublessee, or (b) any other formula such that any portion of the Rent would fail to qualify as “rents from real property” within the meaning of Section 856(d) of the Code, or any similar or successor provision thereto.
Maximum Annual Operating Expense Limit The Maximum Annual Operating Expense Limit with respect to each Fund shall be the amount specified in Schedule A based on a percentage of the average daily net assets of each Fund.
Annual Base Rent Except as otherwise provided in this Lease, in the event of a default by Landlord, Tenant shall be entitled to any remedies available at law or in equity except for the right to terminate or rescind the Lease. It is expressly understood and agreed to between the parties that except as specifically provided in this Lease, Tenant expressly, knowingly, and voluntarily waives any right, claim, or remedy otherwise available to Tenant to terminate or rescind this Lease as a result of Landlord's default as to any covenant or agreement contained in this Lease or as a result of the breach of any promise or inducement allegedly made on behalf of Landlord, whether in this Lease or elsewhere. No act or omission of Landlord or its agents shall constitute an actual or constructive eviction of Tenant unless Landlord shall have first received written notice of Tenant's claim and shall have failed to cure it after having been afforded a reasonable time to do so, which in no event shall be less than thirty (30) days. Notwithstanding anything in this Lease to the contrary, Landlord shall never be liable to Tenant in the event of a default by Landlord or otherwise under any provision of this Lease for any loss of business or profits or other consequential damages or for punitive or special damages of any kind. None of Landlord's officers, members, managers, employees, agents, directors, shareholders, or partners shall ever have any personal liability to Tenant under or in connection with this Lease. Tenant shall look solely to Landlord's estate and interest in the Office Center for the satisfaction of any right or remedy of Tenant under this Lease, or for the collection of any judgment (or other judicial process) requiring the payment of money by Landlord, it being intended that there will be absolutely no personal liability on the part of Landlord, and no other property or assets of Landlord or its principals shall be subject to levy, execution, or other enforcement procedure for the satisfaction of Tenant's rights or remedies under this Lease, the relationship of Landlord and Tenant under this Lease, Tenant's use and occupancy of the Premises, or any other liability of Landlord to Tenant of whatever kind or nature, this exculpation of liability to be absolute and without exception whatsoever.
