Breach of Obligations The Parties acknowledge that a breach of any of the obligations contained herein would result in injuries. The Parties further acknowledge that the amount of the liquidated damages or the method of calculating the liquidated damages specified in this Agreement is a genuine and reasonable pre-estimate of the damages that may be suffered by the non-defaulting party in each case specified under this Agreement.
Conditions of Parties Obligations 7.1 Conditions of Investor's Obligations at the Closing. The --------------------------------------------------- obligation of Investor to purchase and pay for the Investor Stock is subject to the fulfillment prior to or on the Closing Date of the following conditions, any of which may be waived in whole or in part by Investor:
Breach of Contract Claims [Option (Include if University prefers an abbreviated Breach of Contract Claims provision): To the extent that Chapter 2260, Texas Government Code, is applicable to this Agreement and is not preempted by other applicable law, the dispute resolution process provided for in Chapter 2260 and the related rules adopted by the Texas Attorney General pursuant to Chapter 2260, will be used by University and Contractor to attempt to resolve any claim for breach of contract made by Contractor that cannot be resolved in the ordinary course of business. The chief business officer of University will examine Contractor's claim and any counterclaim and negotiate with Contractor in an effort to resolve the claims. The parties specifically agree (i) neither execution of this Agreement by University nor any other conduct, action or inaction of any representative of University relating to this Agreement constitutes or is intended to constitute a waiver of University’s or the state's sovereign immunity to suit; and (ii) University has not waived its right to seek redress in the courts.]
19.1 To the extent that Chapter 2260, Texas Government Code, as it may be amended from time to time (Chapter 2260), is applicable to this Agreement and is not preempted by other Applicable Laws, the dispute resolution process provided for in Chapter 2260 will be used, as further described herein, by University and Contractor to attempt to resolve any claim for breach of contract made by Contractor:
12.19.1.1 Contractor’s claims for breach of this Agreement that the parties cannot resolve pursuant to other provisions of this Agreement or in the ordinary course of business will be submitted to the negotiation process provided in subchapter B of Chapter 2260. To initiate the process, Contractor will submit written notice, as required by subchapter B of Chapter 2260, to University in accordance with the notice provisions in this Agreement. Contractor's notice will specifically state that the provisions of subchapter B of Chapter 2260 are being invoked, the date and nature of the event giving rise to the claim, the specific contract provision that University allegedly breached, the amount of damages Contractor seeks, and the method used to calculate the damages. Compliance by Contractor with subchapter B of Chapter 2260 is a required prerequisite to Contractor's filing of a contested case proceeding under subchapter C of Chapter 2260. The chief business officer of University, or another officer of University as may be designated from time to time by University by written notice to Contractor in accordance with the notice provisions in this Agreement, will examine Contractor's claim and any counterclaim and negotiate with Contractor in an effort to resolve the claims.
12.19.1.2 If the parties are unable to resolve their disputes under Section 12.19.1.1, the contested case process provided in subchapter C of Chapter 2260 is Contractor’s sole and exclusive process for seeking a remedy for any and all of Contractor's claims for breach of this Agreement by University.
12.19.1.3 Compliance with the contested case process provided in subchapter C of Chapter 2260 is a required prerequisite to seeking consent to xxx from the Legislature under Chapter 107,
Repurchase Obligation for Defective Documentation and for Breach of Representation and Warranty It is understood and agreed that the representations and warranties set forth in Section 5 shall survive the sale of the Mortgage Loans to the Purchaser and shall inure to the benefit of the Purchaser and any assignee, transferee or designee of the Purchaser, including the Trustee for the benefit of holders of the Mortgage Pass-Through Certificates evidencing an interest in all or a portion of the Mortgage Loans, notwithstanding any restrictive or qualified endorsement on any Mortgage Note or Assignment or the examination or lack of examination of any Mortgage File. With respect to the representations and warranties contained herein that are made to the knowledge or the best knowledge of the Seller, or as to which the Seller has no knowledge, if it is discovered that the substance of any such representation and warranty is inaccurate and the inaccuracy materially and adversely affects the value of the related Mortgage Loan, or the interest therein of the Purchaser or the Purchaser’s assignee, designee or transferee, then notwithstanding the Seller’s lack of knowledge with respect to the substance of such representation and warranty being inaccurate at the time the representation and warranty was made, such inaccuracy shall be deemed a breach of the applicable representation and warranty and the Seller shall take such action described in the following paragraphs of this Section 6 in respect of such Mortgage Loan. Upon discovery by either the Seller or the Purchaser of a breach of any of the foregoing representations and warranties made by the Seller that materially and adversely affects the value of the Mortgage Loans or the interest of the Purchaser (or which materially and adversely affects the interests of the Purchaser in the related Mortgage Loan in the case of a representation and warranty relating to a particular Mortgage Loan), the party discovering such breach shall give prompt written notice to the other. Within 90 days of the earlier of either discovery by or notice to the Seller of any breach of a representation or warranty made by the Seller that materially and adversely affects the value of a Mortgage Loan or the Mortgage Loans or the interest therein of the Purchaser, the Seller shall use its best efforts promptly to cure such breach in all material respects and, if such breach cannot be cured, the Seller shall, at the Purchaser’s option, repurchase such Mortgage Loan at the Purchase Price. The Seller may, at the request of the Purchaser and assuming the Seller has a Qualified Substitute Mortgage Loan, rather than repurchase a deficient Mortgage Loan as provided above, remove such Mortgage Loan and substitute in its place a Qualified Substitute Mortgage Loan or Loans. If the Seller does not provide a Qualified Substitute Mortgage Loan or Loans, it shall repurchase the deficient Mortgage Loan. Any repurchase of a Mortgage Loan(s) pursuant to the foregoing provisions of this Section 6 shall occur on a date designated by the Purchaser and shall be accomplished by deposit in accordance with Section 2.03 of the Pooling and Servicing Agreement. Any repurchase or substitution required by this Section shall be made in a manner consistent with Section 2.03 of the Pooling and Servicing Agreement. At the time of substitution or repurchase by the Seller of any deficient Mortgage Loan, the Purchaser and the Seller shall arrange for the reassignment of the repurchased or substituted Mortgage Loan to the Seller and the delivery to the Seller of any documents held by the Trustee relating to the deficient or repurchased Mortgage Loan. In the event the Purchase Price is deposited in the Collection Account. The Seller shall, simultaneously with such deposit, give written notice to the Purchaser that such deposit has taken place. Upon such repurchase, the Mortgage Loan Schedule shall be amended to reflect the withdrawal of the repurchased Mortgage Loan from this Agreement. As to any Deleted Mortgage Loan for which the Seller substitutes a Qualified Substitute Mortgage Loan or Loans, the Seller shall effect such substitution by delivering to the Purchaser or its designee for such Qualified Substitute Mortgage Loan or Loans the Mortgage Note, the Mortgage, the Assignment and such other documents and agreements as are required by the Pooling and Servicing Agreement, with the Mortgage Note endorsed as required therein. The Seller shall remit for deposit in the Collection Account the Monthly Payment due on such Qualified Substitute Mortgage Loan or Loans in the month following the date of such substitution. Monthly payments due with respect to Qualified Substitute Mortgage Loans in the month of substitution will be retained by the Seller. For the month of substitution, distributions to the Purchaser will include the Monthly Payment due on such Deleted Mortgage Loan in the month of substitution, and the Seller shall thereafter be entitled to retain all amounts subsequently received by the Seller in respect of such Deleted Mortgage Loan. Upon such substitution, the Qualified Substitute Mortgage Loans shall be subject to the terms of this Agreement in all respects, and the Seller shall be deemed to have made with respect to such Qualified Substitute Mortgage Loan or Loans as of the date of substitution, the covenants, representations and warranties set forth in Section 5. It is understood and agreed that the representations and warranties set forth in Section 5 shall survive delivery of the respective Mortgage Files to the Trustee on behalf of the Purchaser. It is understood and agreed that (i) the obligations of the Seller set forth in this Section 6 to cure, repurchase and substitute for a defective Mortgage Loan and (ii) the obligations of the Seller as provided in the next sentence constitute the sole remedies of the Purchaser respecting a missing or defective document or a breach of the representations and warranties contained in Section 5. The Seller shall indemnify the Purchaser and hold it harmless against any losses, damages, penalties, fines, forfeitures, reasonable and necessary legal fees and related costs, judgments, and other costs and expenses resulting from any claim, demand, defense or assertion based on or grounded upon, or resulting from, a breach of the representations and warranties contained in Sections 5(a), (c), (d) and (e) this Agreement.
Obligations of the Contractor (i) Subject to and on the terms and conditions of this Agreement, the Contractor shall undertake the survey, investigation, design, engineering, procurement, construction, and maintenance of the Project Highway and observe, fulfil, comply with and perform all its obligations set out in this Agreement or arising hereunder.
(ii) The Contractor shall comply with all Applicable Laws and Applicable Permits (including renewals as required) in the performance of its obligations under this Agreement.
(iii) Subject to the provisions of Clauses 4.1 (i) and 4.1 (ii), the Contractor shall discharge its obligations in accordance with Good Industry Practice and as a reasonable and prudent person.
(iv) The Contractor shall remedy any and all loss, defects, or damage to the Project Highway from the Appointed Date until the end of the Construction Period at the Contractor’s cost, save and except to the extent that any such loss, defect, or damage shall have arisen from any wilful default or neglect of the Authority.
(v) The Contractor shall remedy any and all loss, defect or damage to the Project Highway during the Defects Liability Period at the Contractor’s cost to the extent that such loss, defect or damage shall have arisen out of the reasons specified in Clause 17.3.
(vi) The Contractor shall remedy any and all loss or damage to the Project Highway during the Maintenance Period at the Contractor’s cost, including those stated in Clause 14.1 (ii), save and except to the extent that any such loss or damage shall have arisen on account of any wilful default or neglect of the Authority or on account of a Force Majeure Event.
(vii) The Contractor shall, at its own cost and expense, in addition to and not in derogation of its obligations elsewhere set out in this Agreement:
(a) make, or cause to be made, necessary applications to the relevant Government Instrumentalities with such particulars and details as may be required for obtaining Applicable Permits set forth in Schedule-F and obtain and keep in force and effect such Applicable Permits in conformity with the Applicable Laws;
(b) procure, as required, the appropriate proprietary rights, licences, agreements and permissions for Materials, methods, processes and systems used or incorporated into the Project Highway;
(c) make reasonable efforts to maintain harmony and good industrial relations among the personnel employed byit or its Sub-contractors in connection with the performance of its obligations under this Agreement;
(d) ensure and procure that its Sub-contractors comply with all Applicable Permits and Applicable Laws in the performance by them of any of the Contractor’s obligations under this Agreement;
(e) not do or omit to do any act, deed or thing which may in any manner violate any provisions of this Agreement;
(f) support, cooperate with and facilitate the Authority in the implementation and operation of the Project in accordance with the provisions of this Agreement;
(g) ensure that the Contractor and its Sub-contractors comply with the safety and welfare measures for labour in accordance with the Applicable Laws and Good Industry Practice;
(h) keep, on Site, a copy of this Agreement, publications named in this Agreement, the Drawings, Documents relating to the Project, and Change of Scope orders and other communications given under this Agreement. The Authority’s Engineer and its authorised personnel shall have the right of access to all these documents at all reasonable times;
(i) cooperate with other contractors employed by the Authority and personnel of any public authority; and
(j) not interfere unnecessarily or improperly with the convenience of the public, or the access to and use and occupation of all roads and footpaths, irrespective of whether they are public or in the possession of the Authority or of others.
(viii) The Contractor shall undertake all necessary superintendence to plan, arrange, direct, manage, inspect and test the Works. The Contractor shall provide all necessary superintendence of the Works for the proper fulfilling of the Contractor's obligations under the Agreement. Such superintendence shall be given by competent person having adequate knowledge of the operations to be carried out (including the methods and techniques required, the hazards likely to be encountered and methods of preventing accidents) for the satisfactory and safe execution of the Works.
(ix) The Contractor shall obtain and maintain a project related bank account operational at site where all transactions related to the payment of work will be done. The Contractor shall submit a monthly account statement and a detailed report on utilization of funds transferred to this project related bank account to Authority’s Engineer. Notwithstanding anything contrary to this agreement, the authority, in the interest and to ensure timely completion of the work, reserves the right to audit such bank accounts to ensure that there is no diversion of funds from this project specific account to any other project being implemented by the Contractor.
(x) The Contractor shall provide the documents of the Contractor specified in the Agreement, and all Contractors' personnel; Goods, consumables and other things and services, whether of a temporary or permanent nature, required in and for the execution, completion of Works and remedying defects.
(xi) The Contractor shall perform the Works in conformity with the Project requirements and other requirements and standards prescribed under or pursuant to the Agreement.
(xii) The Contractor shall carry out such work incidental and contingent to the original Scope of the Project to comply with Good Industry Practices.
(xiii) The Contractor shall maintain required staff and necessary Contractor’s equipment and materials within the reach of the Site during the Defects Liability Period so that any defects arising are promptly attended.
Failure to Perform Obligations In the event Business Associate fails to perform its obligations under this Agreement, Covered Entity may immediately discontinue providing PHI to Business Associate. Covered Entity may also, at its option, require Business Associate to submit to a plan of compliance, including monitoring by Covered Entity and reporting by Business Associate, as Covered Entity in its sole discretion determines to be necessary to maintain compliance with this Agreement and applicable law.
Breach of other obligations any Security Party commits any breach of or omits to observe any of its obligations or undertakings expressed to be assumed by it under any of the Security Documents (other than those referred to in clauses 10.1.1 and 10.1.2 above) unless such breach or omission, in the opinion of the Agent (following consultation with the Banks) is capable of remedy, in which case the same shall constitute an Event of Default if it has not been remedied within fifteen (15) days of the occurrence thereof; or
Obligations of the Licensee 5.1.1. The Licensee’s Responsibilities and Duties shall include the following, in addition to and without prejudice to other obligations under this Agreement:
a. to obtain due permits, necessary approvals, clearances and sanctions from Maha-Metro and all other competent authorities for all activities or infrastructure facilities including interior decoration, power, water supply, drainage & sewerage, telecommunication, etc.;
b. to comply and observe at all times with all Applicable Permits, approvals and Applicable Laws in the performance of its obligations under this Agreement including those being performed by any of its contractors;
c. to develop, operate and maintain the Licensed Area at all times in conformity with this Agreement;
d. to furnish Maha-Metro with the “As built” Drawings of the Licensed Space(s) within the Moratorium Period;
e. to ensure that no structural damage is caused to the existing buildings and other permanent structures at the station as a result of his activities or any of its agents, contractors etc.;
f. to take all reasonable steps to protect the environment (both on and off the property business space) and to limit damage and nuisance to people and property resulting from construction and operations, within guidelines specified as per Applicable Laws and Applicable Permits;
g. to duly supervise, monitor and control the activities of contractors, agents, etc., if any, under their respective License Agreements as may be necessary;
h. to take all responsible precautions for the prevention of accidents on or about the property business space and provide all reasonable assistance and emergency medical aid to accident victims;
i. not to permit any person, claiming through or under the Licensee, to create or place any encumbrance or security interest over whole or any part of the Licensed premises and/or other installed assets, or on any rights of the Licensee therein or under this Agreement, save and except as expressly permitted in this Agreement;
j. to keep the Licensed Space free from all unnecessary obstruction during execution of works and store the equipment or surplus materials, dispose of such equipment or surplus materials in a manner that causes least inconvenience to the Xxxxx Xxxxxxx, metro commuters or Maha-Metro’s activities.
k. at all times, to afford access to the Licensed Property Business Space to the authorised representatives of Maha-Metro, other persons duly authorised by any Governmental Agency having jurisdiction over the business of Licensed Property Business Space, to inspect the Licensed Property Business Space and to investigate any matter within their authority and upon reasonable notice; and
l. use non-combustable material in the allotted space for creation/erection/installation of any kind of furniture, fixtures and or partitions within the space. Use of combustable material within the property business space shall not be permitted under any circumstances.
m. to comply with the divestment requirements and hand over the Licensed Property Business Space to Maha-Metro upon Termination of the Agreement;
5.1.2. The Licensee shall be solely and primarily responsible to Maha-Metro for observance of all the provisions of this License Agreement on behalf of its employees and representatives and agents and any person acting under or for and on behalf of the Licensee, contractor (s) appointed for the Licensed Space as fully as if they were the acts or defaults of the Licensee, its agents or employees.
Parties Obligations The Parties’ obligations under this Agreement will continue notwithstanding the existence of a Material Change.
Liability for Specific Obligations The Administrator will be liable only for its specific obligations under this Agreement. All other liability is expressly waived and released as a condition of, and consideration for, the execution of this Agreement by the Administrator. The Administrator will be liable for its willful misconduct, bad faith or negligence in performing its obligations under this Agreement.
