NATIONAL JOINT COUNCIL AGREEMENTS 22.1 Subject to the National Joint Council By-Laws, agreements concluded by the National Joint Council of the Public Service on items which may be included in a collective agreement, and which the parties to this agreement have endorsed after December 6, 1978, will form part of this collective agreement, subject to the Federal Public Sector Labour Relations Act (FPSLRA) and any legislation by Parliament that has been or may be, as the case may be, established pursuant to any Act prescribed in Section 113(b) of the PSLRA.
22.2 NJC items which may be included in a collective agreement are those items which the parties to the NJC agreements have designated as such or upon which the Chairman of the Federal Public Sector Labour Relations Board has made a ruling pursuant to (c) of the NJC Memorandum of Understanding which became effective December 6, 1978
22.3 The following directives, as amended from time to time by National Joint Council recommendation and which have been approved by the National Research Council Canada, form part of this Agreement: - Bilingualism Bonus Directive - Commuting Assistance Directive - Occupational Health and Safety Directive - Relocation Directive - Travel Directive - First Aid to the General Public – Allowances for Employees - Public Service Health Care Plan - Uniforms Directive
22.4 During the term of this Agreement, other directives may be added to the above noted list.
22.5 Grievances in regard to the above directives shall be presented in accordance with clause 19.1 of the Grievance Procedure article of this Agreement.
Commercial Operation Date Testing and Modifications Prior to the Commercial Operation Date, the Connecting Transmission Owner shall test the Connecting Transmission Owner’s Attachment Facilities and System Upgrade Facilities and System Deliverability Upgrades and Developer shall test the Large Generating Facility and the Developer Attachment Facilities to ensure their safe and reliable operation. Similar testing may be required after initial operation. Developer and Connecting Transmission Owner shall each make any modifications to its facilities that are found to be necessary as a result of such testing. Developer shall bear the cost of all such testing and modifications. Developer shall generate test energy at the Large Generating Facility only if it has arranged for the injection of such test energy in accordance with NYISO procedures.
Please see the current Washtenaw Community College catalog for up-to-date program requirements Conditions & Requirements
ADDITIONAL SPECIAL CONTRACT CONDITIONS Special Contract Conditions revisions: the corresponding subsections of the Special Contract Conditions referenced below are replaced in their entirety with the following:
OFFICE OF MANAGEMENT AND BUDGET (OMB) AUDIT REQUIREMENTS The parties shall comply with the requirements of the Single Audit Act of 1984, P.L. 98-502, ensuring that the single audit report includes the coverage stipulated in 2 CFR 200.
Informal Resolution Outcomes a. When a complainant approaches an administrative officer and alleges harassment by another BCTF member, the following shall apply:
i. All discussions shall be solely an attempt to mediate the complaint;
ii. Any and all discussions shall be completely off the record and will not form part of any record;
iii. Only the complainant, respondent, and administrative officer shall be present at such meetings
iv. No discipline of any kind would be imposed on the respondent; and
v. The BCTF and its locals, based on the foregoing, will not invoke the notice of investigation and other discipline provisions of the collective agreement at meetings pursuant to Article E.2.5.a.
b. Should a resolution be reached between the complainant and the respondent at Step One under the circumstances of Article E.2.5.a, it shall be written up and signed by both. Only the complainant and the respondent shall have copies of the resolution and they shall be used only for the purpose of establishing that a resolution was reached. No other copies of the resolution shall be made.
c. In the circumstances where a respondent has acknowledged responsibility pursuant to Article E.
FINAL COMPLETION AND FINAL PAYMENT 9.9.1 Upon receipt of written notice that the Work is ready for final inspection and acceptance and upon receipt of a final Application for Payment, the Architect will promptly make such
9.9.2 Neither the final payment nor the remaining retained percentage shall become due until the Contractor submits to the Architect (1) an affidavit that all payrolls, bills for materials and equipment, and other indebtedness connected with the Work for which the State or its property might in any way be responsible, have been paid or otherwise satisfied; (2) consent of surety, if any, to final payment; (3) Other data establishing payment or satisfaction of all such obligations, including, but not limited to, receipts, releases, or other supporting documentation. and (4) final waivers of liens arising out of the Contract, to the extent and in such form as may be designated by the State. If any Subcontractor refuses to furnish a release or waiver required by the State, the Contractor may furnish a bond satisfactory to the State to indemnify him against any such lien. If any such lien remains unsatisfied after all payments are made, the Contractor shall refund to the State all moneys that the latter may be compelled to pay in discharging such lien, including all costs and reasonable attorneys' fees.
9.9.3 If, after Substantial Completion of the Work, final completion thereof is materially delayed through no fault of the Contractor or by the issuance of Change Orders affecting final completion, and the Architect so confirms, the State shall, upon application by the Contractor and certification by the Architect, and without terminating the Contract, make payment of the balance due for that portion of the Work fully completed and accepted. If the remaining balance for Work not fully completed or corrected is less than the retainage stipulated in the Contract Documents, and if bonds have been furnished as required by the Contract Documents, the written consent of the surety to the payment of the balance due for that portion of the Work fully completed and accepted shall be submitted by the Contractor to the Architect prior to certification of such payment. Such payment shall be made under the terms and conditions governing final payment, except that it shall not constitute a waiver of claims.
9.9.4 The making of final payment shall constitute a waiver of all claims by the State except those arising from:
(a) unsettled liens,
(b) faulty or defective Work appearing after Substantial Completion,
(c) failure of the Work to comply with the requirements of the Contract Documents, or
(d) terms of any special warranties required by the Contract Documents.
9.9.5 The acceptance of final payment shall constitute a waiver of all claims by the Contractor except those previously made in writing and identified by the Contractor as unsettled at the time of the final Application for Payment.
Technical Objections to Grievances It is the intent of both Parties of this Agreement that no grievance shall be defeated merely because of a technical error, other than time limitations in processing the grievance through the grievance procedure. To this end, an arbitration board shall have the power to allow all necessary amendments to the grievance and the power to waive formal procedural irregularities in the processing of a grievance, in order to determine the real matter in dispute and to render a decision according to equitable principles and the justice of the case.
CFR Part 200 or Federal Provision - Xxxx Anti-Lobbying Amendment - Continued If you answered "No, Vendor does not certify - Lobbying to Report" to the above attribute question, you must download, read, execute, and upload the attachment entitled "Disclosure of Lobbying Activities - Standard Form - LLL", as instructed, to report the lobbying activities you performed or paid others to perform. Compliance with all applicable standards, orders, or requirements issued under section 306 of the Clean Air Act (42 U.S.C. 1857(h)), section 508 of the Clean Water Act (33 U.S.C. 1368), Executive Order 11738, and Environmental Protection Agency regulations (40 CFR part 15). (Contracts, subcontracts, and subgrants of amounts in excess of $100,000) Pursuant to the above, when federal funds are expended by ESC Region 8 and TIPS Members, ESC Region 8 and TIPS Members requires the proposer certify that in performance of the contracts, subcontracts, and subgrants of amounts in excess of $250,000, the vendor will be in compliance with all applicable standards, orders, or requirements issued under section 306 of the Clean Air Act (42 U.S.C. 1857(h)), section 508 of the Clean Water Act (33 U.S.C. 1368), Executive Order 11738, and Environmental Protection Agency regulations (40 CFR part 15). Does vendor certify compliance? Yes
Payment of Extension Fee The Borrower shall pay to the Agent for the pro rata accounts of the Lenders in accordance with their respective Commitments an extension fee in an amount equal to twenty-five (25) basis points on the Total Commitment in effect on the Maturity Date (as determined without regard to such extension), which fee shall, when paid, be fully earned and non-refundable under any circumstances.
