Construction Phase Fee Contractor’s Construction Phase Fee is the maximum amount payable to Contractor for any cost or profit expectation incurred in the performance of the Work that is not specifically identified as being eligible for reimbursement by Owner elsewhere in this Agreement. References in the UGSC to Contractor’s “overhead” and “profit” mean Contractor’s Construction Phase Fee. The Construction Phase Fee includes, but is not limited to, the following items:
9.1 All profit, profit expectations and costs associated with profit sharing plans such as personnel bonuses, incentives, and rewards; company stock options; or any other like expenses of Contractor.
C1 Contract Price In consideration of the Contractor’s performance of its obligations under the Contract, the Authority shall pay the Contract Price in accordance with clause C2 (Payment and VAT).
Minimum Customer Support Requirements for TIPS Sales Vendor shall provide timely and commercially reasonable support for TIPS Sales or as agreed to in the applicable Supplemental Agreement.
Total Contract Amount The contract total shall not exceed $350,000. Pricing shall be per Exhibit E attached.
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Indirect Cost Rates The System Agency may acknowledge an indirect cost rate for Grantees that is utilized for all applicable Grant Agreements. For subrecipients receiving federal funds, indirect cost rates will be determined in accordance with applicable law including, but not limited to, 2 CFR 200.414(f). For recipients receiving state funds, indirect costs will be determined in accordance with applicable law including, but not limited to, TxGMS. Grantees funded with blended federal and state funding will be subject to both state and federal requirements when determining indirect costs. In the event of a conflict between TxGMS and applicable federal law or regulation, the provisions of federal law or regulation will apply. Grantee will provide any necessary financial documents to determine the indirect cost rate in accordance with the Uniform Grant Guidance (UGG) and TxGMS.
Subcontract Costs Payments made by the Construction Manager to Subcontractors in accordance with the requirements of the subcontracts and this Agreement.
Payment and Contract Price C1 Contract Price
C1.1 In consideration of the Contractor’s performance of its obligations under the Contract, the Authority shall pay the Contract Price in accordance with clause C2 (Payment and VAT).
C1.2 The Authority shall, in addition to the Contract Price and following evidence of a valid VAT invoice, pay the Contractor a sum equal to the VAT chargeable on the value of the Services supplied in accordance with the Contract. C2 Payment and VAT
C2.1 The Authority shall pay all sums due to the Contractor within thirty (30) days of receipt of a valid invoice, submitted Monthly in arrears.
C2.2 The Authority shall pay all sums by direct credit transfer into a suitable bank account or by other electronic payment methods as appropriate.
C2.3 The Contractor shall ensure that each invoice contains a valid purchase order number. All appropriate references and a detailed breakdown of the Services supplied and any other documentation reasonably required by the Authority to substantiate the invoice should be supplied in accordance with Schedule 2.
C2.4 Where the Contractor enters into a sub-contract for the purpose of performing its obligations under the Contract, it shall ensure that a provision is included in such a sub-contract which requires payment to be made of all sums due by the Contractor to the Sub-contractor within a specified period not exceeding thirty (30) days from the receipt of a valid invoice.
C2.5 The Contractor shall add VAT to the Contract Price at the prevailing rate as applicable and the Authority shall pay the VAT to the Contractor following its receipt of a valid VAT invoice.
C2.6 The Contractor shall indemnify the Authority on a continuing basis against any liability, including any interest, penalties or costs incurred, which is levied, demanded or assessed on the Authority at any time in respect of the Contractor’s failure to account for or to pay any VAT relating to payments made to the Contractor under the Contract. Any amounts due under this clause C2.5 shall be paid by the Contractor to the Authority not less than five (5) Working Days before the date upon which the tax or other liability is payable by the Authority.
C2.7 The Contractor shall not suspend the supply of the Services unless the Contractor is entitled to terminate the Contract under clause H2.3 (Termination on Default) for failure to pay undisputed sums of money. Interest shall be payable by the Authority on the late payment of any undisputed sums of money properly invoiced in accordance with the Late Payment of Commercial Debts (Interest) Xxx 0000.
C2.8 Where payment by the Authority of all or any part of any invoice rendered or other claim for payment by the Contractor is disputed, this dispute shall be resolved in accordance with the disputed claims procedure as set out in Schedule 2. C3 Recovery of Sums Due C3.1 Wherever under the Contract any sum of money is recoverable from or payable by the Contractor (including any sum which the Contractor is liable to pay to the Authority in respect of any breach of the Contract), the Authority may unilaterally deduct that sum from any sum then due, or which at any later time may become due to the Contractor under the Contract or under any other agreement or contract with the Authority. C3.2 Any overpayment by either Party, whether of the Contract Price or of VAT or otherwise, shall be a sum of money recoverable by the Party who made the overpayment from the Party in receipt of the overpayment.
C3.3 The Contractor shall make all payments due to the Authority without any deduction whether by way of set-off, counterclaim, discount, abatement or otherwise unless the Contractor has a valid court order requiring an amount equal to such deduction to be paid by the Authority to the Contractor.
C3.4 All payments due shall be made within a reasonable time unless otherwise specified in the Contract, in cleared funds, to such bank or building society account as the recipient Party may from time to time direct. C4 Price adjustment on extension of the Initial Contract Period
C4.1 The Contract Price shall apply for the Initial Contract Period. In the event that the Authority agrees to extend the Initial Contract Period pursuant to clause F8 (Extension of Initial Contract Period), the Authority may, where applicable, in the six (6) Month period prior to the expiry of the Initial Contract Period, enter into good faith negotiations with the Contractor (for a period of not more than thirty (30) Working Days) to agree a variation in the Contract Price. For the avoidance of doubt both Parties accept and acknowledge that any Variation to the Contract Price shall not have the effect of altering the economic balance of the Contract during the period of extension in favour of the Contractor in a manner not provided for in the terms of the Contract.
C4.2 If the Parties are unable to agree a variation in the Contract Price in accordance with clause C4.1, the Contract shall terminate at the end of the Initial Contract Period.
C4.3 If a variation in the Contract Price is agreed between the Authority and the Contractor, the revised Contract Price will take effect from the first day of any period of extension and shall apply during such period of extension.
C4.4 Any increase in the Contract Price pursuant to clause C4.1 shall not exceed the percentage change in the Office of National Statistics’ Consumer Prices Index (CPI) (or another such index specified in the Prices & Rates Schedule) between the Commencement Date and the date six (6) Months before the end of the Initial Contract Period.] C5 Euro
C5.1 Any requirement of Law to account for the Services in Euro (or to prepare for such accounting) instead of and/or in addition to sterling, shall be implemented by the Contractor at nil charge to the Authority.
C5.2 The Authority shall provide all reasonable assistance to facilitate compliance with clause C5.1 by the Contractor. C6 Third Party Revenue
C6.1 The Contractor may not obtain any third party revenue, income or credit based on the Services and/or copyright works delivered under this Contract without the express prior written agreement of the Authority.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
PRICE ESCALATION/DE-ESCALATION (CPI) The County may allow a price escalation provision within this award. The original contract prices shall be firm for an initial one (1) year period. A price escalation/de-escalation will be considered at one (1) year intervals thereafter, provided the Contractor notifies the County, in writing, of the pending price escalation/de-escalation a minimum of sixty (60) days prior to the effective date. Price adjustments shall be based on the latest version of the Consumers Price Index (CPI-U) for All Urban Consumers, All Items, U.S. City Average, non-seasonal, as published by the U.S. Department of Labor, Bureau of Labor Statistics. This information is available at xxx.xxx.xxx. Price adjustment shall be calculated by applying the simple percentage model to the CPI data. This method is defined as subtracting the base period index value (at the time of initial award) from the index value at time of calculation (latest version of the CPI published as of the date of request for price adjustment), divided by the base period index value to identify percentage of change, then multiplying the percentage of change by 100 to identify the percentage change. Formula is as follows: Current Index – Base Index / Base Index = % of Change CPI for current period 232.945 Less CPI for base period 229.815 Equals index point change 3.130 Divided by base period CPI 229.815 Equals 0.0136 Result multiplied by 100 0.0136 x 100 Equals percent change 1.4% % of Change x 100 = Percentage Change CPI-U Calculation Example: A price increase may be requested only at each time interval specified above, using the methodology outlined in this section. To request a price increase, Contractor shall submit a letter stating the percentage amount of the requested increase and adjusted price to the Orange County Procurement Division. The letter shall include the complete calculation utilizing the formula above, and a copy of the CPI-U index table used in the calculation. The maximum allowable increase shall not exceed 4%, unless authorized by the Manager, Procurement Division. All price adjustments must be accepted by the Manager, Procurement Division and shall be memorialized by written amendment to this contract. No retroactive contract price adjustments will be allowed. Should the CPI-U for All Urban Consumers, All Items, U.S City Average, as published by the U.S. Department of Labor, Bureau of Labor Statistics decrease during the term of the contract, or any renewals, the Contractor shall notify the Orange County Procurement Division of price decreases in the method outlined above. If approved, the price adjustment shall become effective on the contract renewal date. If the Contractor fails to pass the decrease on to the County, the County reserves the right to place the Contractor in default, cancel the award, and remove the Contractor from the County Vendor List for a period of time deemed suitable by the County. In the event of this occurrence, the County further reserves the right to utilize any options as stated herein.
