Delays during construction Without prejudice to the provisions of Clause 10.3 (ii), in the event the Contractor does not achieve any of the Project Milestones or the Authority’s Engineer shall have reasonably determined that the rate of progress of Works is such that Completion of the Project Highway is not likely to be achieved by the end of the Scheduled Completion Date, it shall notify the same to the Contractor, and the Contractor shall, within 15 (fifteen) days of such notice, by a communication inform the Authority’s Engineer in reasonable detail about the steps it proposes to take to expedite progress and the period within which it shall achieve the Project Completion Date.
Insurance; Damage to or Destruction of Collateral (a) The Credit Parties shall, at their sole cost and expense, maintain the policies of insurance described on Disclosure Schedule 3.18 as in effect on the date hereof or otherwise in form and amounts and with deductibles as is customary for similarly situated businesses and with insurers reasonably acceptable to Agent. Agent and the Lenders confirm that the form, amounts and insurers described on Disclosure Schedule 3.18 are acceptable as of the Closing Date, and shall continue to be acceptable to Agent until not less than 30 days' prior written notice by Agent to Borrower to the contrary. Such policies of insurance (or the loss payable and additional insured endorsements delivered to Agent) shall contain provisions pursuant to which the insurer agrees to provide 30 days prior written notice to Agent in the event of any non-renewal, cancellation or amendment of any such insurance policy. If any Credit Party at any time or times hereafter shall fail to obtain or maintain any of the policies of insurance required above, or to pay all premiums relating thereto, Agent may at any time or times thereafter obtain and maintain such policies of insurance and pay such premiums and take any other action with respect thereto that Agent deems advisable. Agent shall have no obligation to obtain insurance for any Credit Party or pay any premiums therefor. By doing so, Agent shall not be deemed to have waived any Default or Event of Default arising from any Credit Party's failure to maintain such insurance or pay any premiums therefor. All sums so disbursed, including reasonable attorneys' fees, court costs and other charges related thereto, shall be payable on demand by Borrower to Agent and shall be additional Obligations hereunder secured by the Collateral.
(b) Agent reserves the right at any time (but not to be exercised more than once per Fiscal Year) upon (i) any material change in any Credit Party's risk profile (including any change in the product mix maintained by any Credit Party or any laws affecting the potential liability of such Credit Party), as determined by Agent in its commercially reasonable judgment, and (ii) not less than 30 days' prior written notice to Borrower, to require additional forms and limits of insurance to, in Agent's commercially reasonable judgment, adequately protect both Agent's and Lender's interests in all or any portion of the Collateral and to ensure that each Credit Party is protected by insurance in amounts and with coverage customary for its industry. If reasonably requested by Agent, each Credit Party shall deliver to Agent from time to time a report of a reputable insurance broker, reasonably satisfactory to Agent, with respect to its insurance policies.
(c) Each Credit Party shall deliver to Agent, in form and substance reasonably satisfactory to Agent, endorsements to (i) all "All Risk" and business interruption insurance naming Agent, on behalf of itself and Lenders, as lender loss payee or mortgagee (as the case may be), and (ii) all general liability and other liability policies naming Agent, on behalf of itself and Lenders, as additional insured. Each Credit Party irrevocably makes, constitutes and appoints Agent (and all officers, employees or agents designated by Agent), so long as any Event of Default has occurred and is continuing or the anticipated insurance proceeds exceed $1,000,000, as such Credit Party's true and lawful agent and attorney-in-fact for the purpose of making, settling and adjusting claims under such "All Risk" policies of insurance, endorsing the name of such Credit Party on any check or other item of payment for the proceeds of such "All Risk" policies of insurance and for making all determinations and decisions with respect to such "All Risk" policies of insurance. Agent shall have no duty to exercise any rights or powers granted to it pursuant to the foregoing power-of-attorney. Borrower shall promptly notify Agent of any loss, damage, or destruction to the Collateral in
(i) Borrower shall request a Revolving Credit Advance be made to Borrower in the amount requested to be released; (ii) so long as the conditions set forth in Section 2.2 have been met, Lenders shall make such Revolving Credit Advance; and (iii) in the case of insurance proceeds applied against the Revolving Loan, the Reserve established with respect to such insurance proceeds shall be reduced by the amount of such Revolving Credit Advance. To the extent not used to replace, repair, restore or rebuild the Collateral, such insurance proceeds shall be applied in accordance with Section 1.3(c).
Casualty Damage 18.1 Tenant shall give immediate notice (by telephone, confirmed in writing) to Landlord of any damage caused to the Premises by fire or other casualty, and if Landlord does not elect to terminate this Lease as provided in Section 18.2, Landlord shall proceed with reasonable diligence and at its sole cost and expense to rebuild and repair the Building and/or the Premises, as the case may be, but Landlord shall not be obligated to expend for such rebuilding and repair any amount in excess of the amount of the insurance proceeds actually recovered by Landlord and made available by any Superior Lessor or Superior Mortgagee as a result of such loss.
18.2 If the Building or the Premises shall be destroyed or substantially damaged by a casualty not covered by Landlord’s insurance, or if 25% or more of the Premises is damaged or rendered untenantable by a casualty covered by Landlord’s insurance, or if the Premises are not affected but 25% of the Building or such portion of the Common Facilities as shall render the Premises or the Building untenantable is damaged or rendered untenantable, then in any such event Landlord may elect either to terminate this Lease or to proceed to rebuild and repair the Premises or that portion of the Building so damaged. Landlord shall give written notice to Tenant of such election within 90 days after the occurrence of such casualty, or within 30 days after the adjustment of the insurance settlement, whichever is later. In the event that such notice of termination shall be given, this Lease shall terminate as of the date provided in such notice of termination (whether or not the Term shall have commenced) with the same effect as if that date were the Expiration Date, without prejudice, however, to Landlord’s rights and remedies against Tenant under the terms of this Lease. If at any time prior to Landlord giving the aforesaid notice of termination or commencing the repair pursuant to Section 18.1, there shall be a Successor Landlord, such Successor Landlord shall have a further period of 60 days from the date of so taking possession to terminate this Lease by notice to Tenant and in the event that such a notice of termination shall be given, this Lease shall terminate as of the date provided in such notice of termination (whether or not the Term shall have been commenced) if Tenant is not occupying any portion of the Premises or otherwise as of the date provided in such notice, with the same effect as if that date were the Expiration Date, without prejudice, however, to Landlord’s rights against Tenant under the terms of this Lease.
18.3 Subject to the provisions of Section 18.1, Landlord’s obligation to rebuild and repair under this Article XVIII shall in any event be limited to restoring Landlord’s Work, as described in the Work Letter, to substantially the condition in which the same existed prior to the casualty, and to proceed, at the sole cost and expense of Tenant, to rebuild, repair and restore Tenant’s Work and any additional Improvements made by Tenant during the Term, all to substantially the condition existing prior to such casualty.
18.4 During the period from the occurrence of the casualty until Landlord’s repairs are completed, the Basic Rent payable pursuant to Article V and Additional Rent payable pursuant to Articles VI and VII shall be abated in that proportion which the Premises area rendered untenantable bears to the entire Premises area; provided, however, there shall be no abatement of any other charges or items of Additional Rent provided for herein to be paid by Tenant; and further provided, however, that should Tenant or anyone claiming through or under Tenant occupy a portion of the Premises during the period the repair work is taking place and prior to the date the Premises are no longer untenantable, the Rent allocable to such reoccupied portion, based upon the proportion which the reoccupied portion of the Premises bears to the total area of the Premises, shall be payable by Tenant from the date of such occupancy.
18.5 Landlord shall not the liable for any inconvenience or annoyance to Tenant or injury to the business of Tenant resulting in any way from any such damage by fire or other casualty or the repair thereof.
18.6 Notwithstanding any of the foregoing provisions of this Article, if, by reason of any negligence or willful act on the part of Tenant or any of its employees, agents, licensees, invitees or contractors, either (a) Landlord or the Superior Lessor or the Superior Mortgagee shall be unable to collect all of the insurance proceeds (including rent insurance proceeds) applicable to damage or destruction of the Premises or the Building or the Project by fire or other casualty or (b) the Premises or the Building or the Project shall be damaged or destroyed or rendered completely or partially untenantable on account of fire or other casualty then, without prejudice to any other remedy which may be available against Tenant, the abatement of rent provided for in Section 18.4 shall not be effective to the extent of the uncollected insurance proceeds.
Maintenance during Construction Period (i) During the Construction Period, the Contractor shall maintain, at its cost, the existing lane(s) of the Project Highway so that the traffic worthiness and safety thereof are at no time materially inferior as compared to their condition on Appointed Date, and shall undertake the necessary repair and maintenance works for this purpose; provided that the Contractor may, at its cost, interrupt and divert the flow of traffic if such interruption and diversion is necessary for the efficient progress of Works and conforms to Good Industry Practice; provided further that such interruption and diversion shall be undertaken by the Contractor only with the prior written approval of the Authority’s Engineer which approval shall not be unreasonably withheld. For the avoidance of doubt, it is agreed that the Contractor shall at all times be responsible for ensuring safe operation of the Project Highway. It is further agreed that in the event the Project includes construction of a bypass or tunnel and realignment of the existing carriageway, the Contractor shall maintain the existing highway in such sections until the new Works are open to traffic.
(ii) Notwithstanding anything to the contrary contained in this Agreement, in the event of default by the Contractor in discharging the obligations specified in Clause 10.4 (i) above, the Authority shall get these maintenance works completed in the manner recommended by the Authority’s Engineer to avoid public inconvenience at the risk and cost of the Contractor in order to keep the road in traffic worthy condition.
DAMAGE OR DESTRUCTION OF PREMISES a. In the event the Premises are damaged by fire or other perils or casualty covered by fire and extended coverage insurance, Landlord may, in its sole and absolute discretion, repair or rebuild the same within a reasonable time after the event causing such damage. This Lease shall remain in full force and effect, except that Tenant shall be entitled to a proportionate reduction of the rent from the date of damage and while such repairs are being made, such proportionate reduction to be based upon the extent to which the damage and making of such repairs shall reasonably interfere with the business carried on by Tenant in the Premises as determined by Landlord. If the damage is due to the fault or neglect of Tenant or its employees, as determined by Landlord in its sole discretion, there shall be no reduction of rent. Landlord may authorize or direct construction of an alternative structure or may elect to retain any insurance proceeds received by it if Landlord deems reconstruction or construction of an alternative structure to be impractical or unreasonable in its sole discretion.
b. In the event the Premises are damaged to any extent as a result of any cause other than the perils covered by fire and extended coverage insurance, Landlord shall in its sole discretion have the option to: (1.) to repair, reconstruct or restore the Premises within a reasonable time of the event causing the damage, in which case this Lease shall continue in full force and effect, but the rent shall be proportionately reduced as provided above in 11a. during the period of such repair, reconstruction or restoration, or (2.) to give notice to Tenant at any time within sixty (60) days after such damage occurs, terminating this Lease as of the date specified in such notice, which date shall be no more than thirty (30) days after the giving of such notice. In the event of giving to Tenant such notice of termination, this Lease shall terminate and all interests of Tenant in the Premises shall cease on the date so specified in such notice and Tenant shall pay the rent, as proportionately reduced, based upon the extent, if any, to which such damage interfered with the business carried on by Tenant in the Premises, up to the date of such termination.
c. With regard to Landlord’s duty or option to repair, reconstruct or restore the Premises within a reasonable time of the event causing the damage as provided in 11a. and b. above, Landlord shall act promptly and with due diligence, but Landlord shall not be responsible for delays caused by factors beyond Landlord’s control, including but not limited to delays because of strikes, work slowdowns or stoppages, accidents, acts of God, failure of any governmental or other authority to act in a timely manner, or delays caused by contractors. If such delays occur, Tenant agrees that Landlord shall not be responsible for damages, nor shall Landlord be deemed to be in default under this Lease.
d. Landlord shall not be required to repair any damage by fire or other casualty, or to make any repair or replacements of any leasehold improvements, fixtures, or other personal property of Tenant.
Damage, Destruction or Condemnation (a) In the event of damage to or destruction of any portion of the Project resulting from fire or other casualty during the Term, or in the event any portion of the District is condemned or taken for any public or quasi-public use or title thereto is found to be deficient during the Term, the net proceeds of any insurance relating to such damage or destruction, the net proceeds of such condemnation or taking or the net proceeds of any realization on title insurance shall be paid into, and used in accordance with a construction escrow agreement reasonably satisfactory to the City and Developer ("Casualty Escrow").
(b) If, at any time during the Term, the Project or any part thereof shall be damaged or destroyed by a casualty (the "Damaged Facilities"), Developer, at its sole cost and expense, shall commence and thereafter proceed as promptly as possible to repair, restore and replace the Damaged Facilities as nearly as possible to their condition immediately prior to the casualty and shall be entitled to draw upon the Casualty Escrow for payment of said costs.
(c) If at any time during the Term, title to the whole or substantially all of the Project which has previously been conveyed to Developer shall be taken in condemnation proceedings or by right of eminent domain, Developer, at its sole discretion, may terminate this Agreement as of the date of such taking. For purposes of this Section 6.07(c), "substantially all of the District" shall be deemed to have been taken if the City and Developer, each acting reasonably and in good faith, determine that the untaken portion of the District, including the parking improvements, cannot be practically and economically used by Developer for the purposes and at the times contemplated by this Agreement.
(d) In the event of condemnation of less than the whole or substantially all of the District which has previously been conveyed to Developer during the Term, Developer, at its sole cost and expense, shall commence and thereafter proceed as promptly as possible to repair, restore and replace the remaining part of the Project, as nearly as possible, to its former condition, and shall be entitled to draw upon the Casualty Escrow for payment of said costs.
(e) Nothing in this section will require the Developer to expend funds in excess of the Casualty Escrow for the repair, restoration and/or replacement of the Damaged Facilities.
Damage to Equipment Each Party shall be responsible for damages to or loss of its own equipment. Each Party, and where applicable its insurer or coverage provider, waives the right to sue any other Party for any damages to or loss of its equipment, even if the damages or losses were caused wholly or partially by the negligence of any other Party or its officers, employees or volunteers.
Repair of Damage If the Relevant Space is damaged by fire, storm, flood, earthquake or other insured casualty, Landlord and Tenant shall work cooperatively and diligently with one another to obtain estimates of the cost and time required to repair and restore such damage to the Building and the Relevant Space (which estimates Landlord shall be responsible for obtaining and sharing with Tenant) and to negotiate a settlement payment with the relevant insurance company as quickly as feasible following the date of the casualty event and in any event within ninety (90) days after the date of such casualty event (the “90-Day Casualty Assessment Period”). If it is determined that the damage to the Building and the Relevant Space can be substantially repaired and restored within one hundred eighty (180) days from the expiration of the 90-Day Casualty Assessment Period using standard working methods and procedures, Landlord shall use reasonable efforts to repair and restore the Relevant Space and the Building to its previous condition. Provided, however, if it is determined that the Building and the Relevant Space cannot be repaired and restored within such one hundred eighty (180) day period, then either party may, within ten (10) days after such determination is made and communicated to both Landlord and Tenant, terminate this Lease by giving notice to the other party; provided further, however, Tenant shall not be able to terminate this Lease if the damage was caused by Tenant’s willful misconduct. Notwithstanding the foregoing, Tenant shall reimburse Landlord for the cost of repairing and restoring the Building, the Building-Specific Common Areas, the Exterior Common Areas and/or the Land, or any part thereof, to the extent that any water damage is due to the malfunction, leaking or misuse of any Tenant personal property, equipment, or non- Building Standard Improvements, including, without limitation, refrigerators, fish tanks, icemakers, water fountains and water coolers, to the extent specified in Section 6.4 herein. Additionally, if it is determined that the Building and the Relevant Space will be repaired and restored as provided above, Tenant shall be entitled, by so notifying Landlord in writing during the 90-Day Casualty Assessment Period, to have Landlord’s repair and restoration obligations encompass only a scope of work that is consistent with the Building Shell Improvements originally completed by Landlord prior to the Commencement Date and, in such case, (i) Tenant shall be responsible for all additional work required to repair and restore the Building and the Relevant Space to the condition that existed immediately prior to the casualty event or to a modified condition and receive the relevant insurance proceeds related thereto which remain following the completion of Landlord’s repair and restoration obligations, subject to Landlord’s prior written approval of the plans and specifications for such modifications pursuant to Section 6.1(b) herein (and Tenant shall bear the risk of any shortfall in insurance proceeds to fully pay for such additional work if and to the extent such additional work exceeds the scope of work that would be required to restore the Improvements that existed in the Premises immediately prior to the casualty event), (ii) the foregoing one hundred eighty (180) day period for the completion of the repair and restoration project shall no longer be applicable and (iii) Tenant shall cause such additional work to be completed in an expeditious manner (so that rent hereunder will again be payable with respect to the Relevant Space) and otherwise in compliance with all relevant terms and provisions in this Lease relating to the installation of Improvements by Tenant.
Damage, Destruction and Condemnation (a) Seller will bear the risk of loss for any damage, destruction, or condemnation that may occur prior to Closing. If any portion of the Property is damaged or destroyed prior to Closing, Purchaser may elect to terminate this Agreement, unless prior to Closing all that damage has been repaired and the Improvements restored or replaced to their condition prior to the damage. If any material portion of the Property is condemned or taken prior to Closing, Purchaser may elect to terminate this Agreement.
(b) Purchaser's election under this Section with respect to any condemnation or taking will be exercised by written notice to Seller within twenty (20) days after written notice from Seller of the condemnation or taking. Purchaser's election under this Section with respect to any damage or destruction not repaired prior to Closing will be exercised by written notice to seller within twenty (20) days of the later to occur of:
(i) written notice from Seller of the damage or destruction and Seller's inability to repair and restore prior to Closing; or
(ii) written notice from Seller's insurance carrier regarding the estimated cost of repair, replacement, or reconstruction and the portion of the repair, replacement, or reconstruction for which insurance proceeds will be made available. The Closing Date will be extended as necessary to give Purchaser time to make the election.
(c) If Purchaser elects to terminate this Agreement under this Section, neither party will have any further rights, duties, or obligations. If Purchaser does not elect to terminate this Agreement, this Agreement will remain in full force and the purchase contemplated in this Agreement, less any interest taken by condemnation, will be effected, and at the Closing, Seller will pay the Purchaser the amount of any deductible under Seller's insurance policy and will assign, transfer, and set over to Purchaser all of Seller's right, title, and interest to any condemnation awards or insurance proceeds that have been or that may later be made for the taking or destruction.
Repair of Damage to Premises by Landlord Tenant shall promptly notify Landlord of any damage to the Premises resulting from fire or any other casualty. If the Premises or any Common Areas serving or providing access to the Premises shall be damaged by fire or other casualty, Landlord shall promptly and diligently, subject to reasonable delays for insurance adjustment or other matters beyond Landlord's reasonable control, and subject to all other terms of this Article 1 1, restore the Base Building and such Common Areas. Such restoration shall be to substantially the same condition of the Base Building and the Common Areas prior to the casualty, except for modifications required by zoning and building codes and other laws or by the holder of a mortgage on the Building or Project or any other modifications to the Common Areas deemed desirable by Landlord, which are consistent with the character of the Project, provided that access to the Premises and any common restrooms serving the Premises shall not be materially impaired. Landlord shall repair any injury or damage to the improvements which exist in the Premises as of the Lease Commencement Date (the "Original Improvements") and shall return such Original Improvements to their original condition. Prior to the commencement of construction, Tenant shall submit to Landlord, for Landlord's review and approval, all plans, specifications and working drawings relating thereto, and Landlord shall select the contractors to perform such improvement work. Landlord shall not be liable for any inconvenience or annoyance to Tenant or its visitors, or injury to Tenant's business resulting in any way from such damage or the repair thereof; provided however, that if such fire or other casualty shall have damaged the Premises or Common Areas necessary to Tenant's occupancy, and the Premises are not occupied by Tenant as a result thereof, then during the time and to the extent the Premises are unfit for occupancy, the Rent shall be abated in proportion to the ratio that the amount of rentable square feet of the Premises which is unfit for occupancy for the purposes permitted under this Lease bears to the total rentable square feet of the Premises, provided that if the Premises are so damaged that it is not reasonably practicable for Tenant to continue its business operations from any portion of the Premises, then the Rent shall be fully abated during such time.
