Repayment of Amounts Advanced for Network Upgrades Upon the Commercial Operation Date, the Interconnection Customer shall be entitled to a repayment, equal to the total amount paid to the Participating TO for the cost of Network Upgrades. Such amount shall include any tax gross-up or other tax-related payments associated with Network Upgrades not refunded to the Interconnection Customer pursuant to Article 5.17.8 or otherwise, and shall be paid to the Interconnection Customer by the Participating TO on a dollar-for-dollar basis either through (1) direct payments made on a levelized basis over the five-year period commencing on the Commercial Operation Date; or (2) any alternative payment schedule that is mutually agreeable to the Interconnection Customer and Participating TO, provided that such amount is paid within five (5) years from the Commercial Operation Date. Notwithstanding the foregoing, if this LGIA terminates within five (5) years from the Commercial Operation Date, the Participating TO’s obligation to pay refunds to the Interconnection Customer shall cease as of the date of termination. Any repayment shall include interest calculated in accordance with the methodology set forth in FERC’s regulations at 18 C.F.R. §35.19a(a)(2)(iii) from the date of any payment for Network Upgrades through the date on which the Interconnection Customer receives a repayment of such payment. Interest shall continue to accrue on the repayment obligation so long as this LGIA is in effect. The Interconnection Customer may assign such repayment rights to any person. If the Large Generating Facility fails to achieve commercial operation, but it or another Generating Facility is later constructed and makes use of the Network Upgrades, the Participating TO shall at that time reimburse Interconnection Customer for the amounts advanced for the Network Upgrades. Before any such reimbursement can occur, the Interconnection Customer, or the entity that ultimately constructs the Generating Facility, if different, is responsible for identifying the entity to which reimbursement must be made.
INTERIM MAINTENANCE PERIOD During the interim maintenance period between obtaining of the completion certificate of Project and formation and operationalization of the Association the Promoter shall through itself or through a facility management company constitute a committee to run, operate, manage and maintain the Common Areas.
Documentation of Accounts Maintained as of June 30, 2014 With respect to Reportable Accounts maintained by a Reporting Financial Institution as of June 30, 2014:
Maintenance Period During the Maintenance Period the Developer shall at its own expense maintain repair and otherwise S.9 keep the Works in good working order and repair to the reasonable satisfaction of xxx Xxxxxxxxxx unless xxx Xxxxxxxxxx shall declare that any required maintenance and/or repair is an emergency in which case the Developer shall carry out the said maintenance and/or repair immediately Access to the Works and consequences of inspections The Developer shall arrange for xxx Xxxxxxxxxx to have access to the Works and the Site at all
Overhead Rates The Engineer shall use the provisional overhead rate indicated in Attachment E. If a periodic escalation of the provisional overhead rate is specified in Attachment E, the effective date of the revised provisional overhead rate must be included. For lump sum contracts, the overhead rate remains unchanged for the entire contract period.
Temporary Credit for Unamortized Specified Road Construction Cost When, under B8.33, Contracting Officer orders a delay or interruption of Purchaser’s Operations for more than 30 days when scheduled operations would be occurring but for the order, the Contracting Officer shall credit the unamortized cost of Specified Roads to Purchaser’s Timber Sale Account, upon the written request of Purchaser or at the discretion of Contracting Officer. The amount credited to Purchaser shall be limited to stumpage paid above Base Rates. Any Specified Road construction cost credited to Purchaser pursuant to this Subsection may be refunded or transferred at the request of Purchaser. However, if Purchaser has outstanding debt owing the United States, Contracting Officer must apply the amount of credit that could be refunded to the debt owed in accordance with the Debt Collection Improvement Act of 1996, as amended. Upon written notice from Contracting Officer that the basis for the delay or interruption no longer exists, Purchaser shall pay for timber a per unit amount, in addition to Current Contract Rates, that is equal to the amount credited to Purchaser’s Timber Sale Account divided by 80 percent of the estimated remaining volume of the contract, until the full amount credited to Purchaser has been returned.
Staffing Levels To the extent legislative appropriations and PIN authorizations allow, safe staffing levels will be maintained in all institutions where employees have patient, client, inmate or student care responsibilities. In July of each year, the Secretary or Deputy Secretary of each agency will, upon request, meet with the Union, to hear the employees’ views regarding staffing levels. In August of each year, the Secretary or Deputy Secretary of Budget and Management will, upon request, meet with the Union to hear the employees’ views regarding the Governor’s budget request.
Refinancing Preparation Advance; Capitalizing Front-end Fee and Interest (a) If the Loan Agreement provides for the repayment out of the proceeds of the Loan of an advance made by the Bank or the Association (“Preparation Advance”), the Bank shall, on behalf of such Loan Party, withdraw from the Loan Account on or after the Effective Date the amount required to repay the withdrawn and outstanding balance of the advance as at the date of such withdrawal from the Loan Account and to pay all accrued and unpaid charges, if any, on the advance as at such date. The Bank shall pay the amount so withdrawn to itself or the Association, as the case may be, and shall cancel the remaining unwithdrawn amount of the advance.”
Long Term Cost Evaluation Criterion # 4. READ CAREFULLY and see in the RFP document under "Proposal Scoring and Evaluation". Points will be assigned to this criterion based on your answer to this Attribute. Points are awarded if you agree not i ncrease your catalog prices (as defined herein) more than X% annually over the previous year for years two and thr ee and potentially year four, unless an exigent circumstance exists in the marketplace and the excess price increase which exceeds X% annually is supported by documentation provided by you and your suppliers and shared with TIP S, if requested. If you agree NOT to increase prices more than 5%, except when justified by supporting documentati on, you are awarded 10 points; if 6% to 14%, except when justified by supporting documentation, you receive 1 to 9 points incrementally. Price increases 14% or greater, except when justified by supporting documentation, receive 0 points. increases will be 5% or less annually per question Required Confidentiality Claim Form Required Confidentiality Claim Form This completed form is required by TIPS. By submitting a response to this solicitation you agree to download from th e “Attachments” section, complete according to the instructions on the form, then uploading the completed form, wit h any confidential attachments, if applicable, to the “Response Attachments” section titled “Confidentiality Form” in order to provide to TIPS the completed form titled, “CONFIDENTIALITY CLAIM FORM”. By completing this process, you provide us with the information we require to comply with the open record laws of the State of Texas as they ma y apply to your proposal submission. If you do not provide the form with your proposal, an award will not be made if your proposal is qualified for an award, until TIPS has an accurate, completed form from you. Read the form carefully before completing and if you have any questions, email Xxxx Xxxxxx at TIPS at xxxx.xxxxxx@t xxx-xxx.xxx Choice of Law clauses with TIPS Members If the vendor is awarded a contract with TIPS under this solicitation, the vendor agrees to make any Choice of Law c lauses in any contract or agreement entered into between the awarded vendor and with a TIPS member entity to re ad as follows: "Choice of law shall be the laws of the state where the customer resides" or words to that effect. 5 Agreed Venue of dispute resolution with a TIPS Member In the event of litigation or use of any dispute resolution model when resolving disputes with a TIPS member entity a s a result of a transaction between the vendor and TIPS or the TIPS member entity, the Venue for any litigation or ot her agreed upon model shall be in the state and county where the customer resides unless otherwise agreed by the parties at the time the dispute resolution model is decided by the parties. Agreed
PERIODIC RATES The periodic rates applicable to purchases, cash advances, and balance transfers are disclosed on the Disclosure that accompanies this Agreement. Any penalty rate that may be imposed for failing to make a payment by the payment due date is also disclosed on the Disclosure. Any rate change will be made pursuant to applicable law. If the rate for your account is variable, as indicated on the accompanying Disclosure, the rate charged on purchases, cash advances, balance transfers and any penalty rate will vary periodically as disclosed in the Disclosure accompanying this Agreement. The initial rate on your account for certain types of transactions may be an introductory discounted rate (Introductory Rate) that is lower than the rate that would ordinarily apply for that type of transaction. If an Introductory Rate applies to your account, the rates and the period of time it will be effective is shown on the Disclosure accompanying this Agreement. After the Introductory Rate period expires, the periodic rate will automatically increase to the rates that would ordinarily apply for that type of transaction based on the terms of this Agreement.
