Surrender of Possession Upon the expiration or upon the sooner termination of this Lease, Tenant shall remove all of Tenant’s signs from the exterior of the Building and shall remove all of Tenant’s inventory, equipment, trade fixtures, furniture, supplies, wall decorations and other personal property (collectively, “Tenant’s FF&E”) from within the Leased Premises, including the Building and the Outside Areas, and shall vacate and surrender the Leased Premises, and all portions thereof, to Landlord broom clean and in good condition, reasonable wear and tear excepted. Tenant shall repair all damage to the Leased Premises, and all portions thereof, caused by Tenant’s removal of Tenant’s property. Tenant shall patch and refinish, to Landlord’s reasonable satisfaction, all penetrations made by Tenant or its employees to the floor, walls or ceiling of the Leased Premises, whether such penetrations were made with Landlord’s approval or not. Tenant shall repair or replace all stained or damaged ceiling tiles, wall coverings and floor coverings to the reasonable satisfaction of Landlord. Tenant shall repair all damage caused by Tenant to the exterior surface of the Building and the paved surfaces of the Outside Areas and, where necessary, replace or resurface same. Additionally, to the extent that Landlord shall have notified Tenant in writing at the time Landlord approved any improvements requiring Landlord approval that it desired to have such improvements removed at the expiration or sooner termination of the Lease (“Required Removables”), Tenant shall, upon the expiration or sooner termination of the Lease, remove the Required Removables and repair all damage caused by such removal. If Tenant fails to comply with the terms of this Pxxxxxxxx 0.0, Xxxxxxxx may perform Tenant’s obligations at Tenant’s expense, and Tenant shall be liable to Landlord for all reasonable costs incurred by Landlord in performing such obligations for Tenant (including, without limitation, reasonable costs of Landlord’s oversight of removal, repair and replacement work). Tenant shall pay to Landlord the amount of all costs so incurred within fifteen (15) days of Landlord’s delivery to Tenant of an invoice together with reasonable supporting information. Tenant shall indemnify Landlord against loss or liability resulting from delay by Tenant in surrendering the Leased Premises, including, without limitation, any claims made by any succeeding tenant or any losses to Landlord with respect to lost opportunities to lease to succeeding tenants.
Possession and Use Contractor may possess, use and reproduce Confidential Information solely for the Purpose. Contractor shall not use the Confidential Information for any other purpose.
Transfer of Possession Possession of the Property shall be transferred to Purchaser at the time of Closing subject to the Permitted Encumbrances.
TERM; POSSESSION The Term of this Lease shall commence on the Commencement Date and shall end on the Expiration Date, unless extended or sooner terminated in accordance with this Lease. If Landlord is delayed in delivering possession of all or any portion of the Premises to Tenant as of the Commencement Date, Tenant will take possession on the date Landlord delivers possession, which date will then become the Commencement Date (and the Expiration Date will be extended so that the length of the Term remains unaffected by such delay). Subject to this Section 4, Landlord shall not be liable for any loss or damage to Tenant resulting from any delay in delivering possession due to the holdover of any existing tenant or other circumstances outside of Landlord’s reasonable control. In the event that the Tenant Improvements are not Substantially Completed within one hundred (100) days following the date that Landlord receives a building permit to commence the Tenant Improvements in the Premises (the “Delivery Date”), subject to Tenant Delay or force majeure (in the event of either, the Delivery Date shall be extended by one (1) day for each one (1) day of Tenant Delay or force majeure), Landlord shall credit Tenant against Minimum Annual Rent due under this Lease an amount equal to the holdover portion of Tenant’s existing rental obligations under Tenant’s existing Lease actually incurred by Tenant following the Delivery Date, which Tenant represents to Landlord is equal to $17,031.13 per month. Notwithstanding anything in this Lease to the contrary, if the Commencement Date has not occurred on or before one hundred ninety (190) days following the date that Landlord receives a building permit for the Tenant Improvements, for any reason other than Tenant Delay or force majeure, then Tenant shall have the right to terminate this Lease by written notice to Landlord, as Tenant’s sole and exclusive remedy with respect to such delay, except as provided above, subject to Tenant giving Landlord thirty (30) days’ advance written notice of its intention to terminate this Lease if Substantial Completion shall not occur within such thirty (30) day period, in which event all amounts prepaid or deposited by Tenant hereunder shall be promptly returned to Tenant.
Surrender of Premises Ownership and Removal of Trade Fixtures 23.1 No act or thing done by Landlord or any agent or employee of Landlord during the Lease Term shall be deemed to constitute an acceptance by Landlord of a surrender of the Premises unless such intent is specifically acknowledged in writing by Landlord. The delivery of keys to the Premises to Landlord or any agent or employee of Landlord shall not constitute a surrender of the Premises or effect a termination of this Lease, whether or not the keys are thereafter retained by Landlord, and notwithstanding such delivery Tenant shall be entitled to the return of such keys at any reasonable time upon request until this Lease shall have been properly terminated. The voluntary or other surrender of this Lease by Xxxxxx, whether accepted by Landlord or not, or a mutual termination hereof, shall not work a merger, and at the option of Landlord shall operate as an assignment to Landlord of all subleases or subtenancies affecting the Premises or terminate any or all such subtenants or subtenancies. 23.2 Upon the expiration of the Lease Term, or upon any earlier termination of this Lease, Tenant shall, subject to the provisions of this Article 23 and section 8.2 above, quit and surrender possession of the Premises to Landlord in as good order and condition as when Xxxxxx took possession, ordinary wear and tear and damage thereto by fire or other casualty excepted. Upon such expiration or termination, Tenant shall, without expense to Landlord, remove or cause to be removed from the Premises all debris and rubbish, and such items of furniture, equipment, business and trade fixtures, free-standing cabinet work, movable partitions, voice and data cabling and other articles of personal property owned by Tenant or installed or placed by Tenant at its expense in the Premises, and such similar articles of any other persons claiming under Tenant, as Landlord may, in its sole discretion, require to be removed; provided, however, that in lieu of removing certain cabling, Tenant shall, at Landlord's request, abandon and leave in place, without additional payment to Tenant or credit against rent, any cabling (including conduit) designated by Landlord and installed in the Premises or elsewhere in the Building by or on behalf of Tenant (including all connections for such cabling), in a neat and safe condition in accordance with the requirements of all applicable Legal Requirements, including the National Electric Code or any successor statute, and terminated at both ends of a connector, properly labeled at each end and in each electrical closet and junction box. Any such property not so removed by Tenant shall be deemed to be abandoned and at the option of Landlord shall either (a) become Landlord's property without any payment to Tenant or (b) remain Tenant's property, but Landlord shall have the right to sell or otherwise dispose of such personal property in any commercially reasonable manner, provided that any proceeds realized from the sale of Tenant's property shall be applied first to offset all expenses of storage and sale, then credited against Tenant's outstanding obligations under this Lease (including, without limitation, past due rent amounts and any termination damages owing by Tenant to Landlord pursuant to Article 19 hereof), and any remaining balance shall be returned to Tenant.
Construction or Rehabilitation of Mortgaged Property No Mortgage Loan was made in connection with the construction or rehabilitation of a Mortgaged Property or facilitating the trade-in or exchange of a Mortgaged Property;
REMOVAL OF RECORDS FROM PREMISES Where performance of the Contract involves use by the Contractor (or the Contractor’s subsidiaries, affiliates, partners, agents or subcontractors) of Authorized User owned or licensed papers, files, computer disks or other electronic storage devices, data or records at Authorized User facilities or offices, or via remote access, the Contractor (or the Contractor’s subsidiaries, affiliates, partners, agents or subcontractors) shall not remotely access, modify, delete, copy or remove such Records without the prior written approval of the Authorized User. In no case, with or without the written approval of the Authorized User, can the Authorized User data be accessed, moved or sent outside the continental United States.
LOCATION AND DESCRIPTION OF THE PROPERTY The subject property is a single-storey terraced house bearing the postal address of Xx. 00, Xxxxxx 00/XX0, Xxxxxx Xxxxx Xxxxxxx, 00000 Xxxxxxx Xxxxx, Xxxxxx. The subject property will be sold on an “as is where is basis” and subject to a reserve price of RM310,000.00 (RINGGIT MALAYSIA THREE HUNDRED TEN THOUSAND ONLY) and subject to the Conditions of Sale and by way of an Assignment from the above Assignee/Bank subject to the consent being obtained by the Purchaser from the Developer and other relevant authorities if any, including all terms, conditions, stipulations and covenants which were and may be imposed by the Developer and the relevant authorities. Any arrears of quit rent, assessments and service or maintenance charges which may be lawfully due to any relevant authority or the Developer up to the date of auction sale of the property shall be paid out of the purchase money upon receipt of full purchase price. All other fees, costs and charges relating to the transfer and assignment of the property shall be borne by the successful Purchaser. Online bidders are further subject to the Terms & Conditions on xxx.xxxxxxxxxxxxxxxx.xxx. All intending bidders are required to deposit 10% of the fixed reserve price for the said property by Bank Draft or Cashier’s Order in favour of UOBM for KRISHNAMAL A/P MURLIGIAH & XXXXXXXXXXX A/L XXXXXXX or remit the same through online banking transfer, one (1) working day before auction date. The balance of the purchase money shall be paid by the Purchaser within one hundred and twenty (120) days from the date of auction sale to UNITED OVERSEAS BANK (MALAYSIA) BHD via Real Time Electronics Transfer of Funds and Securities (XXXXXX). For online bidders please refer to the Terms & Conditions on xxx.xxxxxxxxxxxxxxxx.xxx on the manner of payment of the deposit. FOR FURTHER PARTICULARS, please contact M/S HOE & MOIRA, of Xxxxx 000X (Xxxxx), 0xx Xxxxx, Xxxxx Xxxxxx Xxxxxx, Xxxxxxxxxx Xxxx, 00000 Xxxxxx, Xxxxxxxx. (Ref:H&M/MT/Z4P/CB23/16) Tel.: 00-000 0000, Fax: 00-000 0000) the Assignee herein or the undermentioned Auctioneer. Suite C-20-3A, Level 20, Block C, Megan Avenue II, / XXXXX XXXXX BIN XXXXXX 00, Xxxxx Xxx Xxxx Xxxx, 50450 Kuala Lumpur (Licensed Auctioneers) Tel No.: 00-0000 0000 Fax No.: 00-0000 0000 Our Ref: LIAN/UOB1035HM Website: xxx.xxxxxxxxxxxxxxxx.xxx E-mail: xxxx@xxxxxxxxxxxxxxxx.xxx [berkuatkuasa dari 1.11.2022, perniagaan perbankan pengguna (consumer banking business) CITIBANK BERHAD (No. Syarikat: 199401011410 (297089-M) telah dipindahmilik kepada xxx diletakhakkan kepada UOB di bawah Perintah Letakhak bertarikh 12.10.2022 melalui Mahkamah Tinggi Kuala Lumpur Saman Pemula No. WA-24NCC-903-09/2022] Dalam menjalankan xxx xxx kuasa xxxx telah diberikan kepada Pihak Pemegang Serahhak/Bank dibawah Perjanjian Kemudahan, Penyerahanhak xxx Surat Kuasa Wakil kesemuanya Bertarikh 09hb Julai, 2001 diantara Pihak Penyerahhak, Pihak Pelanggan xxx Pihak Pemegang Serahhak/Bank yang diperbuat dalam perkara diatas, adalah dengan ini diisytiharkan bahawa Pihak Pemegang Serahhak/Bank tersebut dengan bantuan Pelelong yang tersebut dibawah.
Selection of Subcontractors, Procurement of Materials and Leasing of Equipment The contractor shall not discriminate on the grounds of race, color, religion, sex, national origin, age or disability in the selection and retention of subcontractors, including procurement of materials and leases of equipment. The contractor shall take all necessary and reasonable steps to ensure nondiscrimination in the administration of this contract. a. The contractor shall notify all potential subcontractors and suppliers and lessors of their EEO obligations under this contract. b. The contractor will use good faith efforts to ensure subcontractor compliance with their EEO obligations.
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.