Change Orders Dispute Resolution
Change Orders Dispute Resolution Sample Clauses
Related to Change Orders Dispute Resolution
I2 Dispute Resolution The Parties shall attempt in good faith to negotiate a settlement to any dispute between them arising out of or in connection with the Contract within twenty (20) Working Days of either Party notifying the other of the dispute and such efforts shall involve the escalation of the dispute to the finance director of the Contractor and the commercial director of the Authority.
Formal Dispute Resolution 10.6.1 If the Parties are unable to resolve the dispute through the informal procedure described in Section 10.5, then either Party may invoke the formal Dispute Resolution procedures described in this Section 10.6. Unless agreed among all Parties, formal Dispute Resolution procedures, including arbitration or other procedures as appropriate, may be invoked not earlier than sixty (60) calendar days after receipt of the letter initiating Dispute Resolution under Section 10.3.
Initial Dispute Resolution If a dispute arises out of or relates to this Contract or its breach, the parties shall endeavor to settle the dispute first through direct discussions between the parties’ representatives who have the authority to settle the dispute. If the parties’ representatives are not able to promptly settle the dispute, they shall refer the dispute to the senior administrators of the parties who have the authority to settle the dispute, who shall meet within fourteen days thereafter. If the dispute is not settled by the senior administrators, the parties may submit the dispute to mediation in accordance with Paragraph 5.2.3.2.
Third Party Dispute Resolution The Consulting Firm shall (i) consider only the items that are then disputed by the parties, (ii) shall be bound by the terms of the Agreement and (iii) shall only make a determination of such disputed matters in favor of the proposal made by the Purchasers or the Sellers (as may be presented by each party to the Consulting Firm in writing, which shall be shared with the other party) and shall not make an independent proposal. The Consulting Firm shall prepare a written determination of any disputed matters and deliver the determination to the Purchasers and the Sellers within fifteen (15) Business Days after the date the Consulting Firm is engaged. Each party shall cooperate fully with the Consulting Firm, including by using reasonable best efforts to provide the information, data and work papers to the extent permitted by applicable Law, so as to enable the Consulting Firm to make a determination of the disputed items as quickly as practicable. The Corrective Action Plan shall be finalized in accordance with the Consulting Firm’s determination of the disputed matters.
CENTRAL DISPUTE RESOLUTION PROCESS The following process pertains exclusively to disputes and grievances on central matters that have been referred to the central process. In accordance with the School Board Collective Bargaining Act, 2014 central matters may also be grieved locally, in which case local grievance processes will apply. In the event that central language is being grieved locally, the local parties shall provide the grievance to their respective central agents.
Dispute Resolution Process Any claim, dispute or other matter in question not resolved by the process identified in Paragraph
Dispute Resolution All or any disputes arising out or touching upon or in relation to the terms and conditions of this Agreement, including the interpretation and validity of the terms thereof and the respective rights and obligations of the Parties, shall be settled amicably by mutual discussion, failing which the same shall be settled through the adjudicating officer appointed under the Act.
Dispute Resolution; Arbitration This Agreement evidences a transaction involving interstate commerce. Any disputes arising from this Agreement shall be decided by binding arbitration which shall be conducted, at the request of any party, in New York, New York, before one arbitrator designated by the American Arbitration Association (the "AAA"), in accordance with the Commercial Arbitration Rules of the AAA, and to the maximum extent applicable, the United States Arbitration Act (Title 9 of the United States Code). Notwithstanding anything in this Agreement to the contrary, any party may proceed to a court of competent jurisdiction to obtain equitable relief at any time. An arbitrator shall have no authority to award punitive damages or other damages not measured by the prevailing party's actual damages. To the maximum extent practicable, an arbitration proceeding under this Agreement shall be concluded within 180 days of the filing of the dispute with the AAA. This arbitration clause shall survive any termination, amendment, or expiration of the Agreement and if any provision of this arbitration clause is found to be unenforceable, the remaining parts of the arbitration clause shall not be affected and shall remain fully enforceable.
Informal Dispute Resolution (a) Prior to the initiation of formal dispute resolution procedures (i.e., arbitration), the Parties shall first attempt to resolve their dispute at the senior manager level. If that level of dispute resolution is not successful, the Parties shall proceed informally, as follows: (i) Upon the written request of either Party, each Party shall appoint a designated representative who does not otherwise devote substantially full time to performance under this Agreement, whose task it will be to meet for the purpose of endeavoring to resolve such dispute. (ii) The designated representatives shall meet as often as the Parties reasonably deem necessary in order to gather and furnish to the other all information with respect to the matter in issue that the Parties believe to be appropriate and germane in connection with its resolution. The representatives shall discuss the problem and attempt to resolve the dispute without the necessity of any formal proceeding. (iii) During the course of discussion, all reasonable requests made by one Party to another for non-privileged non-confidential information reasonably related to this Agreement shall be honored so that each of the Parties may be fully advised of the other's position. (iv) The specific format for the discussions shall be left to the discretion of the designated representatives. (b) Prior to instituting formal proceedings, the Parties will first have their chief executive officers meet to discuss the dispute. This requirement shall not delay the institution of formal proceedings past any statute of limitations expiration or for more than fifteen (15) days. (c) Subject to Subsection (b), formal proceedings for the resolution of a dispute may not be commenced until the earlier of: (i) The designated representatives concluding in good faith that amicable resolution through continued negotiation of the matter does not appear likely; or (ii) Thirty (30) days after the initial written request to appoint a designated representative pursuant to Subsection (a), above, (this period shall be deemed to run notwithstanding any claim that the process described in this Section 11.2 was not followed or completed). (d) This Section 11.2 shall not be construed to prevent a Party from instituting, and a Party is authorized to institute, formal proceedings earlier to avoid the expiration of any applicable limitations period, or to preserve a superior position with respect to other creditors or as provided in Section 11.6(a).
Informal Dispute Resolution Process 1. In the event there is a dispute under this Centralized Contract, the Contractor, OGS and Authorized User agree to exercise their best efforts to resolve the dispute as soon as possible. The Contractor, OGS and Authorized User shall, without delay, continue to perform their respective obligations under this Centralized Contract which are not affected by the dispute. Primary responsibility for resolving any dispute arising under this Centralized Contract shall rest with the Authorized User’s Contractor Coordinators and the Contractor’s Account Executive and the State & Local Government Regional General Manager. 2. In the event the Authorized User is dissatisfied with the Contractor’s Products provided under this Centralized Contract, the Authorized User shall notify the Contractor in writing pursuant to the terms of the Contract. In the event the Contractor has any disputes with the Authorized User, the Contractor shall so notify the Authorized User in writing. If either party notifies the other of such dispute, the other party shall then make good faith efforts to solve the problem or settle the dispute amicably, including meeting with the party’s representatives to attempt diligently to reach a satisfactory result through negotiation. 3. If negotiation between the Contractor and Authorized User fails to resolve any such dispute to the satisfaction of the parties within fourteen (14) business days or as otherwise agreed to by the Contractor and Authorized User, of such notice, then the matter shall be submitted to the State's Contract Administrator and the Contractor’s senior executive officer representative. Such representatives shall meet in person and shall attempt in good faith to resolve the dispute within the next fourteen (14) business days or as otherwise agreed to by the parties. This meeting must be held before either party may seek any other method of dispute resolution, including judicial or governmental resolutions. Notwithstanding the foregoing, this section shall not be construed to prevent either party from seeking and obtaining temporary equitable remedies, including injunctive relief. 4. The Contractor shall extend the informal dispute resolution period for so long as the Authorized User continues to make reasonable efforts to cure the breach, except with respect to disputes about the breach of payment of fees or infringement of its or its licensors’ intellectual property rights.
