Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Changes to the Department's Requirements 5.1 The Department shall notify the Contractor of any material change to the Department's requirement under this Contract.
Human and Financial Resources to Implement Safeguards Requirements 6. The Borrower shall make available necessary budgetary and human resources to fully implement the EMP and the RP.
Required Procurement Procedures for Obtaining Goods and Services The Grantee shall provide maximum open competition when procuring goods and services related to the grant-assisted project in accordance with Section 287.057, Florida Statutes.
Requirement to Utilize HUB Compliance Reporting System Pursuant to Texas Administrative Code, Title 34, Part 1, Sections 20.285(f) and 20.287(b), TFC administers monthly administration HSP-PAR compliance monitoring through its HUB Compliance Reporting System commonly known as B2G. PSP and PSP’s subcontractors/subconsultants shall submit required PAR information into the B2G system. Any delay in the timely submission of PAR information into the B2G system will be treated as an invoicing error subject to dispute under Texas Government Code Section 2251.042.
Technical Standards Applicable to a Wind Generating Plant i. Low Voltage Ride-Through (LVRT) Capability A wind generating plant shall be able to remain online during voltage disturbances up to the time periods and associated voltage levels set forth in the standard below. The LVRT standard provides for a transition period standard and a post-transition period standard.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
Switching System Hierarchy and Trunking Requirements For purposes of routing ECI traffic to Verizon, the subtending arrangements between Verizon Tandem Switches and Verizon End Office Switches shall be the same as the Tandem/End Office subtending arrangements Verizon maintains for the routing of its own or other carriers’ traffic (i.e., traffic will be routed to the appropriate Verizon Tandem subtended by the terminating End Office serving the Verizon Customer). For purposes of routing Verizon traffic to ECI, the subtending arrangements between ECI Tandem Switches and ECI End Office Switches shall be the same as the Tandem/End Office subtending arrangements that ECI maintains for the routing of its own or other carriers’ traffic.
Changes to tariffs and charges (a) If we vary our standing offer prices, we will publish the variation in a newspaper and on our website at least 10 business days before it starts. We will also include details with your next bill if the variation affects you.
Changes to Services The Parties acknowledge and agree that there will be changes to the scope of the Services during the Contract Period. The Customer may amend the Stories that are comprised within the Minimum Marketable Features of a Release at any time during the Release at no additional charge and without adopting the Change Control Procedure set out in Clause 28 above provided that: the Customer shall not be entitled to make any changes to the Stories that form the subject of a Sprint following the mutual agreement by the Parties of the Sprint Plan for that Sprint; new Stories and/or changes to existing Stories may only be introduced if: existing Stories with an equivalent number of Story Points are removed; or existing Stories are reduced in size by the equivalent number of Story Points, such that the total number of Story Points for the Release remains constant throughout the Release. The Supplier shall consider any request by the Customer to increase the number of Story Points for a Release, and may, subject to the Change Control Procedure set out at Clause 28, agree to such request.
