Early Occupancy If Tenant occupies the Property prior to the Commencement Date, Tenant's occupancy of the Property shall be subject to all of the provisions of this Lease. Early occupancy of the Property shall not advance the expiration date of this Lease. Tenant shall pay Base Rent and all other charges specified in this Lease for the early occupancy period.
Maximum Occupancy No more than two (2) guests per one (1) resident (who is present) are permitted in a student room/suite/apartment at any given time unless otherwise approved by the University (Residential Life).
Ready for Occupancy For purposes of Section 1.3.2 of this Agreement, the Premises shall be deemed “Ready for Occupancy” upon the substantial completion of the Tenant Improvement Work. Subject to Section 4.2 below, the Tenant Improvement Work shall be deemed to be “substantially complete” upon the completion of the Tenant Improvement Work pursuant to the Approved Construction Drawings (as reasonably determined by Landlord), with the exception of any details of construction, mechanical adjustment or any other similar matter the non-completion of which does not materially interfere with Tenant’s use of the Premises.
Base Monthly Rent Commencing on the Commencement Date and continuing throughout the Lease Term, Tenant shall pay to Landlord the Base Monthly Rent set forth in Section K of the Summary.
Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).
Minimum Monthly Rent (Section 1.5): Tenant shall pay to Landlord Minimum Monthly Rent for the Premises during the Extended Term in accordance with the schedule and in the amount set forth below: 01/01/13-07/31/13 $ 1,776.25 per month $ 8,645.00 per month $ 10,421.25 per month 08/01/13-07/31/14 $ 1,827.00 per month $ 8,892.00 per month $ 10,719.00 per month 08/01/14-07/31/15 $ 1,877.75 per month $ 9,139.00 per month $ 11,016.75 per month
Monthly Rent a. Commencing as of the Commencement Date, and continuing thereafter on or before the first day of each calendar month during the term hereof, Tenant shall pay to Landlord, as monthly rent for the Premises, the Monthly Rent specified in Paragraph 2 above. If Tenant’s obligation to pay Monthly Rent hereunder commences on a day other than the first day of a calendar month, or if the term of this Lease terminates on a day other than the last day of a calendar month, then the Monthly Rent payable for such partial month shall be appropriately prorated on the basis of a thirty (30)-day month. Monthly Rent and the Additional Rent specified in Paragraph 7 shall he paid by Tenant to Landlord, in advance, without deduction, offset, prior notice or demand, in immediately available funds of lawful money of the United States of America, or by good check as described below, to the lockbox location designated by Landlord, or to such other person or at such other place as Landlord may from time to time designate in writing. Payments made by check must be drawn either on a California financial institution or on a financial institution that is a member of the federal reserve system. Notwithstanding the foregoing, Tenant shall pay to Landlord together with Tenant’s execution of this Lease an amount equal to the Monthly Rent payable for the first full calendar month of the Lease term after Tenant’s obligation to pay Monthly Rent shall have commenced hereunder, which amount shall be applied to the Monthly Rent first due and payable hereunder. b. All amounts payable by Tenant to Landlord under this Lease, or otherwise payable in connection with Tenant’s occupancy of the Premises, in addition to the Monthly Rent hereunder and Additional Rent under Paragraph 7, shall constitute rent owed by Tenant to Landlord hereunder. c. Any rent not paid by Tenant to Landlord when due shall bear interest from the date due to the date of payment by Tenant at an annual rate of interest (the “Interest Rate”) equal to the lesser of (i) twelve percent (12%) per annum or (ii) the maximum annual interest rate allowed by law on such due date for business loans (not primarily for personal, family or household purposes) not exempt from the usury law. Notwithstanding the foregoing, Landlord shall give Tenant notice of non-payment of rent when due and five (5) days after delivery of such notice to cure such non-payment once in each calendar year before assessing interest in such calendar year pursuant to this Paragraph 5.c. Failure by Tenant to pay rent when due, including any interest accrued under this subparagraph, shall constitute an Event of Default (as defined in Paragraph 25 below) giving rise to all the remedies afforded Landlord under this Lease and at law for nonpayment of rent. d. No security or guaranty which may now or hereafter be furnished to Landlord for the payment of rent due hereunder or for the performance by Tenant of the other terms of this Lease shall in any way be a bar or defense to any of Landlord’s remedies under this Lease or at law. e. Notwithstanding anything to the contrary in this Lease: (i) in no event may any rent under this Lease be based in whole or in part on the income or profits derived from the Premises, except for percentage rent based on gross (not net) receipts or sales; (ii) if the holder of a Superior Interest (as defined in Paragraph 21 below) succeeds to Landlord’s interest in the Lease (“Successor Landlord”) and the Successor Landlord is advised by its counsel that all or any portion of the rent payable under this Lease is or may be deemed to be “unrelated business income” within the meaning of the Internal Revenue Code or regulations issued thereunder, such Successor Landlord may, at its option, unilaterally amend the calculation of rent so that none of the rent payable to Landlord under the Lease will constitute “unrelated business income,” but the amendment will not increase Tenant’s payment obligations or other liability under this Lease or reduce the Landlord’s obligations under this Lease and (iii) upon the Successor Landlord’s request, Tenant shall execute any document such holder deems necessary to effect the foregoing amendment to this Lease.
Basic Rent The periodic rent payable for the Aircraft throughout the Basic Term pursuant to Section 3.02 of the Lease, adjusted pursuant to Article 3 of the Lease. Basic Term. The period commencing at the beginning of the day on the Delivery Date and ending at the end of the day on July 15, 2023, or such earlier date on which the Lease shall be terminated as provided therein.
PARTIAL OCCUPANCY OR USE 9.9.1 The Owner may occupy or use any completed or partially completed portion of the Work at any stage when such portion is designated by separate agreement with the Contractor, provided such occupancy or use is consented to by the insurer as required under Paragraph 11.3.1.5, the surety, and authorized by public authorities having jurisdiction over the Project. Such partial occupancy or use may commence whether or not the portion is substantially complete, provided the Owner and Contractor have accepted in writing the responsibilities assigned to each of them for payments, retainage, if any, security, maintenance, heat, utilities, damage to the Work and insurance, and have agreed in writing concerning the period for correction of the Work and commencement of warranties required by the Contract Documents. When the Contractor considers a portion substantially complete, the Contractor shall prepare and submit a list to the Architect as provided under Paragraph 9.8.2. Consent of the Contractor to partial occupancy or use shall not be unreasonably withheld. 9.9.2 Immediately prior to partial occupancy or use, the Owner, Contractor and Architect shall jointly inspect the area to be occupied or portion of the Work to be used in order to determine and record the condition of the Work. 9.9.3 Partial occupancy or use of a portion or portions of the Work shall not constitute acceptance of Work not complying with the requirements of the Contract Documents.
Minimum Rent The defined term “Minimum Rent” set forth in Section 1.66 of the Lease is deleted in its entirety and replaced with the following:
