Notice to Proceed - Land Acquisition The acquisition of the Land shall not occur until the Director has issued a written Notice to Proceed for land acquisition to the Recipient (the "Notice to Proceed"). Such Notice to Proceed will not be issued until the Director has received a Request to Proceed acceptable to the Director and is assured that the Recipient has complied with all requirements for the approval of a grant under Revised Code Sections 164.20 through 164.27 and any requirements for land acquisition set forth in this Agreement, including without limitation the OPWC's approval of the proposed Deed Restrictions and Title Agent. The Notice to Proceed also shall specify the time frame for the Closing.
Land Acquisition Disbursement To initiate the purchase of the Land, the Recipient must first complete and submit a written Request to Proceed to the Director prior to Closing. The Request to Proceed must name the proposed Title Agent and must indicate the amount of Funds requested from the OPWC for the land acquisition, including expected settlement costs, based upon the participation ratio and the amount of funds expected from any Matching Funds. The Request to Proceed must contain as attachments: (a) a copy of the proposed Deed Restrictions; (b) a copy of the executed purchase agreement with respect to, or such other agreement to convey an interest in, the Land between the Recipient and the Land owner; (c) a copy of the performed appraisal according to the specifications provided by the Director; (d) evidence satisfactory to the Director that Recipient will acquire marketable title to the Land at Closing; and (d) if the Recipient desires to elect the pre-closing option described below (i) a copy of the signed escrow agreement among Recipient, Title Agent and the OPWC, executed by Recipient and Title Agent, substantially in the form of Appendix F of this Agreement (the "Escrow Agreement") and (ii) if the Title Agent is an agent for a title insurance company, rather than a title company itself, a closing protection letter issued by the title insurance company to the OPWC. Funds for land acquisition shall be disbursed to the Recipient, as part of a grant to the Recipient pursuant to Revised Code Sections 164.20 through 164.27, pursuant to the pre-closing option and/or the reimbursement option, as described in subsections 5(a) and 5(b), respectively.
Investments and Acquisitions Neither the Company nor any of its Subsidiaries shall have outstanding, acquire, commit itself to acquire or hold any Investment (including any Investment consisting of the acquisition of any business) (or become contractually committed to do so) except for the following: (a) Investments of the Company and its Subsidiaries in Wholly Owned Subsidiaries (a) which are domestic Subsidiaries as of the date of this Agreement or (b) which become domestic Wholly Owned Subsidiaries after the Closing Date and become Guarantors to the extent required by Section 10.09; provided, however, that the aggregate book value of all assets (other than intercompany obligations) owned by Immaterial Subsidiaries shall not exceed $10,000,000. (b) Intercompany loans and advances from any Subsidiary to the Company or any Guarantor that, in the case of loans or advances from Foreign Subsidiaries, are subordinated to the Obligations in accordance with the Foreign Subsidiary Subordination Agreement. (c) Investments in Cash Equivalents. (d) Guarantees permitted by Section 6.06. (e) So long as immediately before and after giving effect thereto no Default exists, and so long as the Company (if the Company is party thereto) or a Guarantor (if the Company is not party thereto) is the surviving entity, the Company and its Subsidiaries may acquire another entity in the same line of business as the Company as described in Section 6.02(a) if: (i) at all times when the Consolidated Leverage Ratio is greater than 2.50 for the most recent period of four consecutive fiscal quarters (calculated on a pro forma basis giving effect to the proposed acquisition as if such acquisition had been consummated at the beginning of such period) for which financial reports have been (or are required to have been) furnished to the Lenders in accordance with Sections 6.04(a) or 6.04(b), the purchase price for all such acquisitions permitted pursuant to this clause (e)(i) does not exceed, except with the consent of the Required Lenders, $100,000,000 in cash (excluding consideration consisting of Capital Stock, the proceeds of the issuance of Capital Stock or Subordinated Indebtedness) in the aggregate over the term of the Agreement; (ii) at all times when the Consolidated Leverage Ratio is less than or equal to 2.50 for the most recent period of four consecutive fiscal quarters (calculated on a pro forma basis giving effect to the proposed acquisition as if such acquisition had been consummated at the beginning of such period) for which financial reports have been (or are required to have been) furnished to the Lenders in accordance with Sections 6.04(a) or 6.04(b), the Company and its Subsidiaries may make unlimited acquisitions; provided, however that in the event a transaction permitted pursuant to this clause (e)(ii) would, on a pro forma basis after giving effect thereto, cause the Consolidated Leverage Ratio to exceed 2.50, the portion of the cash purchase price with respect to such transaction attributed to causing the Consolidated Leverage Ratio to be greater than 2.50 shall only be permitted to be paid to the extent the Company has sufficient availability in the $100,000,000 basket set forth in clause (e)(i) to take into account such excess amount; provided, further, that with respect to any acquisition permitted pursuant to this Section 6.08(e)(ii), (i) the acquisition must be approved by the target entity’s board of directors, (ii) the Company must be in compliance with the Computation Covenants immediately after giving effect to such acquisition, (iii) the acquired entity must not have any environmental liabilities which, after giving effect to such acquisition, would reasonably be expected to result in a Material Adverse Effect and (iv) any Subsidiary acquired under this Section 6.08(e) (other than (a) a Foreign Subsidiary or (b) any Immaterial Subsidiary if the aggregate book value of the assets (other than intercompany obligations) of all Immaterial Subsidiaries acquired under this Section 6.08(e) since the Closing Date does not exceed $10,000,000) shall guarantee the Obligations, as contemplated by Section 10.09. (f) So long as immediately before and after giving effect thereto no Default exists, the Company and its Subsidiaries may make (i) Investments in Unrestricted Affiliates engaged in businesses contemplated by Section 6.02(a) and (ii) Investments consisting of contributions of Property to Unrestricted Affiliates, in an aggregate amount for all such Investments permitted pursuant to this clause (f) (calculated at net book value at the time of such Investment), when taken together with the aggregate amount of all Dispositions permitted pursuant to Section 6.10(e), not to exceed $100,000,000. (g) Loans or advances to employees of the Company in an amount not to exceed (i) $1,000,000 in the aggregate outstanding at any time for the purchase of capital stock of the Company and (ii) $5,000,000 in the aggregate outstanding at any time for all other purposes. (h) So long as immediately before and after giving effect thereto no Default exists, Investments of the Company and its Subsidiaries in foreign Wholly Owned Subsidiaries; provided, however, that other than with respect to Investments outstanding as of the Closing Date as described on Schedule 6.08(h), (i) such Investments shall not involve the transfer of substantial noncash assets from the Company and its domestic Subsidiaries to its Foreign Subsidiaries other than up to $35,000,000 in book value of foreign patents and foreign trademarks; and (ii) net cash Investments of the Company and its domestic Subsidiaries in Foreign Subsidiaries made pursuant to this Section 6.08(h) at any one time outstanding shall not exceed $125,000,000 in the aggregate. (i) So long as immediately before and after giving effect thereto no Default exists, and provided that the Company complies with Section 10.09, the Company may create a Wholly Owned Subsidiary that constitutes a holding company for the Company’s European Subsidiaries.
Mergers, Acquisitions, Etc Merge or consolidate with any other entity or acquire all or a material part of the assets of any person or entity, or form or create any new Subsidiary or affiliate, or commence operations under any other name, organization, or entity, including any joint venture.
Limited Condition Acquisitions Notwithstanding anything in this Agreement or any Loan Document to the contrary, when calculating any applicable ratio or any basket based on Consolidated EBITDA or total assets, or determining other compliance with this Agreement (including the determination of compliance with any provision of this Agreement which requires that no Default or Event of Default has occurred, is continuing or would result therefrom, but excluding Section 4.02 to the extent set forth therein) in connection with a Specified Transaction undertaken in connection with the consummation of a Limited Condition Acquisition, the date of determination of such ratio or any basket based on Consolidated EBITDA or total assets, and determination of whether any Default or Event of Default has occurred, is continuing or would result therefrom or other applicable covenant shall, at the option of the Borrower (the Borrower’s election to exercise such option in connection with any Limited Condition Acquisition, an “LCA Election”), be deemed to be the date the definitive agreements for such Limited Condition Acquisition are entered into (the “LCA Test Date”) and if, after such ratios and other provisions are measured on a Pro Forma Basis after giving effect to such Limited Condition Acquisition and the other Specified Transactions to be entered into in connection therewith (including any incurrence of Indebtedness and the use of proceeds thereof) as if they occurred at the beginning of the applicable Test Period ending prior to the LCA Test Date, the Borrower could have taken such action on the relevant LCA Test Date in compliance with such ratios and provisions, such provisions shall be deemed to have been complied with; provided that no such acquisition shall constitute a Limited Condition Acquisition unless the Payment Conditions are satisfied on a Pro Forma Basis on the applicable LCA Test Date. For the avoidance of doubt, (x) if any of such ratios are exceeded as a result of fluctuations in such ratio (including due to fluctuations in Consolidated EBITDA of the Borrower and its Subsidiaries) at or prior to the consummation of the relevant Limited Condition Acquisition, such ratios and other provisions will not be deemed to have been exceeded as a result of such fluctuations solely for purposes of determining whether the Limited Condition Acquisition is permitted hereunder and (y) such ratios and other provisions shall not be tested at the time of consummation of such Limited Condition Acquisition or related Specified Transactions. If the Borrower has made an LCA Election for any Limited Condition Acquisition, then in connection with any subsequent calculation of any ratio or basket availability with respect to any other Specified Transaction on or following the relevant LCA Test Date and prior to the earlier of the date on which such Limited Condition Acquisition is consummated or the date that the definitive agreement for such Limited Condition Transaction is terminated or expires without consummation of such Limited Condition Acquisition, any such ratio or basket shall be calculated on a Pro Forma Basis assuming such Limited Condition Acquisition and other transactions in connection therewith (including any incurrence of Indebtedness and the use of proceeds thereof) have been consummated.
Loans, Acquisitions and Guaranties Loan, invest in or advance money or assets to any other person, enterprise or entity, (2) purchase, create or acquire any interest in any other enterprise or entity, or (3) incur any obligation as surety or guarantor other than in the ordinary course of business.
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
Land Acquisition Reimbursement for the costs associated with acquiring interest and/or rights to real property (including access rights through ingress/egress easements, leases, license agreements, or other site access agreements; and/or obtaining record title ownership of real property through purchase) must be supported by the following, as applicable: Copies of Property Appraisals, Environmental Site Assessments, Surveys and Legal Descriptions, Boundary Maps, Acreage Certification, Title Search Reports, Title Insurance, Closing Statements/Documents, Deeds, Leases, Easements, License Agreements, or other legal instrument documenting acquired property interest and/or rights. If land acquisition costs are used to meet match requirements, Xxxxxxx agrees that those funds shall not be used as match for any other Agreement supported by State or Federal funds.
Early Construction of Base Case Facilities Developer may request Connecting Transmission Owner to construct, and Connecting Transmission Owner shall construct, subject to a binding cost allocation agreement reached in accordance with Attachment S to the ISO OATT, including Section 25.8.7 thereof, using Reasonable Efforts to accommodate Developer’s In-Service Date, all or any portion of any System Upgrade Facilities or System Deliverability Upgrades required for Developer to be interconnected to the New York State Transmission System which are included in the Base Case of the Class Year Study for the Developer, and which also are required to be constructed for another Developer, but where such construction is not scheduled to be completed in time to achieve Developer’s In-Service Date.
CONSTRUCTION OF THE PROJECT/ APARTMENT The Allottee has seen the proposed layout plan, specifications, amenities and facilities of the [Apartment/Plot] and accepted the floor plan, payment plan and the specifications, amenities and facilities [annexed along with this Agreement] which has been approved by the competent authority, as represented by the Promoter. The Promoter shall develop the Project in accordance with the said layout plans, floor plans and specifications, amenities and facilities. Subject to the terms in this Agreement, the Promoter undertakes to strictly abide by such plans approved by the competent Authorities and shall also strictly abide by the bye-laws, FAR and density norms and provisions prescribed by the [Please insert the relevant State laws]and shall not have an option to make any variation /alteration / modification in such plans, other than in the manner provided under the Act, and breach of this term by the Promoter shall constitute a material breach of the Agreement.
