CLAIMS FOR DAMAGES 7.4.1 Should either party to the Contract suffer injury or damage to person or property because of any act or omission of the other party or of any of his / her employees, agents or others for whose acts he / she is legally liable, claim shall be made in writing to such other party within a reasonable time after the first observance of such injury or damage.
CLAIMS FOR ADDITIONAL COST 12.3.1 If the Contractor wishes to make a claim for an increase in the Contract Sum, he shall give the Architect written notice thereof within twenty days after the occurrence of the event giving rise to such claim. This notice shall be given by the Contractor before proceeding to execute the Work, except in an emergency endangering life or property in which case the Contractor shall proceed in accordance with Paragraph 10.3 of these General Conditions. No such claim shall be valid unless so made. If the State and the Contractor cannot agree on the amount of the adjustment in the Contract Sum, it shall be determined by the Architect. Any change in the Contract Sum resulting from such claim shall be authorized by Change Order.
12.3.2 If the Contractor claims that additional cost is involved because of, but not limited to, (1) any order by the State to stop the Work pursuant to Paragraph 3.3 of these General Conditions where the Contractor was not at fault, or (2) failure of payment by the State pursuant to Paragraph 9.7(of these General Conditions), the Contractor shall make such claim as provided in Subparagraph 12.3.1 of this agreement.
12.3.3 The Architect will have authority to order minor changes in the Work not involving an adjustment in the Contract Sum or an extension of the Contract Time and not inconsistent with the intent of the Contract Documents. Such changes shall be effected by written order and shall be binding on the State and Contractor within 10 days unless the Contractor or the State objects to the change in writing.
Mechanisms for Cooperation Pursuant to Article 149 (Objectives), the Parties hereby establish a Committee on Cooperation comprising representatives of each Party.
Claims for Benefits All Claims for benefits will be deemed to have been filed on the date received by AvMed. If a Claim is a Pre-Service or Urgent Care Claim, a Health Professional with knowledge of the Member’s Condition will be permitted to act as the Member’s authorized representative, and will be notified of all approvals on the Member’s behalf.
Procedures for Third Party Claims In the case of any claim for indemnification arising from a claim of a third-party other than an Infringement Claim subject to Section 13.3 above (a “Third-Party Claim”), a party seeking indemnification hereunder (each an “Indemnified Party”) shall give prompt written notice, following such Indemnified Party’s receipt of such claim or demand, to the party from which indemnity is sought (each an “Indemnifying Party”) of any claim or demand of which such Indemnified Party has knowledge and as to which it may request indemnification hereunder; provided, however, that failure to give such notice will not affect such Indemnified Party’s rights hereunder unless, and then solely to the extent that, the rights of the Indemnifying Parties from whom indemnity is sought are prejudiced as a result of such failure. The Indemnifying Party shall have the right (and if it elects to exercise such right, shall do so within twenty (20) days after receiving such notice from the Indemnified Party) to defend and to direct the defense against any such claim or demand, in its name or in the name of the Indemnified Party, as the case may be, at the expense of the Indemnifying Party, and with counsel selected by the Indemnifying Party; provided, that the Indemnifying Party shall be entitled to assume control of the defense of such action only if the Indemnifying Party acknowledges in writing its indemnity obligations and assumes and holds the Indemnified Party harmless from and against all Losses resulting from such Third-Party Claim; and provided further that the Indemnifying Party shall not be entitled to assume control of such defense if (i) the Indemnifying Party shall not have notified the Indemnified Party of its exercise of its right to defend such Third-Party claim within such twenty (20) day period; (ii) such claim or demand seeks an injunction or other equitable relief against the Indemnified Party, (iii) the Indemnified Party shall have reasonably concluded that (x) there is a conflict of interest between the Indemnified Party and the Indemnifying Party in the conduct of the defense of such claim or demand or (y) the Indemnified Party has one or more defenses not available to the Indemnifying Party, (iv) such claim relates to or arises in connection with any criminal proceeding, action, indictment, allegation or investigation, or (v) the appropriate court rules that the Indemnifying Party failed or is failing to vigorously prosecute or defend such Third-Party Claim. Notwithstanding anything in this Agreement to the contrary, the Indemnified Party shall, at the expense of the Indemnifying Party, cooperate with the Indemnifying Party, and keep the Indemnifying Party fully informed, in the defense of such claim or demand. The Indemnified Party shall have the right to participate in the defense of any claim or demand with counsel employed at its own expense; provided, however, that, in the case of any claim or demand described in clause (i) or (ii) of the second preceding sentence or as to which the Indemnifying Party shall not in fact have employed counsel to assume the defense of such claim or demand, the reasonable fees and disbursements of such counsel shall be at the expense of the Indemnifying Party. The Indemnifying Party shall have no indemnification obligations with respect to any such claim or demand which shall be settled by the Indemnified Party without the prior written consent of the Indemnifying Party, which consent shall not be unreasonably withheld, delayed or conditioned. The Indemnifying Party shall not settle any such claim without the prior written consent of the Indemnified Party (which consent shall not be unreasonably withheld, delayed or conditioned if such settlement is accompanied by a document releasing the Indemnified Party from all liability with respect to the matter in controversy that is binding, valid and enforceable against all applicable Parties). Notwithstanding the foregoing, if the Indemnified Party fails to object to the settlement within five (5) Business Days of receipt of a written notice from the Indemnifying Party containing the terms and condition of such settlement, the Indemnified Party shall be deemed to have consented to the settlement.
Claims and Suits (a) The Receiver shall have the right, in its discretion, to (i) defend or settle any claim or suit against the Assuming Bank with respect to which the Receiver has indemnified the Assuming Bank in the same manner and to the same extent as provided in Article XII, and (ii) defend or settle any claim or suit against the Assuming Bank with respect to any Liability Assumed, which claim or suit may result in a loss to the Receiver arising out of or related to this Agreement, or which existed against the Failed Bank on or before Bank Closing. The exercise by the Receiver of any rights under this Section 9.3(a) shall not release the Assuming Bank with respect to any of its obligations under this Agreement.
(b) In the event any action at law or in equity shall be instituted by any Person against the Receiver and the Corporation as codefendants with respect to any asset of the Failed Bank retained or acquired pursuant to this Agreement by the Receiver, the Receiver agrees, at the request of the Corporation, to join with the Corporation in a petition to remove the action to the United States District Court for the proper district. The Receiver agrees to institute, with or without joinder of the Corporation as coplaintiff, any action with respect to any such retained or acquired asset or any matter connected therewith whenever notice requiring such action shall be given by the Corporation to the Receiver.
Claims Submission Unless otherwise prohibited by federal or state law, Provider will submit Clean Claims for all Covered Services to BCBSM within one hundred eighty (180) days of the date of service.
Claims for Consequential Damages The Owner retains its right to claim for consequential damages in the event the Design Professional fails to perform under this Contract.
Claims Process We intend to appoint the senior trustee as the authorized representative to take action on behalf of holders of each series of the notes under the guarantee. The authorized representative will agree to make a demand of the FDIC upon our failure to pay interest or principal on any series of the notes when due. As provided in the FDIC’s regulations, a holder will also have the option to elect not to be represented by the authorized representative. Upon our failure to pay interest or principal, the authorized representative and a holder that has elected not to be so represented must follow the FDIC’s required procedures for making a demand under the guarantee. In addition to the procedures described below, the authorized representative will be required when making a demand, to the extent not previously provided in the master agreement, to provide the FDIC with information regarding its authority, including: its financial and organizational capacity to act as representative, its exclusive authority to act on behalf of each noteholder and its fiduciary responsibility to the noteholders when acting as such, as established by the senior indenture, and its authority to make the assignment of each noteholder’s right, title, and interest in the notes to the FDIC. Any demand under the guarantee must be accompanied by a proof of claim, satisfactory in form and content to the FDIC, which includes evidence of the occurrence of a payment default and the claimant’s ownership of the applicable notes. The claimant must provide to the FDIC an assignment, satisfactory in form and content to the FDIC, of the noteholder’s right, title and interest in the notes to the FDIC and the transfer to the FDIC of any claim in any insolvency proceeding against us. The assignment must also grant to the FDIC the right to receive any and all distributions on the note from the proceeds of any bankruptcy. If a holder receives a payment on a note from a bankruptcy, any obligation of the FDIC under the guarantee would be reduced proportionally. Demands must be made by the authorized representative or by a holder that elects not to be represented by the authorized representative within 60 days of the occurrence of the payment default. Upon payment by the FDIC of any amount under the guarantee, the FDIC will be subrogated to the rights of the recipient noteholder against us, including in respect of any insolvency proceeding, to the extent of such payment.
Claims for Additional Time If the Contractor wishes to make a Claim for an increase in the Contract Time, written notice as provided herein shall be given. The Contractor’s Claim shall include an estimate of cost and of probable effect of delay on progress of the Work. In the case of a continuing delay, only one Claim is necessary.
