Claims for Incidental Migration Sample Clauses

Claims for Incidental Migration the Incidental Migration of Hazardous Materials that existed as of the applicable Phase Closing Date from any portion of the NAS Alameda property acquired by the City to the applicable Phase, whether such Incidental Migration occurs prior to or after the applicable Phase Closing Date. Notwithstanding the foregoing provisions of this Section or anything to the contrary herein, nothing herein shall negate, limit, release, or discharge the City Released Parties in any way from, or be deemed a waiver of any Claims by the Developer (or anyone claiming by, through or under the Developer, including, without limitation, any successor owner of the applicable Phase) with respect to (i) any fraud or intentional concealment or willful misconduct committed by any of the City Released Parties, (ii) any premises liability or bodily injury claims accruing prior to the applicable Phase Closing Date to the extent such claims are not based on the acts of the Developer, its partners or any of their respective agents, employees, contractors, consultants, officers, directors, affiliates, members, shareholders, partners or other representatives (the “Developer Parties”); (iii) any violation of law by any of the City Released Parties prior to the applicable Phase Closing Date; (iv) any breach by the City of any of the City's representations, warranties or covenants expressly set forth in this Agreement; or (v) the release (including negligent exacerbation but excluding Incidental Migration) of Hazardous Materials by the City Parties at, on, under or otherwise affecting the applicable Phase or (vi) any claim that is actually accepted as an insured claim under any pollution legal liability policy maintained by the City (collectively, the "Excluded Developer Claims").
Sample 1
AutoNDA by SimpleDocs

Related to Claims for Incidental Migration

  • Claims for Indemnification A Person entitled to indemnification under this Section 10.1 (an “Indemnified Party”) shall give prompt written notification to the Party from whom indemnification is sought (the “Indemnifying Party”) of the commencement of any action, suit or proceeding relating to a Third Party claim for which indemnification may be sought or, if earlier, upon the assertion of any such claim by a Third Party (it being understood and agreed, however, that the failure by an Indemnified Party to give notice of a Third Party claim as provided in this Section 10.1(c) shall not relieve the Indemnifying Party of its indemnification obligation under this Agreement except and only to the extent that such Indemnifying Party is actually damaged as a result of such failure to give notice). Within [**] days after delivery of such notification, the Indemnifying Party may, upon written notice thereof to the Indemnified Party, assume control of the defense of such action, suit, proceeding or claim with counsel reasonably satisfactory to the Indemnified Party. If the Indemnifying Party does not assume control of such defense, the Indemnified Party shall control such defense. The Party not controlling such defense may participate therein at its own expense. The Party controlling such defense shall keep the other Party advised of the status of such action, suit, proceeding or claim and the defense thereof and shall consider recommendations made by the other Party with respect thereto. The Indemnified Party shall not agree to any settlement of such action, suit, proceeding or claim without the prior written consent of the Indemnifying Party, which consent the Indemnifying Party shall not unreasonably withhold, condition or delay. The Indemnifying Party shall not agree, without the prior written consent of the Indemnified Party, which consent the Indemnified Party shall not unreasonably withhold, condition or delay, to any settlement of such action, suit, proceeding or claim or consent to any judgment in respect thereof that does not include a complete and unconditional release of the Indemnified Party from all liability with respect thereto or that imposes any liability or obligation on the Indemnified Party.

  • CLAIMS FOR DAMAGES 7.4.1 Should either party to the Contract suffer injury or damage to person or property because of any act or omission of the other party or of any of his / her employees, agents or others for whose acts he / she is legally liable, claim shall be made in writing to such other party within a reasonable time after the first observance of such injury or damage.

  • Procedures for Indemnification of Third Party Claims (a) If an Indemnified Party shall receive notice or otherwise learn of the assertion of any Third Party Claim or of the commencement by any such Person of any Action with respect to which an Indemnifying Party may be obligated to provide indemnification to such Indemnified Party pursuant to this Section 12.4, such Indemnified Party shall give such Indemnifying Party written notice thereof within 20 days after becoming aware of such Third Party Claim. Any such notice shall describe the Third Party Claim in reasonable detail. Notwithstanding the foregoing, the failure of any Indemnified Party or other Person to give notice as provided in this Section 12.4 shall not relieve the Indemnifying Party of its obligations under this Section 12.4, except to the extent that such Indemnifying Party is actually prejudiced by such failure to give notice. (b) An Indemnifying Party may elect to defend (and to seek to settle or compromise), at such Indemnifying Party’s own expense and by such Indemnifying Party’s own counsel, any Third Party Claim. Within 30 days after the receipt of notice from an Indemnified Party in accordance with Section 12.4(a) (or sooner, if the nature of such Third Party Claim so requires), the Indemnifying Party shall notify the Indemnified Party of its election whether the Indemnifying Party will assume responsibility for defending such Third Party Claim, which election shall specify any reservations or exceptions. After notice from an Indemnifying Party to an Indemnified Party of its election to assume the defense of a Third Party Claim, such Indemnified Party shall have the right to employ separate counsel and to participate in (but not control) the defense, compromise, or settlement thereof, but the fees and expenses of such counsel shall be the expense of such Indemnified Party except as set forth in the next sentence. If the Indemnifying Party has elected to assume the defense of the Third Party Claim but has specified, and continues to assert, any reservations or exceptions in such notice, then, in any such case, the reasonable fees and expenses of one separate counsel for all Indemnified parties shall be borne by the Indemnifying Party, but the Indemnifying Party shall be entitled to reimbursement by the Indemnified Party for payment of any such fees and expenses to the extent that it establishes that such reservations and exceptions were proper. (c) If an Indemnifying Party elects not to assume responsibility for defending a Third Party Claim, or fails to notify an Indemnified Party of its election as provided in Section 12.4(b) such Indemnified Party may defend such Third Party Claim at the cost and expense of the Indemnifying Party. (d) Unless the Indemnifying Party has failed to assume the defense of the Third Party Claim in accordance with the terms of this Agreement, no Indemnified Party may settle or compromise any Third Party Claim without the consent of the Indemnifying Party. No Indemnifying Party shall consent to entry of any judgment or enter into any settlement of any pending or threatened Third Party Claim in respect of which any Indemnified Party is or could have been a party and indemnity could have been sought hereunder by such Indemnified Party without the consent of the Indemnified Party if (i) the effect thereof is to permit any injunction, declaratory judgment, other order or other nonmonetary relief to be entered, directly or indirectly against such Indemnified Party and (ii) such settlement does not include an unconditional release of such Indemnified Party from all liability on claims that are the subject matter of such Third Party Claim.

  • Liability for Incidental and Consequential Damages Contractor shall be responsible for incidental and consequential damages resulting in whole or in part from Contractor’s acts or omissions.

  • Claims for Additional Time If the Contractor wishes to make a Claim for an increase in the Contract Time, written notice as provided herein shall be given. The Contractor’s Claim shall include an estimate of cost and of probable effect of delay on progress of the Work. In the case of a continuing delay, only one Claim is necessary.

  • INDEMNIFICATION FOR INFRINGEMENT The terms of this Section 10 do not apply to the Community Edition Licensees. Licensor will defend or settle, at its own expense, any claim against Licensee asserting a copyright, trademark or trade secret which concerns the Product used within the scope of the Agreement hereunder. Licensor shall indemnify Licensee against any loss, expense or liability including reasonable attorney's fees from any damages alleged against Licensee. Licensor's obligations under this Section are conditioned on Licensee promptly notifying Licensor in writing after Licensee first receives notice of any such claim, action or allegation of infringement and, Licensor being given sole control of the defense of any action and all negotiations for its settlement or compromise, with the reasonable assistance of Licensee. Licensor shall not be liable for any costs or expenditures incurred by Licensee without Licensor's prior written consent. If an injunction or order is obtained against Licensee's use of the Product by reason of the allegations of infringement, or if in Licensor's opinion the Product is likely to become the subject of a claim of infringement, Licensor shall, at its expense: (a) Procure for Licensee the right to continue using the Product; or (b) Modify or replace the Product with a compatible, functionally equivalent, non-infringing Product(s); or (c) If neither (a) nor (b) is reasonably practical in Licensor's judgment, remove the Product and issue Licensee a pro rata credit based upon the License fees paid for the Product prorated over a thirty-six (36) month period from the date of shipment of the Product. Thereafter, termination shall proceed in accordance with the terms of Section 4. Licensor shall have no obligation under this Section to the extent the alleged infringement results from (i) modification of the Product other than by Licensor; (ii) the combination of the Product with products not provided by Licensor; or (iii) use of any older version of the Product when use of a newer version made available to Licensee would have avoided the infringement. This Section 10 is Licensor's entire liability and Licensee's sole and exclusive remedy in the event of intellectual property infringement of any kind.

  • Claims for Consequential Damages The Owner retains its right to claim for consequential damages in the event the Design Professional fails to perform under this Contract.

  • PROCEDURE FOR INDEMNIFICATION--THIRD PARTY CLAIMS (a) Promptly after receipt by an indemnified party under Section 12.1 or 12.2 of notice of the commencement of any proceeding against it, such indemnified party will, if a claim is to be made against an indemnifying party under such Section, give notice to the indemnifying party of the commencement of such claim, but the failure to notify the indemnifying party will not relieve the indemnifying party of any liability that it may have to any indemnified party, except to the extent that the indemnifying party demonstrates that the defense of such action is prejudiced by the indemnifying party's failure to give such notice. (b) If any proceeding referred to in Section 12.4(a) is brought against an indemnified party and it gives notice to the indemnifying party of the commencement of such proceeding, the indemnifying party will be entitled to participate in such proceeding and, to the extent that it wishes (unless the indemnifying party is also a party to such proceeding and the indemnified party determines in good faith that joint representation would be inappropriate), to assume the defense of such proceeding with counsel satisfactory to the indemnified party and, after notice from the indemnifying party to the indemnified party of its election to assume the defense of such proceeding, the indemnifying party will not, as long as it diligently conducts such defense, be liable to the indemnified party under this Section 12 for any fees of other counsel or any other expenses with respect to the defense of such proceeding, in each case subsequently incurred by the indemnified party in connection with the defense of such proceeding, other than reasonable costs of investigation. If the indemnifying party assumes the defense of a proceeding, (i) it will be conclusively established for purposes of this Agreement that the claims made in that proceeding are within the scope of and subject to indemnification; (ii) no compromise or settlement or such claims may be effected by the indemnifying party without the indemnified party's consent unless the sole relief provided is monetary damages that are paid in full by the indemnifying party; and (iii) the indemnified party will have no liability with respect to any compromise or settlement of such claims effected without its consent. If notice is given to an indemnifying party of the commencement of any proceeding and the indemnifying party does not, within ten days after the indemnified party's notice is given, give notice to the indemnified party of its election to assume the defense of such proceeding, the indemnifying party will be bound by any determination made in such proceeding or any compromise or settlement effected by the indemnified party.

  • Procedures for Third Party Claims In the case of any claim for indemnification arising from a claim of a third-party other than an Infringement Claim subject to Section 13.3 above (a “Third-Party Claim”), a party seeking indemnification hereunder (each an “Indemnified Party”) shall give prompt written notice, following such Indemnified Party’s receipt of such claim or demand, to the party from which indemnity is sought (each an “Indemnifying Party”) of any claim or demand of which such Indemnified Party has knowledge and as to which it may request indemnification hereunder; provided, however, that failure to give such notice will not affect such Indemnified Party’s rights hereunder unless, and then solely to the extent that, the rights of the Indemnifying Parties from whom indemnity is sought are prejudiced as a result of such failure. The Indemnifying Party shall have the right (and if it elects to exercise such right, shall do so within twenty (20) days after receiving such notice from the Indemnified Party) to defend and to direct the defense against any such claim or demand, in its name or in the name of the Indemnified Party, as the case may be, at the expense of the Indemnifying Party, and with counsel selected by the Indemnifying Party; provided, that the Indemnifying Party shall be entitled to assume control of the defense of such action only if the Indemnifying Party acknowledges in writing its indemnity obligations and assumes and holds the Indemnified Party harmless from and against all Losses resulting from such Third-Party Claim; and provided further that the Indemnifying Party shall not be entitled to assume control of such defense if (i) the Indemnifying Party shall not have notified the Indemnified Party of its exercise of its right to defend such Third-Party claim within such twenty (20) day period; (ii) such claim or demand seeks an injunction or other equitable relief against the Indemnified Party, (iii) the Indemnified Party shall have reasonably concluded that (x) there is a conflict of interest between the Indemnified Party and the Indemnifying Party in the conduct of the defense of such claim or demand or (y) the Indemnified Party has one or more defenses not available to the Indemnifying Party, (iv) such claim relates to or arises in connection with any criminal proceeding, action, indictment, allegation or investigation, or (v) the appropriate court rules that the Indemnifying Party failed or is failing to vigorously prosecute or defend such Third-Party Claim. Notwithstanding anything in this Agreement to the contrary, the Indemnified Party shall, at the expense of the Indemnifying Party, cooperate with the Indemnifying Party, and keep the Indemnifying Party fully informed, in the defense of such claim or demand. The Indemnified Party shall have the right to participate in the defense of any claim or demand with counsel employed at its own expense; provided, however, that, in the case of any claim or demand described in clause (i) or (ii) of the second preceding sentence or as to which the Indemnifying Party shall not in fact have employed counsel to assume the defense of such claim or demand, the reasonable fees and disbursements of such counsel shall be at the expense of the Indemnifying Party. The Indemnifying Party shall have no indemnification obligations with respect to any such claim or demand which shall be settled by the Indemnified Party without the prior written consent of the Indemnifying Party, which consent shall not be unreasonably withheld, delayed or conditioned. The Indemnifying Party shall not settle any such claim without the prior written consent of the Indemnified Party (which consent shall not be unreasonably withheld, delayed or conditioned if such settlement is accompanied by a document releasing the Indemnified Party from all liability with respect to the matter in controversy that is binding, valid and enforceable against all applicable Parties). Notwithstanding the foregoing, if the Indemnified Party fails to object to the settlement within five (5) Business Days of receipt of a written notice from the Indemnifying Party containing the terms and condition of such settlement, the Indemnified Party shall be deemed to have consented to the settlement.

  • Action for Indemnification To indemnify Indemnitee for any expenses incurred by Indemnitee with respect to any action, suit or proceeding instituted by Indemnitee to enforce or interpret this Agreement, unless Indemnitee is successful in establishing Indemnitee’s right to indemnification in such action, suit or proceeding, in whole or in part, or unless and to the extent that the court in such action, suit or proceeding shall determine that, despite Indemnitee’s failure to establish their right to indemnification, Indemnitee is entitled to indemnity for such expenses; provided, however, that nothing in this Section 8(b) is intended to limit the Corporation’s obligation with respect to the advancement of expenses to Indemnitee in connection with any such action, suit or proceeding instituted by Indemnitee to enforce or interpret this Agreement, as provided in Section 4 hereof.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!