CLIMAX AVIATION’s rights and duties Sample Clauses

CLIMAX AVIATION’s rights and duties. 3.1. CLIMAX AVIATION shall perform the Services (i) in a professional manner; (ii) in conformance with that level of care and skill ordinarily exercised in similar circumstances by providers of the same or similar services; (iii) in compliance with all applicable laws and regulations. 3.2. The correct execution of the Assignment is an obligation to perform to the best of one’s ability. 3.3. CLIMAX AVIATION can freely decide how the Assignment is to be executed and which CLIMAX AVIATION employees are involved in its execution. CLIMAX AVIATION can have the Assignment (or part of it) performed by a CLIMAX AVIATION subcontractor or any other third party. 3.4. CLIMAX AVIATION shall ensure that all Personnel assigned to perform the Services have the appropriate level of expertise, training, experience and, where applicable, licenses, necessary to perform such Services.
Sample 1
AutoNDA by SimpleDocs

Related to CLIMAX AVIATION’s rights and duties

  • Express Rights and Remedies Not Limited The express rights and remedies of the LHIN are in addition to and will not limit any other rights and remedies available to the LHIN at law or in equity. For further certainty, the LHIN has not waived any provision of any applicable statute, including LHSIA, nor the right to exercise its rights under these statutes at any time.

  • Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.

  • Application of Takeover Protections; Rights Agreements The Company and the Board of Directors have taken all necessary action, if any, in order to render inapplicable any control share acquisition, business combination, poison pill (including any distribution under a rights agreement) or other similar anti-takeover provision under the Company’s charter documents or the laws of its state of incorporation that is or could reasonably be expected to become applicable to any of the Purchasers as a result of the Purchasers and the Company fulfilling their obligations or exercising their rights under the Transaction Documents, including, without limitation, the Company’s issuance of the Securities and the Purchasers’ ownership of the Securities.

  • Application of Takeover Protections; Rights Agreement The Company and its board of directors have taken all necessary action, if any, in order to render inapplicable any control share acquisition, interested stockholder, business combination, poison pill (including, without limitation, any distribution under a rights agreement), stockholder rights plan or other similar anti-takeover provision under the Certificate of Incorporation, Bylaws or other organizational documents or the laws of the jurisdiction of its incorporation or otherwise which is or could become applicable to any Buyer as a result of the transactions contemplated by this Agreement, including, without limitation, the Company’s issuance of the Securities and any Buyer’s ownership of the Securities. The Company and its board of directors have taken all necessary action, if any, in order to render inapplicable any stockholder rights plan or similar arrangement relating to accumulations of beneficial ownership of shares of Common Stock or a change in control of the Company or any of its Subsidiaries.

  • Power of the Authority to undertake works (i) In the event the Parties are unable to agree to the proposed Change of Scope Orders in accordance with Clause 13.2, the Authority may, after giving notice to the Contractor and considering its reply thereto, award such Works or services to any person or agency on the basis of open competitive bidding. It is also agreed that the Contractor shall provide assistance and cooperation to the person or agency who undertakes the works or services hereunder. The Contractor shall not be responsible for rectification of any Defects, but the Contractor shall carry out maintenance of such works after completion of Defect Liability Period of work by other person or agency during the remaining period of this agreement without any extra payment. (ii) The Works undertaken in accordance with this Clause 13.5 shall conform to the Specifications and Standards and shall be carried out in a manner that minimises the disruption in operation of the Project Highway. The provisions of this Agreement, insofar as they relate to Works and Tests, shall apply mutatis mutandis to the Works carried out under this Clause 13.5.

  • General Enforcement Authority That the terms of this Agreement shall be enforced in accordance with the provisions, terms and authorities provided in this Agreement and under the respective laws and regulations of each Participating State.

  • Installation and Use Rights You may install and use any number of copies of the software on your devices.

  • TEACHERS’ RIGHTS A. Pursuant to the Employer-Employee Relations Act, the Board and the Association agree that every member of the unit shall have the right freely to organize, join and support the Association and its affiliates for the purpose of engaging in collective negotiations and other concerted activities for mutual aid and protection, or to refrain from such activities. The Board and the Association undertake and agree that they shall not directly or indirectly discourage or deprive or coerce any teacher in the enjoyment of any rights conferred by the Employer-Employee Relations Act, or other laws of New Jersey or the constitutions of New Jersey or the United States. B. Nothing contained herein shall be construed to deny or restrict to any teacher such rights as he/she may have under New Jersey School Laws or other applicable laws and regulations. The rights granted to teachers hereunder shall be deemed to be in addition to those provided elsewhere. C. No teacher shall be disciplined, reprimanded or reduced in rank or compensation without just cause. Any such action asserted by the Board, or any agent or representative thereof, shall be subject to the grievance procedure herein set forth. For purposes of this provision, discharge, removal, or non-renewal shall not be considered as discipline, reprimand or reduction in rank or compensation. D. Whenever any teacher is required to appear before any Administrator or Supervisor, the Superintendent, Board or any committee thereof for a meeting or conference, the purpose of which adversely concerns the continuance of that teacher in his/her office, position, or employment or adversely concerns salary or any increments pertaining thereto, he/she shall be given prior written notice of the reason for such meeting or conference and shall be entitled to have a representative of the Association present to advise and represent him/her during such meeting or conference, provided that no unreasonable delay shall be incurred in the scheduling of such meeting due to a lack of representation. E. The Board shall provide a job description of co- curricular jobs for which compensation is provided. This description shall be prepared by the Board of Education in consultation with the Association.

  • ADMINISTRATION OF THE CONTRACT 2.2.1 The Architect will provide administration of the Contract as hereinafter described. 2.2.2 The Architect will be the State's representative during construction and until final payment is due. The Architect will advise and consult with the State. The State's instructions to the Contractor shall be forwarded through the Architect. The Architect will have authority to act on behalf of the State only to the extent provided in the Contract Documents, unless otherwise modified by written instrument in accordance with Subparagraph 2.2.10. 2.2.3 The Architect will visit the site at intervals appropriate to the stage of construction to familiarize himself or herself generally with the progress and quality of the Work and to determine in general if the Work is proceeding in accordance with the Contract Documents. However, the Architect will not be required to make exhaustive or continuous on-site inspections to check the quality or quantity of the Work. On the basis of his or her on-site observations as an architect, he or she will keep the State informed of the progress of the Work, and will endeavor to guard the State against defects and deficiencies in the Work of the Contractor. 2.2.4 The Architect will not be responsible for and will not have control or charge of construction means, methods, techniques, sequences or procedures, or for safety precautions and programs in connection with the Work, and he or she will not be responsible for the Contractor's failure to carry out the Work in accordance with the Contract Documents. The Architect will not be responsible for or have control or charge over the acts or omissions of the Contractor, 2.2.5 The Architect shall at all times have access to the Work wherever it is in preparation and progress. The Contractor shall provide facilities for such access so the Architect may perform his or her functions under the Contract Documents.

  • County of Orange Child Support Enforcement Subrecipient certifies it is in full compliance with all applicable federal and state reporting requirements regarding its employees and with all lawfully served Wage and Earnings Assignment Orders and Notices of Assignments and will continue to be in compliance throughout the term of the Contract with the County of Orange. Failure to comply shall constitute a material breach of the Contract and failure to cure such breach within 60 calendar days of notice from the County shall constitute grounds for termination of the Contract.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!