Possession and Control The Grantor has exclusive possession and control of its Equipment and Inventory.
POSSESSION AND CLOSING Possession of the Property shall be delivered to Purchaser by Seller at the Closing, subject to the Permitted Exceptions and the rights of the Tenants under Tenant Leases. Purchaser shall make its own arrangements for the provision of public utilities to the Property and Seller shall terminate its contracts with such utility companies that provide services to the Property.
TERM; POSSESSION The Term of this Lease shall commence on the Commencement Date and shall end on the Expiration Date, unless extended or sooner terminated in accordance with this Lease. If Landlord is delayed in delivering possession of all or any portion of the Premises to Tenant as of the Commencement Date, Tenant will take possession on the date Landlord delivers possession, which date will then become the Commencement Date (and the Expiration Date will be extended so that the length of the Term remains unaffected by such delay). Subject to this Section 4, Landlord shall not be liable for any loss or damage to Tenant resulting from any delay in delivering possession due to the holdover of any existing tenant or other circumstances outside of Landlord’s reasonable control. In the event that the Tenant Improvements are not Substantially Completed within one hundred (100) days following the date that Landlord receives a building permit to commence the Tenant Improvements in the Premises (the “Delivery Date”), subject to Tenant Delay or force majeure (in the event of either, the Delivery Date shall be extended by one (1) day for each one (1) day of Tenant Delay or force majeure), Landlord shall credit Tenant against Minimum Annual Rent due under this Lease an amount equal to the holdover portion of Tenant’s existing rental obligations under Tenant’s existing Lease actually incurred by Tenant following the Delivery Date, which Tenant represents to Landlord is equal to $17,031.13 per month. Notwithstanding anything in this Lease to the contrary, if the Commencement Date has not occurred on or before one hundred ninety (190) days following the date that Landlord receives a building permit for the Tenant Improvements, for any reason other than Tenant Delay or force majeure, then Tenant shall have the right to terminate this Lease by written notice to Landlord, as Tenant’s sole and exclusive remedy with respect to such delay, except as provided above, subject to Tenant giving Landlord thirty (30) days’ advance written notice of its intention to terminate this Lease if Substantial Completion shall not occur within such thirty (30) day period, in which event all amounts prepaid or deposited by Tenant hereunder shall be promptly returned to Tenant.
Peaceful Possession The Authority hereby warrants that:
a) The Project Site has been acquired through the due process of law and belongs to and is vested with the Authority and that the Authority has full powers to hold, dispose of and deal with the same consistent, inter alia, with the provisions of this Agreement.
b) In the event the Developer is obstructed by any Person claiming any right, title or interest in or over the Project Site or any part thereof, or in the event of any enforcement action including any attachment, distrait, appointment of receiver or liquidator being initiated by any Person claiming to have any interest in/charge or the Project Site or any part thereof, the Authority shall, if called upon by the Developer, defend such claims and proceedings and also keep the Developer indemnified against any consequential loss or damages which the Developer may suffer, on account of any such right, title, interest or charge.
Possession and Use Contractor may possess, use and reproduce Confidential Information solely for the Purpose. Contractor shall not use the Confidential Information for any other purpose.
Title to Properties; Possession Under Leases (a) Each of the Borrower and the Subsidiaries has valid title in fee simple or equivalent to, or valid leasehold interests in, or easements or other limited property interests in, all its Real Properties (including all Mortgaged Properties) and has valid title to its personal property and assets, in each case, except for Permitted Liens and except for defects in title that do not materially interfere with its ability to conduct its business as currently conducted or to utilize such properties and assets for their intended purposes and except where the failure to have such title would not reasonably be expected to have, individually or in the aggregate, a Material Adverse Effect. All such properties and assets are free and clear of Liens, other than Permitted Liens or Liens arising by operation of law. The Equity Interests of the Borrower owned by Holdings (prior to a Qualified IPO) are free and clear of Liens, other than Liens permitted by Article VIA.
(b) The Borrower and each of the Subsidiaries has complied with all material obligations under all leases to which it is a party, except where the failure to comply would not reasonably be expected to have Material Adverse Effect, and all such leases are in full force and effect, except leases in respect of which the failure to be in full force and effect would not reasonably be expected to have a Material Adverse Effect.
(c) As of the Closing Date, none of the Borrower and the Subsidiaries has received any written notice of any pending or contemplated condemnation proceeding affecting any material portion of the Mortgaged Properties or any sale or disposition thereof in lieu of condemnation that remains unresolved as of the Closing Date, except as set forth on Schedule 3.07(c).
(d) As of the Closing Date, none of the Borrower and its Subsidiaries is obligated under any right of first refusal, option or other contractual right to sell, assign or otherwise Dispose of any Mortgaged Property or any interest therein, except as permitted under Section 6.02 or 6.05 or as would not reasonably be expected to have a Material Adverse Effect.
(e) Schedule 1.01(E) lists each Material Real Property owned by any Loan Party as of the Closing Date.
Documents, Records and Funds in Possession of the Master Servicer to be Held for the Trustee. The Master Servicer shall account fully to the Trustee for any funds it receives or otherwise collects as Liquidation Proceeds or Insurance Proceeds in respect of any Mortgage Loan. All Mortgage Files and funds collected or held by, or under the control of, the Master Servicer in respect of any Mortgage Loans, whether from the collection of principal and interest payments or from Liquidation Proceeds, including any funds on deposit in the Certificate Account, shall be held by the Master Servicer for and on behalf of the Trustee and shall be and remain the sole and exclusive property of the Trustee, subject to the applicable provisions of this Agreement. The Master Servicer also agrees that it shall not create, incur or subject any Mortgage File or any funds that are deposited in the Certificate Account, the Collection Account, Distribution Account, or any Escrow Account, or any funds that otherwise are or may become due or payable to the Trustee for the benefit of the Certificateholders, to any claim, lien, security interest, judgment, levy, writ of attachment, or other encumbrance, or assert by legal action or otherwise any claim or right of setoff against any Mortgage File or any funds collected on, or in connection with, a Mortgage Loan, except, however, that the Master Servicer shall be entitled to set off against and deduct from any such funds any amounts that are properly due and payable to the Master Servicer under this Agreement.
Quiet Possession Upon Tenant paying the rent reserved hereunder and observing and performing all of the covenants, conditions and provisions on Tenant's part to be observed and performed hereunder, Tenant shall have quiet possession of the Premises for the entire term hereof, subject to all the provisions of this Lease.
Possession and Assembly of Collateral Secured Party may, without notice, demand or initiate legal process of any kind, take possession of any or all of the Collateral (in addition to Collateral of which Secured Party already has possession), wherever it may be found, and for that purpose may pursue the same wherever it may be found, and may at any time enter into any of Grantor's premises where any of the Collateral may be or is supposed to be, and search for, take possession of, remove, keep and store any of the Collateral until the same shall be sold or otherwise disposed of and Secured Party shall have the right to store and conduct a sale of the same in any of Grantor's premises without cost to Secured Party. At Secured Party's request, Grantor will, at Grantor’s sole expense, assemble the Collateral and make it available to Secured Party at a place or places to be designated by Secured Party which is reasonably convenient to Secured Party and Grantor.
Possession of the Property The Parties hereby agree that the exclusive possession of the Property shall be delivered by the Seller to the Buyer on
