Cost of remedying Defects Any repair or rectification undertaken in accordance with the provisions of Clause 17.2, including any additional testing, shall be carried out by the Contractor at its own risk and cost, to the extent that such rectification or repair is attributable to:
(a) the design of the Project;
(b) Plant, Materials or workmanship not being in accordance with this Agreement and the Specifications and Standards;
(c) improper maintenance during construction of the Project Highway by the Contractor; and/ or
(d) failure by the Contractor to comply with any other obligation under this Agreement.
Tenant’s Remedies Notwithstanding any other provision of this Lease, if any default hereunder by Landlord is not cured within the applicable cure period provided in Paragraph 20(c) or any other applicable cure period provided in this Lease (including any Mortgagee’s additional cure period), Tenant’s exclusive remedies shall be (i) an action for specific performance, or (ii) an action for actual damages. Notwithstanding any other provision of this Lease, the liability of Landlord to Tenant for any breach or default by Landlord under the terms of this Lease, or for any other matter related to this Lease or to the Premises or Project, shall be limited to Tenant’s actual direct, but not consequential, damages therefor, and any judgment against Landlord in connection therewith shall be recoverable only from the interest of Landlord in the Buildings. Tenant hereby waives any claim for damages for any disturbance, loss of business, nuisance, injury or inconvenience to or interference with Tenant’s business, any loss of occupancy or quiet enjoyment of the Premises, and any other loss arising from Landlord’s entry and acts pursuant to Paragraph 18 or otherwise with respect to any act, omission or breach of Landlord. Without limiting the preceding sentence, in no event shall Landlord be liable to Tenant for any consequential damages, including, without limitation, any losses arising from any interruption of Tenant’s business, or for lost profits, or for charges or expenses which continue but would have been earned if the business had gone on without interruption, or for any other loss, claim, cost, expense or damage which would be covered by a standard policy of business interruption insurance. Landlord, or if Landlord is a partnership its partners whether general or limited, or if Landlord is a corporation its directors, officers or shareholders, or if Landlord is a limited liability company its members or managers, shall never be personally liable for any such judgment. Any lien obtained to enforce such judgment and any levy of execution thereon shall be subject and subordinate to any Mortgage (excluding any Mortgage which was created as part of an effort to defraud creditors, i.e., a fraudulent conveyance); provided, however that any such judgment and any such levy of execution thereon shall not be subject or subordinated to any Mortgage that is created or recorded in the official records of the county in which the Project is located after the date of the judgment giving rise to such lien. Landlord’s interest in the Buildings shall include any insurance proceeds received by Landlord which are not controlled by any Mortgagee or other lender. Tenant hereby waives the benefit of any Laws granting it (A) the right to perform Landlord’s obligations, or (B) the right to terminate this Lease or withhold Rent on account of any Landlord default, including, without limitation, Sections 1932(1), 1941 and 1942 of the California Civil Code.
Performance Default and Remedies Subsection B. DEFAULT AND REMEDIES, second paragraph of the Contract is modified as follows (underlined language is added and stricken language is deleted): “Written notice of default and a reasonable 30-day opportunity to cure must be issued by the party claiming default.”
Termination for Default; Remedies 8.2.1 Each of the following shall constitute an immediate event of default (“Event of Default”) under this Agreement:
(a) Contractor fails or refuses to perform or observe any term, covenant or condition contained in any of the following Sections of this Agreement:
Landlord’s Default and Tenant’s Remedies In the event Landlord fails to perform any of its obligations under this Lease, Landlord shall nevertheless not be in default under the terms of this Lease until such time as Tenant shall have first given Landlord written notice specifying the nature of such failure to perform its obligations, and then only after Landlord shall have had a reasonable period of time following its receipt of such notice within which to perform such obligations. In the event of Landlord’s default as above set forth, then, and only then, Tenant shall have the following remedies only:
A. Tenant may then proceed in equity or at law to compel Landlord to perform its obligations and/or to recover damages proximately caused by such failure to perform (except as and to the extent Tenant has waived its right to damages as provided in this Lease).
B. Tenant, at its option, may then cure any default of Landlord at Landlord’s cost. If, pursuant to this Subarticle, Tenant reasonably pays any sum to any third party or does any act that requires the payment of any sum to any third part at any time by reason of Landlord’s default, the sum paid by, Tenant shall be immediately due from Landlord to Tenant at the time Tenant supplies Landlord with an invoice therefor (provided such invoice sets forth and is accompanied by a written statement of Tenant setting forth in reasonable detail the amount paid, the party to whom it was paid, the date it was paid, and the reasons giving rise to such payment), together with interest at twelve percent per annum from the date of such invoice until Tenant is reimbursed by Landlord. Tenant may not offset such sums against any installment of rent due Landlord under the terms of this Lease.
Landlord’s Remedies (a) Upon the occurrence of any Default by Tenant, then in addition to any other remedies available to Landlord, Landlord may exercise the following remedies:
(i) Landlord may terminate Tenant’s right to possession of the Premises by any lawful means, in which case this Lease shall terminate and Tenant shall immediately surrender possession of the Premises to Landlord. Such termination shall not affect any accrued obligations of Tenant under this Lease. Upon termination, Landlord shall have the right to reenter the Premises and remove all persons and property. Landlord shall also be entitled to recover from Tenant:
(1) The worth at the time of award of the unpaid Rent which had been earned at the time of termination;
(2) The worth at the time of award of the amount by which the unpaid Rent which would have been earned after termination until the time of award exceeds the amount of such loss that Tenant proves could have been reasonably avoided;
(3) The worth at the time of award of the amount by which the unpaid Rent for the balance of the Term after the time of award exceeds the amount of such loss that Tenant proves could be reasonably avoided;
(4) Any other amount necessary to compensate Landlord for all the detriment proximately caused by Tenant’s failure to perform its obligations under this Lease or which in the ordinary course of things would be likely to result from Tenant’s default, including, but not limited to, the cost of recovering possession of the Premises, commissions and other expenses of reletting, including necessary repair, renovation, improvement and alteration of the Premises for a new tenant, reasonable attorneys’ fees, and any other reasonable costs; and
(5) At Landlord’s election, all other amounts in addition to or in lieu of the foregoing as may be permitted by law. Any sum, other than Basic Rent, shall be computed on the basis of the average monthly amount accruing during the 24 month period immediately prior to Default, except that if it becomes necessary to compute such rental before the 24 month period has occurred, then the computation shall be on the basis of the average monthly amount during the shorter period. As used in subparagraphs (1) and (2) above, the “worth at the time of award” shall be computed by allowing interest at the rate of 10% per annum. As used in subparagraph (3) above, the “worth at the time of award” shall be computed by discounting the amount at the discount rate of the Federal Reserve Bank of San Francisco at the time of award plus 1%.
(ii) Landlord may elect not to terminate Tenant’s right to possession of the Premises, in which event Landlord may continue to enforce all of its rights and remedies under this Lease, including the right to collect all rent as it becomes due. Efforts by the Landlord to maintain, preserve or relet the Premises, or the appointment of a receiver to protect the Landlord’s interests under this Lease, shall not constitute a termination of the Tenant’s right to possession of the Premises. In the event that Landlord elects to avail itself of the remedy provided by this subsection (ii), Landlord shall not unreasonably withhold its consent to an assignment or subletting of the Premises subject to the reasonable standards for Landlord’s consent as are contained in this Lease.
(b) The various rights and remedies reserved to Landlord in this Lease or otherwise shall be cumulative and, except as otherwise provided by California law, Landlord may pursue any or all of its rights and remedies at the same time. No delay or omission of Landlord to exercise any right or remedy shall be construed as a waiver of the right or remedy or of any breach or Default by Tenant. The acceptance by Landlord of rent shall not be a (i) waiver of any preceding breach or Default by Tenant of any provision of this Lease, other than the failure of Tenant to pay the particular rent accepted, regardless of Landlord’s knowledge of the preceding breach or Default at the time of acceptance of rent, or (ii) a waiver of Landlord’s right to exercise any remedy available to Landlord by virtue of the breach or Default. The acceptance of any payment from a debtor in possession, a trustee, a receiver or any other person acting on behalf of Tenant or Tenant’s estate shall not waive or cure a Default under Section 14.1. No payment by Tenant or receipt by Landlord of a lesser amount than the rent required by this Lease shall be deemed to be other than a partial payment on account of the earliest due stipulated rent, nor shall any endorsement or statement on any check or letter be deemed an accord and satisfaction and Landlord shall accept the check or payment without prejudice to Landlord’s right to recover the balance of the rent or pursue any other remedy available to it. Tenant hereby waives any right of redemption or relief from forfeiture under California Code of Civil Procedure Section 1174 or 1179, or under any successor statute, in the event this Lease is terminated by reason of any Default by Tenant. No act or thing done by Landlord or Landlord’s agents during the Term shall be deemed an acceptance of a surrender of the Premises, and no agreement to accept a surrender shall be valid unless in writing and signed by Landlord. No employee of Landlord or of Landlord’s agents shall have any power to accept the keys to the Premises prior to the termination of this Lease, and the delivery of the keys to any employee shall not operate as a termination of the Lease or a surrender of the Premises.
Default and Remedies Either of the following constitutes cause to declare this Contract, or any Participating Entity order under this Contract, in default:
1. Nonperformance of contractual requirements, or
2. A material breach of any term or condition of this Contract. The party claiming default must provide written notice of the default, with 30 calendar days to cure the default. Time allowed for cure will not diminish or eliminate any liability for liquidated or other damages. If the default remains after the opportunity for cure, the non-defaulting party may: • Exercise any remedy provided by law or equity, or • Terminate the Contract or any portion thereof, including any orders issued against the Contract.
REMEDY OF DEFECTS (a) The BUILDER shall remedy, at its expense, any defects, against which the VESSEL is guaranteed under this Article, by making all necessary repairs or replacements at the SHIPYARD or elsewhere as provided for in (b) hereinbelow. In such case, the VESSEL shall be taken at the BUYER's cost and responsibility to the place selected, ready in all respects for such repairs or replacements and in any event, the BUILDER shall not be responsible for towage, dockage, wharfage, port charges and anything else incurred for the BUYER's getting and keeping the VESSEL ready for such repairing or replacing.
(b) However, if it is impractical (which shall include, but not be limited to, an emergency) to bring the VESSEL to the SHIPYARD, the BUYER may cause the necessary repairs or replacements to be made elsewhere which is deemed by the BUYER with the consent of the BUILDER which shall not be unreasonably withheld, to be suitable for the purpose, provided that, in such event, the BUILDER may forward or supply replacement parts or materials under the terms described in (c) hereinbelow, unless forwarding or supplying thereof under the terms described in (c) hereinbelow would impair or delay the operation or working schedule of the VESSEL. In the event that the BUYER proposes to cause the necessary repairs or replacements to be made to the VESSEL at any shipyard or works other than the SHIPYARD, the BUYER shall first (but in all events as soon as reasonably possible) give the BUILDER notice by email or facsimile of the time and place such repairs will be made, and if the VESSEL is not thereby delayed, or her operation or working schedule is not thereby impaired, the BUILDER shall have the right to verify by its own representative(s) the nature and extent of the defects complained of. The BUILDER shall, in such case, promptly advise the BUYER by email or facsimile, after such examination has been completed, of its acceptance or rejection of the defects as ones that are covered by the guarantee herein provided. Upon the BUILDER's acceptance of the defects as justifying remedy under this Article, or upon award of the arbitration so determining, the BUILDER shall compensate the BUYER an amount equal to the reasonable cost of making the same repairs or replacements at the SHIPYARD.
(c) In the event that it is necessary for the BUILDER to forward a replacement for a defective part under this guarantee, replacement parts shall be shipped to the BUYER under the C.I.F terms to the BUYER's nominated port. The BUILDER reserves the option to retrieve, at the BUILDER's cost, any of the replaced equipment/parts in case defects are remedied in accordance with the provisions in this Article.
(d) Any dispute under this Article shall be referred to arbitration in accordance with the provisions of Article XIII hereof.
Incident Notice and Remediation If Contractor becomes aware of any Incident, it shall notify the State immediately and cooperate with the State regarding recovery, remediation, and the necessity to involve law enforcement, as determined by the State. Unless Contractor can establish that none of Contractor or any of its agents, employees, assigns or Subcontractors are the cause or source of the Incident, Contractor shall be responsible for the cost of notifying each person who may have been impacted by the Incident. After an Incident, Contractor shall take steps to reduce the risk of incurring a similar type of Incident in the future as directed by the State, which may include, but is not limited to, developing and implementing a remediation plan that is approved by the State at no additional cost to the State.
Defaults and Remedies Section 6.01.
