Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Additional Requirements for Sleeping Rooms The Contractor shall provide departing Attendees a secured area for storing belongings.
Service Requirement Except as otherwise provided in Section 6(e) of the Plan or Section 2 of this Agreement, this Option may be exercised only while you continue to provide Service to the Company or any Affiliate, and only if you have continuously provided such Service since the Grant Date of this Option.
Funding Restrictions and Order Quantities The Agency reserves the right to reduce or increase estimated or actual quantities in whatever amount necessary without prejudice or liability to the Agency, if:
12.3.1 Funding is not available;
12.3.2 Legal restrictions are placed upon the expenditure of monies for this category of service or supplies; or,
12.3.3 The Agency’s requirements in good faith change after award of the contract.
Forecasting Requirements 19.5.1 The Parties shall exchange technical descriptions and forecasts of their Interconnection and traffic requirements in sufficient detail necessary to establish the Interconnections necessary for traffic completion to and from all Customers in their respective designated service areas.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
Minimum Balance Requirements To be a member and maintain Accounts with Us You must purchase 1 share in the Credit Union. The par value of a share in this Credit Union is $5.00. If the balance in Your primary share Account drops below 1 share ($5.00), at any time, We may, at Our option, close Your Account. Nonsufficient Funds Returns. Any share draft or pre-authorized transfer, or transaction made through the use of a debit card, or other electronic means, as is applicable (including any in-person transaction), that is presented to Us for payment on Your Account when Your Account lacks sufficient collected funds to pay any such item may, at Our option, be returned for nonsufficient funds or We may honor any such item and charge You a fee for doing so. Overdraft Balance Calculation. When processing transactions that debit or credit Your Account, We start each Business Day with Your final Account balance from the preceding Business Day. The final balance takes into account all of the debit and credit transactions that were settled that Business Day pursuant to Our Funds Availability Policy, as well as any other debits or credits to Your Account that were finally settled that day, as described above in the "Deposit of Items" and "Collection and Processing of Items" sections of the Account Agreement. This starting balance at the beginning of a Business Day (the preceding Business Day's final balance) is sometimes referred to as Your "actual balance."
Invoice Requirements Contractor hereby waives the right to enforce any term which contradicts or modifies any term of the solicitation or any Contract that may result, including subsequent amendments to the Contract, or would result in an unencumbered expense if enforced against the state. Contract quote and invoice must contain, at a minimum:
SPECIALIZED SERVICE REQUIREMENTS In the event that the Participating Entity requires service or specialized performance requirements not addressed in this Contract (such as e- commerce specifications, specialized delivery requirements, or other specifications and requirements), the Participating Entity and the Supplier may enter into a separate, standalone agreement, apart from this Contract. Sourcewell, including its agents and employees, will not be made a party to a claim for breach of such agreement.
Service Requirements Grantee shall:
