Compliance with Progress Schedule Sample Clauses

Compliance with Progress Schedule. Subcontractor shall commence preparatory and planning work immediately upon execution of this Subcontract Agreement and shall timely mobilize its forces to the Project site in order to commence its work in accordance with Contractor’s schedule included as part of the Contract Documents, or otherwise provided to Subcontractor by Contractor (the “Progress Schedule”). The Progress Schedule is attached hereto as an Attachment, and is subject to revision by Contractor from time to time. Subcontractor shall diligently prosecute its work in accordance with the Progress Schedule and all revisions thereto, it being expressly understood that Contractor has agreed to meet one or more dates of substantial completion for the Project as further set forth and defined in the Contract Documents, and that Contractor has undertaken that obligation to the Owner in reliance upon Subcontractor’s ability and promise to timely perform its work in accordance with the Progress Schedule. If Subcontractor, in the reasonable judgment of Contractor, fails to satisfactorily maintain its progress of the Subcontract Work, then Contractor may direct Subcontractor to cure the issues impeding Subcontractor’s progress and to take such steps as Contractor deems necessary to improve the rate of progress of the Subcontract Work, including requiring Subcontractor to increase the number of shifts and/or to pursue overtime operations, and to submit for approval a schedule demonstrating the manner in which the required rate of progress will be regained, all without additional cost to Contractor. If Subcontractor fails to commence or begin taking diligent steps to commence and continue with promptness to cure, in response to Contractor’s direction to cure the deficiencies impeding the rate of progress of Subcontractor’s Work, within 24 hours after receipt of written notice, Contractor may proceed as provided in Article XXI of this Subcontract Agreement.
Sample 1Sample 2Sample 3See All (25)
AutoNDA by SimpleDocs
Compliance with Progress Schedule. Provided that it is not prevented from doing so by another party's delay or breach of this agreement, each party agrees, on and from the Notice to Proceed Date to: (a) provide their Works so as to ensure suitable interfacing with the Works of the other parties (including complying with any reasonable requests by Powerlink about interfacing of the parties’ respective works); and (b) undertake and complete each component of their Works by each Milestone Date for which they are responsible under the Progress Schedule, in accordance with this agreement.
Sample 1Sample 2

Related to Compliance with Progress Schedule

  • COMPLIANCE WITH POLICIES AND PROCEDURES During the period that Executive is employed with the Company hereunder, Executive shall adhere to the policies and standards of professionalism set forth in the policies and procedures of the Company and IAC as they may exist from time to time.

  • Compliance with Policies Each Individual Limited Partner hereby agrees that he shall comply with all policies and procedures adopted by any member of the Och-Ziff Group or which Limited Partners are required to observe by law, or by any recognized stock exchange, or other regulatory body or authority.

  • Compliance with Procurement Laws This Contract is the result of compliance with applicable procurement laws of the State of Texas. DIR issued a solicitation on the Comptroller of Public Accounts’ Electronic State Business Daily, Request for Offer (RFO) DIR-TSO-TMP-225, on February 27, 2015, for Software, including Software as a Service, Products and Related Services. Upon execution of this Contract, a notice of award for RFO DIR-TSO-TMP-225 shall be posted by DIR on the Electronic State Business Daily.

  • Compliance with Rules To comply with, and to require the Contractors to comply with, all rules, regulations, ordinances and laws bearing on the conduct of the work on the Improvements, including the requirements of any insurer issuing coverage on the Project and the requirements of any applicable supervising boards of fire underwriters.

  • Compliance with Orders The Company is not in violation of any material judgment, decree, or order of any court, arbitrator or other governmental authority.

  • Compliance with FCPA Each of the Credit Parties and their Subsidiaries is in compliance with the Foreign Corrupt Practices Act, 15 U.S.C. §§ 78dd-1, et seq., and any foreign counterpart thereto. None of the Credit Parties or their Subsidiaries has made a payment, offering, or promise to pay, or authorized the payment of, money or anything of value (a) in order to assist in obtaining or retaining business for or with, or directing business to, any foreign official, foreign political party, party official or candidate for foreign political office, (b) to a foreign official, foreign political party or party official or any candidate for foreign political office, and (c) with the intent to induce the recipient to misuse his or her official position to direct business wrongfully to such Credit Party or its Subsidiary or to any other Person, in violation of the Foreign Corrupt Practices Act, 15 U.S.C. §§ 78dd-1, et seq.

  • Compliance with Rules and Policies The Executive shall perform all services in accordance with the lawful policies, procedures and rules established by the Company and the Board. In addition, the Executive shall comply with all laws, rules and regulations that are generally applicable to the Company or its subsidiaries and their respective employees, directors and officers.

  • Compliance with OFAC None of the Company and its Subsidiaries or, to the Company’s knowledge, any director, officer, agent, employee or affiliate of the Company and its Subsidiaries or any other person acting on behalf of the Company and its Subsidiaries, is currently subject to any U.S. sanctions administered by the Office of Foreign Assets Control of the U.S. Department of the Treasury (“OFAC”), and the Company will not, directly or indirectly, use the proceeds of the Offering hereunder, or lend, contribute or otherwise make available such proceeds to any subsidiary, joint venture partner or other person or entity, for the purpose of financing the activities of any person currently subject to any U.S. sanctions administered by OFAC.

  • Compliance with Privacy Code The Corporation acknowledges that the Warrant Agent may, in the course of providing services hereunder, collect or receive financial and other personal information about such parties and/or their representatives, as individuals, or about other individuals related to the subject matter hereof, and use such information for the following purposes: (a) to provide the services required under this Indenture and other services that may be requested from time to time; (b) to help the Warrant Agent manage its servicing relationships with such individuals; (c) to meet the Warrant Agent’s legal and regulatory requirements; and (d) if Social Insurance Numbers are collected by the Warrant Agent, to perform tax reporting and to assist in verification of an individual’s identity for security purposes. The Corporation acknowledges and agrees that the Warrant Agent may receive, collect, use and disclose personal information provided to it or acquired by it in the course of its acting as agent hereunder for the purposes described above and, generally, in the manner and on the terms described in its privacy code, which the Warrant Agent shall make available on its website or upon request, including revisions thereto. Further, the Corporation agrees that it shall not provide or cause to be provided to the Warrant Agent any personal information relating to an individual who is not a party to this Indenture unless the Corporation has assured itself that such individual understands and has consented to the aforementioned uses and disclosures.

  • Compliance with FINRA Rules The Company hereby agrees that it will ensure that the Reserved Securities will be restricted as required by FINRA or the FINRA rules from sale, transfer, assignment, pledge or hypothecation for a period of three months following the date of this Agreement. The Underwriters will notify the Company as to which persons will need to be so restricted. At the request of the Underwriters, the Company will direct the transfer agent to place a stop transfer restriction upon such securities for such period of time. Should the Company release, or seek to release, from such restrictions any of the Reserved Securities, the Company agrees to reimburse the Underwriters for any reasonable expenses (including, without limitation, legal expenses) they incur in connection with such release.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!