Common use of Compliance with Progress Schedule Clause in Contracts

Compliance with Progress Schedule. Subcontractor shall commence preparatory and planning work immediately upon execution of this Subcontract Agreement and shall timely mobilize its forces to the Project site in order to commence its work in accordance with Contractor’s schedule included as part of the Contract Documents, or otherwise provided to Subcontractor by Contractor (the “Progress Schedule”). The Progress Schedule is attached hereto as an Attachment, and is subject to revision by Contractor from time to time. Subcontractor shall diligently prosecute its work in accordance with the Progress Schedule and all revisions thereto, it being expressly understood that Contractor has agreed to meet one or more dates of substantial completion for the Project as further set forth and defined in the Contract Documents, and that Contractor has undertaken that obligation to the Owner in reliance upon Subcontractor’s ability and promise to timely perform its work in accordance with the Progress Schedule. If Subcontractor, in the reasonable judgment of Contractor, fails to satisfactorily maintain its progress of the Subcontract Work, then Contractor may direct Subcontractor to cure the issues impeding Subcontractor’s progress and to take such steps as Contractor deems necessary to improve the rate of progress of the Subcontract Work, including requiring Subcontractor to increase the number of shifts and/or to pursue overtime operations, and to submit for approval a schedule demonstrating the manner in which the required rate of progress will be regained, all without additional cost to Contractor. If Subcontractor fails to commence or begin taking diligent steps to commence and continue with promptness to cure, in response to Contractor’s direction to cure the deficiencies impeding the rate of progress of Subcontractor’s Work, within 24 hours after receipt of written notice, Contractor may proceed as provided in Article XXI of this Subcontract Agreement.

Compliance with Progress Schedule. Subcontractor shall commence preparatory and planning work immediately upon execution of this Subcontract Agreement and shall timely mobilize its forces to the Project site in order to commence its work in accordance with Contractor’s schedule included as part of the Contract Documents, or otherwise provided to Subcontractor by Contractor (the “Progress Schedule”). The Progress Schedule is attached hereto as an Attachment, and is subject to revision by Contractor from time to time. Subcontractor shall diligently prosecute its work in accordance with the Progress Schedule and all revisions thereto, it being expressly understood that Contractor has agreed to meet one or more dates of substantial completion for the Project as further set forth and defined in the Contract Documents, and that Contractor has undertaken that obligation to the Owner in reliance upon Subcontractor’s ability and promise to timely perform its work in accordance with the Progress Schedule. If Subcontractor, in the reasonable judgment opinion of Contractor, fails to satisfactorily maintain its progress of the Subcontract Work, then Contractor may direct Subcontractor to cure the issues impeding Subcontractor’s progress and to take such steps as Contractor deems necessary to improve the rate of progress of the Subcontract Work, including requiring Subcontractor to increase the number of shifts and/or to pursue overtime operations, and to submit for approval a schedule demonstrating the manner in which the required rate of progress will be regained, all without additional cost to Contractor. If Subcontractor fails to commence or begin taking diligent steps to commence and continue with promptness to cure, in response to Contractor’s direction to cure the deficiencies impeding the rate of progress of Subcontractor’s Work, within 24 hours after receipt of written notice, Contractor may proceed as provided in Article XXI of this Subcontract Agreement.

Compliance with Progress Schedule. Subcontractor shall commence preparatory and planning work immediately upon execution of this Subcontract Agreement and shall timely mobilize its forces to the Project site in order to commence its work in accordance with Contractor’s 's schedule included as part of the Contract Documents, or otherwise provided to Subcontractor by Contractor (the “"Progress Schedule”"). The Progress Schedule is attached hereto as an Attachment, and is subject to revision by Contractor from time to time. Subcontractor shall diligently prosecute its work in accordance with the Progress Schedule and all revisions thereto, it being expressly understood that Contractor has agreed to meet one or more dates of substantial completion for the Project as further set forth and defined in the Contract Documents, and that Contractor has undertaken that obligation to the Owner in reliance upon Subcontractor’s 's ability and promise to timely perform its work in accordance with the Progress Schedule. If Subcontractor, in the reasonable judgment judgement of Contractor, fails to satisfactorily maintain its progress of the Subcontract Work, then Contractor may direct Subcontractor to cure the issues impeding Subcontractor’s 's progress and to take such steps as Contractor deems necessary to improve the rate of progress of the Subcontract Work, including requiring Subcontractor to increase the number of shifts and/or to pursue overtime operations, and to submit for approval a schedule demonstrating the manner in which the required rate of progress will be regained, all without additional cost to Contractor. If Subcontractor fails to commence or begin taking diligent steps to commence and continue with promptness to cure, in response to Contractor’s 's direction to cure the deficiencies impeding the rate of progress of Subcontractor’s 's Work, within 24 hours after receipt of written notice, Contractor may proceed as provided in Article XXI of this Subcontract Agreement.

Compliance with Progress Schedule. Subcontractor shall commence preparatory and planning work immediately upon execution of this Subcontract Agreement and shall timely mobilize its forces to the Project site in order to commence its work in accordance with Contractor’s schedule included as part of the Contract Documents, or otherwise provided to Subcontractor by Contractor (the “Progress Schedule”). The Progress Schedule is attached hereto as an Attachment, and is subject to revision by Contractor from time to time. Subcontractor shall diligently prosecute its work in accordance with the Progress Schedule and all revisions thereto, it being expressly understood that Contractor has agreed to meet one or more dates of substantial completion for the Project as further set forth and defined in the Contract Documents, and that Contractor has undertaken that obligation to the Owner General Contractor in reliance upon Subcontractor’s ability and promise to timely perform its work in accordance with the Progress Schedule. If Subcontractor, in the reasonable judgment of Contractor, fails to satisfactorily maintain its progress of the Subcontract Work, then Contractor may direct Subcontractor to cure the issues impeding Subcontractor’s progress and to take such steps as Contractor deems necessary to improve the rate of progress of the Subcontract Work, including requiring Subcontractor to increase the number of shifts and/or to pursue overtime operations, and to submit for approval a schedule demonstrating the manner in which the required rate of progress will be regained, all without additional cost to Contractor. If Subcontractor fails to commence or begin taking diligent steps to commence and continue with promptness to cure, in response to Contractor’s direction to cure the deficiencies impeding the rate of progress of Subcontractor’s Work, within 24 hours after receipt of written notice, . Contractor may proceed as provided in Article XXI of this Subcontract Agreement.

Compliance with Progress Schedule. Subcontractor shall commence preparatory and planning work immediately upon execution of this Subcontract Agreement and shall timely mobilize its forces to the Project site in order to commence its work in accordance with Contractor’s schedule included as part of the Contract Documents, or otherwise provided to Subcontractor by Contractor (the “Progress Schedule”). The Progress Schedule is attached hereto as an Attachment, and is subject to revision by Contractor from time to time. Subcontractor shall diligently prosecute its work in accordance with the Progress Schedule and all revisions thereto, it being expressly understood that Contractor has agreed to meet one or more dates of substantial completion for the Project as further set forth and defined in the Contract Documents, and that Contractor has undertaken that obligation to the Owner General Contractor in reliance upon Subcontractor’s ability and promise to timely perform its work in accordance with the Progress Schedule. If Subcontractor, in the reasonable judgment opinion of Contractor, fails to satisfactorily maintain its progress of the Subcontract Work, then Contractor may direct Subcontractor to cure the issues impeding Subcontractor’s progress and to take such steps as Contractor deems necessary to improve the rate of progress of the Subcontract Work, including requiring Subcontractor to increase the number of shifts and/or to pursue overtime operations, and to submit for approval a schedule demonstrating the manner in which the required rate of progress will be regained, all without additional cost to Contractor. If Subcontractor fails to commence or begin taking diligent steps to commence and continue with promptness to cure, in response to Contractor’s direction to cure the deficiencies impeding the rate of progress of Subcontractor’s Work, within 24 hours after receipt of written notice, . Contractor may proceed as provided in Article XXI of this Subcontract Agreement.

Compliance with Progress Schedule. Subcontractor shall commence preparatory and planning work immediately upon execution of this Subcontract Agreement and shall timely mobilize its forces to the Project site in order to commence its work in accordance with Contractor’s 's schedule included as part of the Contract Documents, or otherwise provided to Subcontractor by Contractor (the “"Progress Schedule”"). The Progress Schedule is attached hereto as an Attachment, and is subject to revision by Contractor from time to time. Subcontractor shall diligently prosecute its work in accordance with the Progress Schedule and all revisions thereto, it being expressly understood that Contractor has agreed to meet one or more dates of substantial completion for the Project as further set forth and defined in the Contract Documents, and that Contractor has undertaken that obligation to the Owner General Contractor in reliance upon Subcontractor’s 's ability and promise to timely perform its work in accordance with the Progress Schedule. If Subcontractor, in the reasonable judgment opinion of Contractor, fails to satisfactorily maintain its progress of the Subcontract Work, then Contractor may may, upon 24 hours written notice, direct Subcontractor to cure the issues impeding Subcontractor’s 's progress and to take such steps as Contractor deems necessary to improve the rate of progress of the Subcontract Work, including requiring Subcontractor to increase the number of shifts and/or to pursue overtime operations, and to submit for approval a schedule demonstrating the manner in which the required rate of progress will be regained, all without additional cost to Contractor. If Subcontractor fails to commence or begin taking diligent steps to commence and continue with promptness to cure, in response timely respond to Contractor’s 's direction to cure the deficiencies impeding the rate of progress of Subcontractor’s 's Work, within 24 hours after receipt of written notice, Contractor may proceed as provided in Article XXI of this Subcontract Agreement.

Compliance with Progress Schedule. Subcontractor shall commence preparatory and planning work immediately upon execution of this Subcontract Agreement and shall timely mobilize its forces to the Project site in order to commence its work in accordance with Contractor’s 's schedule included as part of the Contract Documents, or otherwise provided to Subcontractor by Contractor (the “"Progress Schedule”"). The Progress Schedule is attached hereto as an Attachment, and is subject to revision by Contractor from time to time. Subcontractor shall diligently prosecute its work in accordance with the Progress Schedule and all revisions thereto, it being expressly understood that Contractor has agreed to meet one or more dates of substantial completion for the Project as further set forth and defined in the Contract Documents, and that Contractor has undertaken that obligation to the Owner in reliance upon Subcontractor’s 's ability and promise to timely perform its work in accordance with the Progress Schedule. If Subcontractor, in the reasonable judgment opinion of Contractor, fails to satisfactorily maintain its progress of the Subcontract Work, then Contractor may direct Subcontractor to cure the issues impeding Subcontractor’s 's progress and to take such steps as Contractor deems necessary to improve the rate of progress of the Subcontract Work, including requiring Subcontractor to increase the number of shifts and/or to pursue overtime operations, and to submit for approval a schedule demonstrating the manner in which the required rate of progress will be regained, all without additional cost to Contractor. If Subcontractor fails to commence or begin taking diligent steps to commence and continue with promptness to cure, in response to Contractor’s 's direction to cure the deficiencies impeding the rate of progress of Subcontractor’s 's Work, within 24 hours after receipt of written notice, Contractor may proceed as provided in Article XXI of this Subcontract Agreement.

Compliance with Progress Schedule. Subcontractor shall commence preparatory and planning work immediately upon execution of this Subcontract Agreement and shall timely mobilize its forces to the Project site in order to commence its work in accordance with Contractor’s 's schedule included as part of the Contract Documents, or otherwise provided to Subcontractor by Contractor (the “"Progress Schedule”"). The Progress Schedule is attached hereto as an Attachment, and is subject to revision by Contractor from time to time. Subcontractor shall diligently prosecute its work in accordance with the Progress Schedule and all revisions thereto, it being expressly understood that Contractor has agreed to meet one or more dates of substantial completion for the Project as further set forth and defined in the Contract Documents, and that Contractor has undertaken that obligation to the Owner in reliance upon Subcontractor’s ability and promise to timely perform its work in accordance with the Progress Schedule. If Subcontractor, in the reasonable judgment opinion of Contractor, fails to satisfactorily maintain its progress of the Subcontract Work, then Contractor may direct Subcontractor to cure the issues impeding Subcontractor’s 's progress and to take such steps as Contractor deems necessary to improve the rate of progress of the Subcontract Work, including requiring Subcontractor to increase the number of shifts and/or to pursue overtime operations, and to submit for approval a schedule demonstrating the manner in which the required rate of progress will be regained, all without additional cost to Contractor. If Subcontractor fails to commence or begin taking diligent steps to commence and continue with promptness to cure, in response to Contractor’s 's direction to cure the deficiencies impeding the rate of progress of Subcontractor’s 's Work, within 24 hours after receipt of written notice, Contractor may proceed as provided in Article XXI of this Subcontract Agreement.

Compliance with Progress Schedule. Subcontractor shall commence preparatory and planning work immediately upon execution of this Subcontract Agreement and shall timely mobilize its forces to the Project site in order to commence its work in accordance with Contractor’s schedule included as part of the Contract Documents, or otherwise provided to Subcontractor by Contractor (the “Progress Schedule”). The Progress Schedule is attached hereto as an Attachment, and is subject to revision by Contractor from time to time. Subcontractor shall diligently prosecute its work in accordance with the Progress Schedule and all revisions thereto, it being expressly understood that Contractor has agreed to meet one or more dates of substantial completion for the Project as further set forth and defined in the Contract Documents, and that Contractor has undertaken that obligation to the Owner General Contractor in reliance upon Subcontractor’s ability and promise to timely perform its work in accordance with the Progress Schedule. If Subcontractor, in the reasonable judgment opinion of Contractor, fails to satisfactorily maintain its progress of the Subcontract Work, then Contractor may may, upon 24 hours written notice, direct Subcontractor to cure the issues impeding Subcontractor’s progress and to take such steps as Contractor deems necessary to improve the rate of progress of the Subcontract Work, including requiring Subcontractor to increase the number of shifts and/or to pursue overtime operations, and to submit for approval a schedule demonstrating the manner in which the required rate of progress will be regained, all without additional cost to Contractor. If Subcontractor fails to commence or begin taking diligent steps to commence and continue with promptness to cure, in response timely respond to Contractor’s direction to cure the deficiencies impeding the rate of progress of Subcontractor’s Work, within 24 hours after receipt of written notice, Contractor may proceed as provided in Article XXI of this Subcontract Agreement.

Compliance with Progress Schedule. Subcontractor shall commence preparatory and planning work immediately upon execution of this Subcontract Agreement and shall timely mobilize its forces to the Project site in order to commence its work in accordance with Contractor’s schedule included as part of the Contract Documents, or otherwise provided to Subcontractor by Contractor (the “Progress Schedule”). The Progress Schedule is attached hereto as an Attachment, and is subject to revision by Contractor from time to time. Subcontractor shall diligently prosecute its work in accordance with the Progress Schedule and all revisions thereto, it being expressly understood that Contractor has agreed to meet one or more dates of substantial completion for the Project as further set forth and defined in the Contract Documents, and that Contractor has undertaken that obligation to the Owner General Contractor in reliance upon Subcontractor’s ability and promise to timely perform its work in accordance with the Progress Schedule. If Subcontractor, in the reasonable judgment opinion of Contractor, fails to satisfactorily maintain its progress of the Subcontract Work, then Contractor may direct Subcontractor to cure the issues impeding Subcontractor’s progress and to take such steps as Contractor deems necessary to improve the rate of progress of the Subcontract Work, including requiring Subcontractor to increase the number of shifts and/or to pursue overtime operations, and to submit for approval a schedule demonstrating the manner in which the required rate of progress will be regained, all without additional cost to Contractor. If Subcontractor fails to commence or begin taking diligent steps to commence and continue with promptness to cure, in response to Contractor’s direction to cure the deficiencies impeding the rate of progress of Subcontractor’s Work, within 24 hours after receipt of written notice, .Contractor may proceed as provided in Article XXI of this Subcontract Agreement.